Seattle Washington Building Expert Directory

Fundamental Fairness Trumps Contract Language

September 24, 2014 — Craig Martin – Construction Contractor Advisor
The Texas Supreme Court recently ruled that a “no-damages-for-delay” clause would not be enforced where the delay was caused by the owner. The court’s ruling flies squarely in the face of the contract language that attempted to insulate the owner from any delay claims, even those it caused. In the case of Zachary Construction v. Port of Houston underlying contract, proposed by the Port of Houston, was heavy handed, to say the least. The contract provided: “[Contractor] shall receive no financial compensation for delay or hindrance to the Work. In no event shall the Port Authority be liable to [Contractor] … for any damages arising out of or associated with any delay or hindrance to the Work, regardless of the source of the delay or hindrance, including events of Force Majeure, AND EVEN IF SUCH DELAY OR HINDRANCE RESULTS FROM, ARISES OUT OF OR IS DUE IN WHOLE OR IN PART, TO THE NEGLIGENCE, BREACH OF CONTRACT OR OTHER FAULT OF THE PORT AUTHORITY. [Contractor’s] sole remedy in any such case shall be an extension of time.” Wow, that’s some one-sided language. If the contract was enforced, the contractor could not get any damages for delay, even those damages caused by the active interference of the Port of Houston. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

Can a Lease Force a Tenant's Insurer to Defend the Landlord?

October 10, 2022 — Kerianne Kane Luckett - Saxe Doernberger & Vita, P.C.
Can an indemnification clause in a commercial lease obligate a tenant’s insurer to defend a landlord? Recently, the United States District Court for the Northern District of New York said, “Yes!” On August 9, 2022, the district court issued a decision in ConMed Corp. vs. Federal Insurance Company, holding that the indemnification clause in a policyholder’s lease triggered the insurer’s duty to defend the landlord in an action arising out of the tenant’s negligence. Facts of the Case ConMed is a medical technology company that leases warehouse space in Georgia from Breit Industrial Canyon (“the Landlord”) to sterilize its medical equipment. ConMed’s employees filed suit against ConMed and a contractor that performed the sterilization, alleging injuries caused by exposure to excessive amounts of chemicals used in the sterilization process (the “ConMed Action”). Thereafter, ConMed’s employees filed a separate lawsuit against the Landlord, alleging that the Landlord permitted storage of unsafe levels of the chemicals at the warehouse without adequate ventilation (the “Landlord Action”). The lease agreement required ConMed to indemnify the Landlord “except in the event of, and to the extent of, Landlord’s negligence or willful misconduct.” Read the court decision
Read the full story...
Reprinted courtesy of Kerianne Kane Luckett, Saxe Doernberger & Vita, P.C.
Ms. Luckett may be contacted at KKane@sdvlaw.com

Traub Lieberman Attorneys Recognized as 2021 Top Lawyers by Hudson Valley Magazine

February 08, 2021 — Traub Lieberman
Thirteen Traub Lieberman attorneys have been named 2021 Top Lawyers by Hudson Valley magazine. The honored attorneys represent the firm's Hawthorne New York office and six practice areas. Hudson Valley magazine uses online peer-voting and an internet search process to select outstanding lawyers from more than 30 practice areas, who have attained a high degree of peer recognition and professional achievement. "We are very proud of all of our attorneys for being recognized as among the top lawyers in the Hudson Valley,” said Partner and Vice-Chair Lisa Shrewsberry. Related Attorneys: Sara Kiridly, Mario Castellitto, Colleen E. Hastie, Timothy G. McNamara, Robert S. Nobel, Richard J. Rogers, Adam Krauss, Taylor C. Eagan, Stephen D. Straus, Lisa L. Shrewsberry, Lisa M. Rolle, Jonathan R. Harwood, Hillary J. Raimondi Read the court decision
Read the full story...
Reprinted courtesy of Traub Lieberman

Waiving The Right to Arbitrate Under Federal Law

November 08, 2021 — David Adelstein - Florida Construction Legal Updates
If there is an arbitration provision in your contract that you want to enforce, you do not want to take action inconsistent with those rights as this could give rise to a waiver argument, i.e., that you waived your rights to arbitrate, particularly if the other party has been prejudiced. Under federal policy and law, establishing waiver requires the party arguing waiver to “bear a heavy burden of proof.” U.S. f/u/b/o John Wayne Construction, G.S.A. Division, LLC v. Federal Ins. Co., 2021 WL 4526727 (M.D.Fla. 2021) quoting Stone v. E.F. Hutton & Co., 898 F.2d 1542, 1543 (11th Cir. 1990). “To determine whether the right to arbitrate has been waived, courts apply a two part test: i) whether, “‘under the totality of the circumstances,’ the party ‘has acted inconsistently with the arbitration right’”; and ii) “whether, by doing so, that party ‘has in some way prejudiced the other party.’” Id. quoting Ivax Corp. V. B. Braun of Am., Inc., 286 F.3d 1309, 1315-16 (11th Cir. 2002). Substantial participation in litigation prior to invoking the right to arbitrate supports a party acting inconsistent with the right to arbitrate. Id. And, “‘[p]rejudice has been found in situations where the party seeking arbitration allows the opposing party to undergo the types of litigation expenses that arbitration was designed to alleviate.’” Id. quoting Morewitz v. W. of Eng. Ship Owners Mut. Prot. & Indem. Ass’n (Luxembourg), 62 F.3d 1356, 1366 (11th Cir. 1995). Hence the heavy burden for a party to support to prove waiver– establishing both substantial participation in litigation that is inconsistent with the right to arbitrate AND prejudice. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Another Reminder that Your Construction Contract Language Matters

June 06, 2018 — Christopher G. Hill - Construction Law Musings
Here at Musings, I have often (some might say too often) discussed the fact that in Virginia (as well as other places), your construction contract language will be strictly enforced. I have also discussed the need for attorney fees provisions as well as other language in order to mitigate your risk as a contractor. A recent case from the City of Roanoke Circuit Court discussed both of these principals and their intersection. In LAM Enterprises, LLC v. Roofing Solutions, Inc., the Roanoke Court looked at a contract between LAM and Roofing Solutions, Inc. that contained two provisions of the construction contract between the parties. The first provision limited the liability of Roofing Solutions to the contract price. The second provision is a relatively typical “prevailing party” attorney fees provision in which the winner of any lawsuit would be entitled to collect its attorney fees. For the specific language of these provisions, I commend the opinion linked above for your reading. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Seventh Circuit Remands “Waters of the United States” Case to Corps of Engineers to Determine Whether there is a “Significant Nexus”

July 10, 2018 — Anthony B. Cavender - Gravel2Gavel Construction & Real Estate Law Blog
On June 27, the U.S. Court of Appeals for the Seventh Circuit decided the case of Orchard Hill Building Co. v. U.S. Army Corps of Engineers. The Court of Appeals vacated the decision of the District Court granting the U.S. Army Corps of Engineers’ (Corps) motion for summary judgment dismissing the Orchard Hill Building Company’s (Orchard) complaint that the Corps’ jurisdictional determination erroneously found that the waters at issue were “jurisdictional waters” under the Clean Water Act (CWA) subject to the Corps’ jurisdiction. Acknowledging that the Corps and EPA had promulgated a new rule re-defining “waters of the United States” in 2015—which is now being challenged in the courts—the Court of Appeals noted that this case is controlled by the pre-2015 definition of “waters of the United States.” The Court of Appeals remanded the case to the Corps, directing it to determine if there was a significant nexus, as required. Read the court decision
Read the full story...
Reprinted courtesy of Anthony B. Cavender, Pillsbury Winthrop Shaw Pittman LLP
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

Climate Change a Factor in 'Unprecedented' South Asia Floods

July 18, 2022 — The Associated Press (Aniruddha Ghosal & Al-Emrun Garjon) - Bloomberg
Sylhet, Bangladesh (AP) -- Scientists say climate change is a factor behind the erratic and early rains that triggered unprecedented floods in Bangladesh and northeastern India, killing dozens and making lives miserable for millions of others. Although the region is no stranger to flooding, it typically takes place later in the year when monsoon rains are well underway. This year's torrential rainfall lashed the area as early as March. It may take much longer to determine the extent to which climate change played a role in the floods, but scientists say that it has made the monsoon — a seasonable change in weather usually associated with strong rains — more variable over the past decades. This means that much of the rain expected to fall in a year is arriving in a space of weeks. Read the court decision
Read the full story...
Reprinted courtesy of Bloomberg

Congratulations to Haight Attorneys Selected to the 2021 Southern California Super Lawyers List

January 25, 2021 — Haight Brown & Bonesteel LLP
Eight Haight attorneys have been selected to the 2021 Southern California Super Lawyers list. Congratulations to:

Read the court decision
Read the full story...
Reprinted courtesy of Haight Brown & Bonesteel LLP

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES