Seattle Washington Building Expert Directory

Pacing in Construction Scheduling Disputes

September 14, 2017 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway. However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

Hundreds Celebrated the Grand Opening of the Associated Builders and Contractors of Southern California Riverside Construction Training Center

February 14, 2023 — Associated Builders and Contractors
RIVERSIDE, Calif., Feb. 10, 2023 (GLOBE NEWSWIRE) -- Today the Associated Builders and Contractors Southern California Chapter (ABC), hosted hundreds of community members as they cut the "ribbon" of their third training center in Southern California. "Today is a celebration, but it also represents a continued commitment by ABC and our membership to supply a skilled, trained, and safe construction workforce for Southern California," stated Nick McFayden, ABC SoCal's Board Chair. Jon Krystafik, Vice Chairman of the Training Trust commented, "Our training facility is unique. You may have toured other facilities but with ours you will see we don't just train one craft. Here Apprentices and Craft trainees are receiving cutting edge training in Electrical, Plumbing, Low Voltage and HVAC/Sheet Metal." Krystafik added, "Our trustees had a dream 10 years ago to train residents in the inland empire. Today it is a reality!" ABC Southern California Chapter is an association of contractors that believe in the Merit Shop Philosophy. Merit shop encourages open competition and a free enterprise approach that awards contracts and employment based solely on merit, safety, quality, and cost, regardless of labor affiliation. The chapter is one of 68 throughout the country and represents nearly 400 member companies. Read the court decision
Read the full story...
Reprinted courtesy of

Safety Officials Investigating Death From Fall

September 09, 2011 — CDJ STAFF

California safety officials are looking into the circumstances surrounding the death of a construction worker who fell from a roof in Tiburon, California. Another worker found Gabriel Vasquez unconscious at the site. Vasquez was later pronounced dead. The State Division of Occupational Safety and Health are trying to determine how Vasquez fell.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

Colorado Adopts Twombly-Iqbal “Plausibility” Standard

July 14, 2016 — Jesse Howard Witt – The Witt Law Firm Blog, Acerbic Witt
Last week, the Colorado Supreme Court announced a dramatic shift in its rules of pleading, adopting the federal courts’ requirement that a claim must be “plausible on its face” to survive a motion to dismiss. Although seemingly subtle, this change transfers much more power to district court judges and weakens the right to a jury in civil actions. For decades in Colorado, courts have held that a plaintiff’s complaint need merely provide a defendant with notice of the transaction that caused an alleged injury. Judges would not dismiss the complaint unless it appeared “beyond doubt” that the plaintiff could prove “no set of facts” which would entitle him or her to relief. See Davidson v. Dill, 180 Colo. 123, 131, 503 P.2d 157, 162 (1972), quoting Conley v. Gibson, 355 U.S. 41 (1957). This was rooted in the notion that the civil jury was the ultimate arbiter of disputed facts in American jurisprudence. Every party was entitled to have his or her “day in court” and present claims to a group of jurors selected from the community, rather than a judge appointed by the governor. Reprinted courtesy of Jesse Howard Witt, Acerbic Witt Mr. Witt welcomes comments at www.witt.law Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

How Do You Get to the Five Year Mark? Some Practical Advice

August 26, 2015 — Christopher G. Hill – Construction Law Musings
For this week’s Guest Post Friday here at Construction Law Musings, we would like to welcome back (again) Sean Lintow Sr. of SLS Construction & Building Solutions . Sean has over 20 years working directly in the trenches in the construction arena. Since moving to Illinois, the focus of his business has shifted to helping builders, trade professionals& even code officials not only understand and meet the latest energy codes but how to improve their methods to accomplish it better and more affordably. Currently he is RESNET Rater, AEE CEA (Certified Energy Auditor), ENERGY STAR partner & verifier, EPA Indoor airPLUS verifier, Level 2 Infrared Thermographer, Volunteer Energy Rater for Habitat for Humanity, and Builders Challenge Partner & Verifier. You may also want to check out his great resources on The HTRC (Homeowners & Trades Resource Center). I would like to thank Chris for inviting me back for my 6th musing on this great site. I would also like to give him a Belated Happy Birthday for reaching 5 years since going solo. Reaching five years is a big milestone for many businesses as most new ventures (I think it is 85% or maybe even 90%) fail during that time. Therefore, a big congrats to you Chris & here is to another five plus years. For the most part the blame game for failure comes down to; wrong product offerings (market to saturated, not interested in, etc…), their ability to market, or poor business skills (not charging enough, realizing what they are spending, etc…) as the main point of failures. There is another group though that never seems to get much press and that is the ones that seemingly are blindsided by the dreaded “ignorance of the law” is no excuse… Not only does this effect many large companies but also many solo operations which is where I do want to focus today, especially on 4 “lesser” known issues. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, Law Office of Christopher G. Hill, PC
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Contractor's Agreement to Perform Does Not Preclude Coverage Under Contractual Liability Exclusion

January 31, 2014 — Tred R. Eyerly – Insurance Law Hawaii
In a much anticipated decision, the Texas Supreme Court ruled that a general contractor who agrees to perform its work in a good and workmanlike manner does not "assume liability" for damages arising out of its defective work so as to trigger the Contractual Liability Exclusion. Ewing Constr. Co., Inc. v. Amerisure Ins. Co., 2014 Tex. LEXIS 39 (Tex. Jan.17, 2014). Ewing signed an agreement with the School District to serve as general contractor to renovate and build additions to a school, including tennis courts. After construction was completed, the tennis courts started flaking, crumbling, and cracking. The School District filed suit, alleging breach of contract and negligence. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

No Indemnity After Insured Settles Breach of Implied Warranty of Habitability Claims

June 09, 2016 — Tred R. Eyerly – Insurance Law Hawaii
Applying Illinois law, the federal district court ruled that there was no coverage for the insured's settlement of claims based upon breach of the implied warranty of habitability. Allied Prop. & Cas. Ins. Co. v. Metro North Condo. Ass'n, 2016 U.S. Dist. LEXIS 43452 (E.D. Ill. March 31, 2016). Metro North sued the developer of its condominium and a number of its contractors and subcontractors for defective construction that caused various problems, including water infiltration. One subcontractor, CSC, was to provide window and glazing services. After a rainstorm, water infiltrated the project due to CSC's work. Metro North claimed that CSC was liable for breach of the implied warranty of habitability. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Charges in Kansas Water Park Death

March 28, 2018 — David Suggs - CDJ STAFF
Caleb Schwab, a 10-year old boy was killed by decapitation on a water slide at a Kansas City water park, Schlitterbahn in 2016. Thirteen other people had suffered injuries on the ride prior to Caleb’s death ranging in severity from broken toes to concussions. Schlitterbahn employees have since claimed that park officials covered up past occurrences of water slide injuries. Three people have been indicted in this case according to a CNN report by Marlena Baldacci, Sheena Jones and Hollie Silverman. Jeffrey Henry, the co-owner of the Schlitterbahn water park, Tyler Austin Miles, the park’s former director of operations and John Schooley. Charges include second-degree murder, involuntary manslaughter, aggravated battery and aggravated child endangerment. Caleb suffered a fatal injury when the raft that he and the two women who were riding with him became airborne and contacted the netting attached overhead. Investigators have found maintenance issues and ride design flaws that violate safety standards leading to lack of prevention of rafts becoming airborne during the ride. Caleb’s family will receive nearly $20 million in the settlement. Caleb’s father Scott, released a statement about placing full trust in the Attorney General Derek Schmidt who is presiding over the investigation and indictments. Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES