Fairfield Connecticut Building Expert Directory

Recovering Unabsorbed Home Office Overhead Due to Delay

May 30, 2022 — David Adelstein - Florida Construction Legal Updates
In the preceding article, I discussed the use of a retrospective as-built delay analysis in a case before the Civilian Board of Contract Appeals (CBCA). This case also discussed a damages component in certain delay claims known as unabsorbed home office overhead—a challenging damages component to recover because this deals with indirect costs as opposed to direct costs. Unabsorbed home office overhead is a damages component when the contractor is on standby, but this is NOT as easy as just claiming standby thereby you are automatically entitled to unabsorbed home office overhead. There are requirements that MUST be met.

To obtain an equitable adjustment for unabsorbed home office overhead as compensation for being on standby, [the contractor] must initially show “[1] a government-caused delay of uncertain duration,” that “[2] the delay extended the original time for performance” or precluded the contractor from finishing earlier than scheduled, and that “[3] the contractor [was] on standby and unable to take on other work during the delay period. CTA I, LLC v. Department of Veteran Affairs, CBCA 5826, 2022 WL 884710 (CBCA 2022) quoting Nicon, Inc. v. U.S., 331 F.3d 878, 883 (Fed. Cir. 2003).

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Insurance Policy’s “No Voluntary Payment” Clauses Lose Some Bite in Colorado

October 22, 2013 — Brady Iandiorio — Higgins, Hopkins, McLain & Roswell, LLC.
The Colorado Court of Appeals recently handed down an opinion dulling the teeth of the “no voluntary payment” clauses found in many contractors’ insurance policies. In the case of Stresscon Corporation v. Travelers Property Casualty Company of America, 2013 WL 4874352 (Colo. App. 2013), the Court of Appeals found that an insured’s breach of the “no voluntary payment” clause does not always bar the insured from receiving benefits from its insurance company. In July 2007, at a construction project run by Mortenson (the “GC”), a partially erected building collapsed, killing one worker and gravely injuring another. The collapse was caused by a crane hook pulling a concrete component off of its supports. The GC contracted with Stresscon Corporation (“Stresscon”) to build pre-cast concrete components for the project, and in turn Stresscon hired two sub-subcontractors, RMS and Hardrock (the “Crane Team”) to work together to erect those concrete components. Stresscon and the Crane Team had liability insurance, and Stresscon was insured by Travelers Property Casualty Company of America (“Travelers”). The accident led to three separate lawsuits: 1) one brought by the deceased worker; 2) one brought by the injured worker; and 3) one brought by the GC against Stresscon claiming it was entitled to contract damages incurred because the project was delayed. Read the court decision
Read the full story...
Reprinted courtesy of Brady Iandiorio
Brady Iandiorio can be contacted at Iandiorio@hhmrlaw.com

California Supreme Court Adopts Vertical Exhaustion for Long-Tail Claims

June 15, 2020 — Tred R. Eyerly - Insurance Law Hawaii
In another round of litigation involving coverage issues between Montrose Chemical Corporation and its insurers, the California Supreme Court ruled in favor of Montrose, adopting vertical exhaustion of excess policies. Montrose Chem. Corp. of Calif. v. The Superior Court of Los Angeles County, 9 Ca. 5th 215 (2020). In 1990, the United States and the State of California sued Montrose for contamination from 1947 to 1982 caused by Montrose's facility manufacturing insecticides. Montrose had primary and excess liability policies from defendant insurers between 1961 and 1985. Forty insurers collectively issued more than 115 excess policies, which collectively provided coverage sufficient to indemnify Montrose's anticipate total liability. Primary coverage was exhausted. Each excess policy provided that Montrose had to exhaust the limits of its underlying coverage before there would be excess coverage. Which excess carrier could be called on first was the issued before the California Supreme Court. Montrose proposed a rule of "vertical exhaustion" or "elective stacking," whereby it could access any excess policy once it exhausted other policies with lower attachment points in the same policy period. The insurers, in contract, argued for "horizontal exhaustion," whereby Montrose could access an excess policy only after it exhausted other policies with lower attachment points from every policy period in which the environmental damage resulting in liability occurred. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Green Home Predictions That Are Best Poised to Come True in 2014 and Beyond (guest post)

July 16, 2014 — Melissa Dewey Brumback – Construction Law in North Carolina
Today, a guest post on the green design issues that are becoming realities from Penny Olmos, who is associated with Holloway Houston, Inc. a leading industrial lifting equipment manufacturing company. Welcome, Penny! The scorching heat singed us and the winter wave chilled us — more than ever before. What are we heading to? Earthquakes, volcanoes, tsunamis, tornadoes and extreme temperatures? Mother Nature is warning us in myriad ways. And the good news is that we are heeding her calls after long. Saving our natural resources and going green has found many takers. We have seen many eco-friendly homes and buildings designed and created in the last decade. Green homes are here to stay. We look at the popular green home design and construction trends in 2014 that are about to transform the landscape of green realty. Rise of Net Zero Energy Homes It seemed impossible until a couple of years ago but 2014 will witness a rise in net zero energy homes. These are homes with zero net energy consumption. The total amount of energy used by these buildings annually equals the amount of renewable energy created on the property. This is the greenest and the most energy efficient house you can possess. And you do not need to cut down on any of your comforts. There are heating, cooling, entertainment and utility appliances functioning in the house like they would in any other home. Read the court decision
Read the full story...
Reprinted courtesy of Melissa Dewey Brumback, Construction Law in North Carolina
Ms. Brumback may be contacted at mbrumback@rl-law.com

Architectural Democracy – Interview with Pedro Aibéo

July 13, 2017 — Aarni Heiskanen - AEC Business
In this podcast interview with Pedro Aibéo, we discuss Architectural Democracy, a research project, and its practical implementations. Architectural Democracy started as a doctoral research by Pedro Aibéo, architect and civil engineer. Pedro has been doing his research at Aalto Bim Lab, Aalto University School of Engineering. The project has now grown into a larger working group of researchers and entrepreneurs who are currently putting in practice the developed technologies. Pedro’s research “aims at investigating possibilities and benefits of combining existing technologies (Smartphones and BIM) in collaboration with government policies, in order to include end-users as participants in the decision making process of the built environment.” Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at info@aepartners.fi

Musings: Moving or Going into a New Service Area, There is More to It Than Just…

July 16, 2023 — Christopher G. Hill - Construction Law Musings
For this week’s Guest Post Friday here at Construction Law Musings, we would like to welcome back (again) Sean Lintow Sr. (@The_HTRC) Sean has over 20 years in the construction and project management fields. As many know he pulled up stakes and moved to the State of Illinois almost a year ago where he still focuses on the “green” / energy efficiency markets by helping builders & trade professionals to improve their methods not only locally but nationally. Currently he is RESNET Rater, AEE CEA (Certified Energy Auditor), ENERGY STAR partner & verifier, EPA Indoor airPLUS verifier, Level 2 Infrared Thermographer, Volunteer Energy Rater for Habitat for Humanity, and Builders Challenge Partner & Verifier. I would like to thank Chris for inviting me back as a guest poster. One item that struck a bell with me lately was his recent post for contractors considering work in another state is to check that states contractor licensing laws. Part of me was just saying – ahh if it were just that simple… With that in mind, here are some additional thoughts of mine along with advice picked up and given to others considering a move to greener pastures in another state, another town or maybe even taking that sweet little project outside of your current area that seems too good to pass up. Licensing: Yep this is a no-brainer – but unfortunately, as I pointed out in a 2012 piece it isn’t always that simple as in some cases the state may not require licensing and instead leave it to the towns which can be real fun to figure out. How long will it take to obtain? Ahh, but what about other licenses that a township may require? Working on a pre-78 house – is the state a self-managed one or is your current EPA certificate and training good enough? (Living in a self-managed state but working on an Indian Reservation? Well you will need to be EPA certified) Does the area require a specialty Storm Water Certificate or??? Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Lawmakers Strike Deal on New $38B WRDA

January 09, 2023 — Tom Ichniowski - Engineering News-Record
Key Senate and House leaders have reached a bipartisan agreement on a new Water Resources Development Act (WRDA) that would authorize more than $37 billion in federal funds for 25 new and five modified Army Corps of Engineers flood and hurricane protection, harbor dredging and other civil works projects across the U.S. Reprinted courtesy of Tom Ichniowski, Engineering News-Record Mr. Ichniowski may be contacted at ichniowskit@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Release Language Extended To Successor Entity But Only Covered “Known” Claims

August 06, 2019 — David Adelstein - Florida Construction Legal Updates
A recent case contains valuable analysis that has impact on whether a “successor” entity will be bound by a settlement agreement it was not a direct party to. This case contains arguments for contractors that can be raised in a number of different contexts if it is sued by a successor or related entity. The same case discusses the difference between releasing a party for “known” claims without releasing the same party for “unknown” claims. This is an important distinction because unknown claims refer to latent defects so a release that only releases a party for known claims is not releasing that party for latent defects. In MBlock Investors, LLC v. Bovis Lend Lease, Inc., 44 Fla. L. Weekly D1432d (Fla. 3d DCA 2019), an owner hired a contractor to construct a project. At completion, the owner transferred the project to an affiliated entity (collectively, the “Owner”). The contractor sued the Owner for unpaid work, the Owner claimed construction defects with the work, and a settlement was entered into that released the contractor for KNOWN claims. Thereafter, the Owner defaulted on the construction loan and agreed to convey the property through a deed in lieu of foreclosure to an entity created by the lender (the “Lender Entity”). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES