Seattle Washington Building Expert Directory

Formal Request for Time Extension Not Always Required to Support Constructive Acceleration

April 25, 2022 — David Adelstein - Florida Construction Legal Updates
Does a constructive acceleration claim require the contractor to always request an extension of time which is then denied by the owner? While this is certainly the preference and the contractor should be requesting an extension of time as a matter of course for an excusable delay, the answer is NO! in certain circumstances. This is conveyed in the factually detailed case discussed below where a formal request for an extension of time was not required for the contractor to support its constructive acceleration claim. But first, what is constructive acceleration: Constructive acceleration “occurs when the government demands compliance with an original contract deadline, despite excusable delay by the contractor.” The Federal Circuit in Fraser defined the elements of constructive acceleration as follows: (1) that the contractor encountered a delay that is excusable under the contract; (2) that the contractor made a timely and sufficient request for an extension of the contract schedule; (3) that the government denied the contractor’s request for an extension or failed to act on it within a reasonable time; (4) that the government insisted on completion of the contract within a period shorter than the period to which the contractor would be entitled by taking into account the period of excusable delay, after which the contractor notified the government that it regarded the alleged order to accelerate as a constructive change in the contract; and (5) that the contractor was required to expend extra resources to compensate for the lost time and remain on schedule. Nova Group/Tutor-Saliba v. U.S., 2022 WL 815826, *42 (Fed.Cl. 2022) quoting Fraser Constr. Co. v. U.S., 384 F.3d 1354, 1361 (Fed. Cir. 2004) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Traub Lieberman Attorneys Recognized as 2020 Super Lawyers and Rising Stars

November 16, 2020 — Traub Lieberman
Traub Lieberman is pleased to announce that Super Lawyers has named nineteen of our attorneys as 2020 Super Lawyers and Rising Stars. Super Lawyers selects attorneys using a multiphase selection process in which nominations and evaluations are combined with independent research. Each candidate is evaluated on 12 indicators of peer recognition and professional achievement. Selections are made on an annual, state-by-state basis. The objective is to create a credible, comprehensive and diverse listing of outstanding attorneys that can be used as a resource for attorneys and consumers searching for legal counsel. The Super Lawyers designation recognizes the top 5% of attorneys in the U.S. and the Rising Stars designation recognizes the top 2.5% of attorneys in the U.S. under the age of forty, as chosen by their peers and through independent research within their practice area. Read the court decision
Read the full story...
Reprinted courtesy of Traub Lieberman

Insurer Not Responsible for Insured's Assignment of Policy Benefits

February 21, 2022 — Tred R. Eyerly - Insurance Law Hawaii
The Florida Court of Appeals affirmed the lower court's granting summary judgment to the insurer after failing to abide by an assignment to which it was not a party. Expert Inspections, LLC v. United Property & Cas. Ins. Co., 2022 Fla. App. LEXIS 88 (Fla. Ct. App. Jan. 5, 2022). The insured's property sustained damage from Hurricane Irma resulting in a covered loss. The insured retained Expert Inspections to perform mold-related services. As payment, the insured assigned her policy benefits pursuant to an assignment of benefits agreement. Under the agreement, the insured agreed to cooperate with the assignee to ensure that payments were made by the insurer upon completion of work. The insured gave authority to the assignee to endorse any checks with her name listed on the check. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

2018 Legislative Changes Affecting the Construction Industry

June 06, 2018 — Melinda S. Gentile - Peckar & Abramson
The 2018 Florida Legislative Session recently concluded and a number of important construction-related House Bills (HB) and Senate Bills (SB) were presented during the Session. Florida Governor Rick Scott has 15 days to act on the legislation once each Bill has passed the House and Senate. Bills signed by the Governor go into effect on July 1, 2018, unless indicated otherwise. These Bills may impact General Contractors and Construction Managers in a number of ways, not the least of which is the period of time that a cause of action may be initiated for the design, planning or construction of an improvement. Read the court decision
Read the full story...
Reprinted courtesy of Melinda Gentile, Peckar & Abramson
Ms. Gentile may be contacted at mgentile@pecklaw.com

Contract Void Ab Initio: Key Insights into the KBR vs. Corps of Engineers Affirmative Defense

February 12, 2024 — Matthew DeVries - Best Practices Construction Law
In a recent Board decision dated December 13, 2023, the United States Army Corps of Engineers sought to amend its answer in the case of APPEALS OF – KELLOGG BROWN & ROOT SERVICES, INC., under Contract No. W912GB-13-C-0011. The proposed amendment introduces an affirmative defense, contending that Kellogg Brown & Root Services, Inc. (KBR) made material misrepresentations in its proposal, rendering the fully-performed contract void ab initio. Background: The contract in question, executed on July 9, 2013, was for the construction of an Aegis Ashore Missile Defense System site in Deveselu, Romania, with a firm, fixed-price amount of $134,211,592. The Corps moved to amend its answer to allege that KBR’s material misrepresentations induced the Corps to enter the contract, justifying the voiding of the contract. The alleged misrepresentations include issues related to subcontractor quotes, firm fixed prices, subcontracting plans, and more. Motion to Amend and Legal Defense: The Corps, despite delays in formally amending its answer, argued that KBR was aware of the potential affirmative defense before the conclusion of fact discovery. The proposed affirmative defense asserts that KBR made eight material misrepresentations in its proposal, upon which the Corps relied in awarding the contract and defending against a GAO protest. Read the court decision
Read the full story...
Reprinted courtesy of Matthew DeVries, Burr & Forman LLP
Mr. DeVries may be contacted at mdevries@burr.com

Building Inspector Refuses to State Why Apartments Condemned

August 06, 2014 — Beverley BevenFlorez-CDJ STAFF
In Lockport, New York, “more than two dozen tenants have been locked out of their apartment building…but they have yet to find out why,” according to WIVB news. Brian Belson, Lockport’s building inspector, condemned the building and ordered the tenants to leave, providing only 15 minutes advanced warning. Once all of the tenants were out, the first floor windows and doors were boarded up. At first, tenants were told that they would be able to return in a few days, but now they are being told it could be weeks. However, WIVB News reported that Brian Belson has not returned any of their phone calls, so they have “filed a Freedom of Information request at Town Hall, seeking that information.” Belson has five days to respond to the request. Read the court decision
Read the full story...
Reprinted courtesy of

Houston Home Sales Fall for the First Time in Six Months

March 19, 2015 — John Gittelsohn and Prashant Gopal - Bloomberg
(Bloomberg) -- Houston home sales fell in February for the first time in six months, a sign lower oil prices are spooking buyers. Sales of single-family houses dropped 5.8 percent from a year earlier to 4,521 homes, the Houston Association of Realtors reported Wednesday. Purchases fell among residences costing less than $150,000 because of tight supply, and among properties selling for more than $500,000 as wealthier buyers paused amid economic uncertainty, said James Gaines, research economist at Texas A&M University’s real estate center. “They don’t know what the real impact of falling oil prices is,” Gaines said in a telephone interview from College Station, Texas. “We’re living in the twilight of uncertainty.” Reprinted courtesy of John Gittelsohn, Bloomberg and Prashant Gopal, Bloomberg Mr. Gittelsohn may be contacted at johngitt@bloomberg.net Mr. Gopal may be contacted at pgopal2@bloomberg.net Read the court decision
Read the full story...
Reprinted courtesy of

Ohio Court of Appeals: Absolute Pollution Exclusion Bars Coverage For Workplace Coal-Tar Pitch Exposure Claims

January 24, 2018 — White and Williams LLP
On December 28, 2017, the Ohio Court of Appeals (Eighth District) held in GrafTech International, Ltd., et al. v. Pacific Employers Ins. Co., et al., No. 105258 that coverage for alleged injurious exposures to coal tar pitch was barred by a liability insurance policy’s absolute pollution exclusion. Applying Ohio law, the court concluded that Pacific Employers had no duty to defend GrafTech or pay defense costs in connection with claims by dozens of workers at Alcoa smelting plants that they were exposed to hazardous substances in GrafTech products supplied to Alcoa as early as 1942. Read the court decision
Read the full story...
Reprinted courtesy of White and Williams

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES