A Changing Climate for State Policy-Making Regarding Climate Change
February 18, 2020 —
Sheila McCafferty Harvey - Gravel2Gavel Construction & Real Estate Law BlogIssued by 13 federal agencies, the 2018 Fourth National Climate Assessment presented a stark warning on the consequences of climate change for the United States. The report predicts that if significant steps are not taken to rein in global warming, the damage will reduce the U.S. economy by as much as 10 percent by the end of the century. The report, which was mandated by Congress and made public by the White House, is notable not only for the precision of its calculations and bluntness of its conclusions—the 1,656-page assessment lays out the devastating effects of a changing climate on the economy—but also in how it conflicts with President Donald Trump’s environmental deregulation plan. U.S. policy efforts at the state and local levels are ramping up to address this complex topic. These include:
Targeting Net-Zero Emissions. Hailed as the most aggressive climate law in the nation, New York State’s Climate Leadership and Community Protection Act are targeting 100 percent carbon-free electricity by 2040 and economy-wide, net-zero carbon emissions by 2050. California set a statewide target to reach carbon neutrality by 2045.
Reducing and Renewing. New Mexico established a statewide goal of reducing greenhouse gas emissions by 45 percent below 2005 levels by 2030. Nevada passed a bill to increase the amount of electricity it gets from renewable resources to 50 percent by 2030.
Read the court decisionRead the full story...Reprinted courtesy of
Sheila McCafferty Harvey, PillsburyMs. Harvey may be contacted at
sheila.harvey@pillsburylaw.com
Cape Town Seeks World Cup Stadium Construction Collusion Damages
March 19, 2015 —
Janice Kew – Bloomberg(Bloomberg) -- The City of Cape Town filed a civil damages claim against builders Aveng Ltd., Wilson Bayly Holmes-Ovcon Ltd. and Stefanutti Stocks Holdings Ltd. for colluding on a tender for a stadium built for the 2010 FIFA Soccer World Cup.
The claim for at least 428 million rand ($35 million) will be heard in the North Gauteng High Court, Ian Neilson, Cape Town’s executive deputy mayor, said by phone on Monday. The amount claimed is subject to change, he said.
Antitrust authorities fined 15 builders, including the trio facing the Cape Town claim, a total of 1.5 billion rand in June 2013 for rigging contracts for projects including the construction of stadiums for the 2010 World Cup hosted by South Africa. Aveng was fined 307 million rand, WBHO 311 million rand and Stefanutti 307 million rand.
Read the court decisionRead the full story...Reprinted courtesy of
Janice Kew, BloombergMs. Kew may be contacted at
jkew4@bloomberg.net
APROPLAN and GenieBelt Merge, Creating “LetsBuild” – the Build Phase End-to-End Digital Platform
March 18, 2019 —
Aarni Heiskanen - AEC BusinessResponding to a rising need to deliver an all-in-one solution, supporting on-site planning, progress communication, snagging, drawings and checklists, GenieBelt and APROPLAN have decided to merge to form LetsBuild – the European leader in delivering an end-to-end solution to the global construction industry.
For the past five years, GenieBelt CEO Klaus Nyengaard and APROPLAN CEO Thomas Goubau have met on a regular basis to discuss developments in the construction technology sector and how to increase efficiency and minimise rework, miscommunication, and errors.
“We share the vision that ‘simple to use’-products will bring immense value to the construction sector. When we met in October 2018, we concluded that the way to realize this vision was to unite our companies to create a broader product and cover more needs in the market,” says LetsBuild CEO Klaus Nyengaard.
Read the court decisionRead the full story...Reprinted courtesy of
Aarni Heiskanen, AEC BusinessMr. Heiskanen may be contacted at
aec-business@aepartners.fi
Home Prices in 20 U.S. Cities Kept Climbing in January
April 06, 2016 —
Victoria Stilwell – BloombergHome values in 20 U.S. cities kept climbing in January, a sign the limited supply of available properties may push prices out of reach for some buyers.
The S&P/Case-Shiller index of property values increased 5.7 percent from January 2015, following a 5.6 percent gain in the year ended in December, the group said Tuesday in New York. That matched the median projection of 26 economists surveyed by Bloomberg. Nationally, prices rose 5.4 percent year-over-year.
Home values that are rising more quickly than incomes could pose a problem for the housing recovery, as they put purchases out of reach for first-time and low-income buyers. A wider selection of available homes will be needed to help keep price increases in an accessible range.
Read the court decisionRead the full story...Reprinted courtesy of
Victoria Stilwell, Bloomberg
Are COVID-19 Claims Covered by Builders Risk Insurance Policies?
May 04, 2020 —
Jason M. Adams, Gibbs Giden Locher Turner Senet & Wittbrodt LLP and Cheryl L. Kozdrey, Saxe Doernberger & Vita, P.C.If you are an attorney, insurance broker, or other professional representing developers and contractors, then your clients have likely reached out with concerns about losses related to COVID-19. One common question is whether there is potential coverage under builders risk insurance policies.
The short answer is: It depends. As with most questions pertaining to insurance coverage, the answers depend on the specific policy language and underlying facts required to trigger coverage. Builders risk policies are even more fact specific due to the lack of uniformity of base policy forms and endorsements between insurance carriers.
The first step in any analysis is to gather facts and carefully document any impending and potential damages or delays. The facts are crucial because the coverage analysis may vary depending on the specific reason the project was shut down. For example, the analysis would be different if the project was shut down as a result of an express government order, such as those in Northern California and Washington, versus the project shutting down as a result of workers testing positive for COVID-19. Properly analyzing builders risk coverage involves a granular account of the facts and damages, and can require a great deal of hair splitting with respect to specific policy language.
Regardless of the strength of the insured’s facts and damages, or the breadth of its policy language, the policyholder still likely faces an uphill battle in finding coverage for COVID-19 related claims. The unfortunate reality of most builders risk policies is that they are property policies that require some evidence of physical loss or damage to trigger coverage. Whether or not COVID-19 claims constitute property damage will be the subject of great debate and litigation over the coming months and years. The outcome will likely depend on how the insured’s jurisdiction ultimately rules on the litany of COVID-19 cases that have already been filed – specifically, how broadly each court interprets the meaning of “physical loss or damage.”
Although these key issues have yet to be clearly defined by the courts, some policies are better than others and there are specific variables that could affect the likelihood of coverage. For example, some of the more policyholder-friendly insurance programs may contain coverage extensions for delay in completion, business interruption, loss of rental income, or civil authority that may not be tied to the property damage requirement, and which would tend to support coverage for COVID-19 claims.
Even if the insured crosses the initial threshold and can demonstrate a covered claim, the following common endorsements and exclusions may require additional analysis depending on the facts.
- Virus or Pandemic Exclusions: Virus or pandemic exclusions are not as common on builders risk policies as they may be on other forms of coverage. However, they do exist and, if present, result in a significant barrier to coverage. As with the policy itself, every endorsement is different and should be analyzed in terms of the express language contained in the endorsement and the facts.
- Abandonment or Cessation of Work: Most builders risk policies include provisions that preclude coverage in the event of the abandonment of the project or a lengthy cessation of work. As a result, the insured should take steps to articulate to the carrier that the project has not been abandoned, and that there exists an intent to return as soon as possible. The insured should also maintain a record of ongoing project oversight and protection efforts taken during the period when construction operations are suspended.
- Security and Safety Requirements: Many builders risk policies contain provisions requiring the insured to maintain protective safeguards and security protocols throughout the pendency of the project. Safety fencing, lighting and security guards are common examples. The policy should be analyzed to ensure that the policyholder can meet any such requirements during a COVID-19 related shutdown. For example, can the insured continue to staff a security guard? If not, arrangements will likely need to be made with the carrier depending on the language of the policy.
- Insurable Limits: Builders risk policies are typically underwritten based upon the total completed value of the structure, including materials and labor. The insured will need to analyze the policy to consider whether increased material or labor costs as a result of COVID-19 will alter the terms of coverage, trigger any escalation clauses, or result in an increase in premium due. If increased cost projections become apparent, the insured should report these changes to the carrier immediately.
- Extensions of Coverage: The insurance industry was facing a hard market even before the COVID-19 pandemic, which resulted in higher premiums and limited coverage options. The COVID-19 pandemic has only exacerbated these issues and it may be difficult to obtain coverage extensions on projects that have been shut down. The insured should work with its risk management team (risk manager, insurance broker and lawyer) to engage the carriers to negotiate any necessary coverage extensions resulting from COVID-19 related project delays.
To summarize, builders risk coverage for COVID-19 claims is far from certain, but not impossible. Insureds should provide notice of a claim to all potentially applicable carriers in order to preserve their rights. The insured should also report increased construction cost and articulate its intent to return to the project to preserve their escalation clause and avoid arguments that they have abandoned the project. The insured should continue to document its claims and damages, and be ready to substantiate its claims and push back on any coverage denial. Throughout the entirety of this process, the insured should work with its risk management team to get out in front of any extensions it may need to complete the project. In a climate where insurance carriers are receiving an insurmountable number of claims, the insured should be prepared to fight for coverage and not simply throw up its hands in the face of a denial. Given the intense social, legislative and executive pressure to cover COVID-19 claims, there may be a tendency for the courts to find coverage in gray areas, particularly if the insured was fortunate enough to have purchased one of the broader coverage forms referenced above.
About the Authors
Jason M. Adams, Esq. (jadams@gibbsgiden.com) is a partner at Gibbs Giden representing construction professionals in the areas of Construction Law, Insurance Law and Risk Management and Business/Civil Litigation. Adams is also a licensed property and casualty insurance broker and certified Construction Risk & Insurance Specialist (CRIS). Jason represents developers, contractors, public entities, investors, lenders, REITs, design professionals, and other construction professionals at all stages of the construction process. Jason is a published author and sought-after speaker at seminars across the country regarding high level construction risk management and insurance topics. Gibbs Giden is nationally and locally recognized by U. S. News and Best Lawyers as among the “Best Law Firms” in both Construction Law and Construction Litigation. Chambers USA Directory of Leading Lawyers has consistently recognized Gibbs Giden as among California’s elite construction law firms.
Cheryl L. Kozdrey, Esq. (clk@sdvlaw.com) is an associate at Saxe Doernberger & Vita, P.C., a national insurance coverage law firm dedicated exclusively to policyholder representation and advocacy. Cheryl advises insurance brokers, risk managers, and construction industry professionals regarding optimal risk transfer strategies and insurance solutions, including key considerations for Builder’s Risk, Commercial General Liability, D&O, and Commercial Property policies. She assists clients with initial policy reviews, as well as renewals and modification(s) of existing policies to ensure coverage needs are satisfied. Cheryl also represents policyholders throughout the claims process, and in coverage dispute litigation against insurance carriers. She is currently working on some of the largest construction defect cases in the country. Cheryl is a published author and is admitted to practice in the State of California and all federal district courts within the State.
Read the court decisionRead the full story...Reprinted courtesy of
Hawaiian Electric Finalizes $2 Billion Maui Fire Settlement
November 18, 2024 —
Mark Chediak - BloombergHawaiian Electric Industries formalized a $2 billion agreement to settle damage claims from a wildfire that razed the historic town of Lahaina and killed more than 100 people.
The utility-owner had reached a tentative agreement in August in which it, along with other defendants including the state of Hawaii, Maui County and landowners, would pay $4 billion to resolve hundreds of lawsuits stemming from last year’s wildfire, according to a filing Tuesday.
The settlements don’t resolve claims with insurers that are part of separate lawsuits.
Read the court decisionRead the full story...Reprinted courtesy of
Mark Chediak, Bloomberg
Remote Depositions in the Post-Covid-19 World
September 06, 2021 —
Islam M. Ahmad - Wilke Fleury, LLPDespite the easing of COVID-19 restrictions in California, many of the changes imposed on the legal industry by the pandemic will likely remain in effect for the foreseeable future. One major change for litigators has been conducting depositions remotely. This change takes an already intricate task and makes it further complex by adding a new dimension of factors to consider. It is imperative that litigators understand these factors to avoid giving their opposition an undue advantage and to maximize the utility of depositions. While we may disagree as to whether remote depositions are a welcome change, the fact of the matter is that lawyers must adapt to them and provide adequate legal representation. This article explores some of the challenges and opportunities presented by remote depositions.
- The Deponent
The deponent is the single most important element of any deposition and handing it properly becomes even more delicate in remote settings. I recently took a deposition where the plaintiff met their attorney for the first time at their deposition. The result was not spectacular. The plaintiff was ill-prepared, and the case eventually settled for far less than what it might have if it had been better prepared.
Read the court decisionRead the full story...Reprinted courtesy of
Islam M. Ahmad, Wilke Fleury, LLPMr. Ahmad may be contacted at
iahmad@wilkefleury.com
Design Firm Settles over Construction Defect Claim
July 31, 2013 —
CDJ STAFFA Pennsylvania township has announced that it has reached a settlement with the architectural firm that designed its administration building. Cee Jay Frederick Associates will be paying than $1.05 million to settle claims of defects in the design of the building.
West Whiteland’s administration building was completed in July 2007. The first leaks were noticed in November and December 2008. In response, the township stopped payments to the contractor, Magnum, Inc. Magnum sued, claiming that their work was not to blame for the leaks. Magnum joined the township in suing the design firm.
Although Cee Jay Frederick Associates will be paying the township to settle the claim, West Whiteland will be paying $75,000 of that back to the firm to settle outstanding bills that had been withheld during litigation.
Read the court decisionRead the full story...Reprinted courtesy of
