Fairfield Connecticut Building Expert Directory

Home Prices Up, Inventory Down

February 04, 2013 — CDJ STAFF
"Housing is clearly recovering," David Blitzer of Standard & Poor told USA Today. Standard & Poor issued their Case-Shiller Index of home sale prices for November. In their review of twenty metropolitan areas, prices rose in all but one area. In the report for October, housing overall saw a 0.1% decline with gains only in ten cities. The article attributes this in part to that the inventory of unsold homes was 4.4 months, which was the lowest since May 2005. "Any new listings are getting eaten up right away," said E. J. Bowlds, a broker at Coldwell Banker Bain. He is seeing six to ten competing offers on homes in his area of Washington State. Read the court decision
Read the full story...
Reprinted courtesy of

Property Damage to Insured's Own Work is Not Covered

May 27, 2019 — Tred R. Eyerly - Insurance Law Hawaii
The Michigan Court of Appeals found there was no coverage for a lawsuit filed against the insureds for faulty workmanship. Skanska United States Bldg. v M.A.P. Mech. Contrs., 2019 Mich App. LEXIS 529 (Mich. Ct. App. March 19, 2019). Contractor Skanska United States Building was the construction manager on a renovation project for the medical center. The heating and cooling portion of the project was subcontracted to M.A.P. Mechanical Contractors (MAP). MAP had a CGL policy from Amerisure Insurance Company. Skanska and the medical center were named as additional insureds on the policy. After installation of the steam boiler and related piping, it was discovered that the heating system did not function property. Skanska discovered that MAP had installed some of the expansion joints backward, causing damage to concrete, steel, and heating system. The medical center sent a demand to MAP. Skanska performed the repairs and replaced the damaged property. Skanska then submitted a claim to Amerisure, which was denied. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Which Cities have the Most Affordable Homes?

October 08, 2014 — Beverley BevenFlorez-CDJ STAFF
Builder analyzed U.S. cities with populations of half a million or more and then filtered further with cities that have a “median new home closing price under $250,000, a first mortgage rate below 4 percent for new homes, and a median new home price per square foot below $125.” Topping the list was El Paso, Texas with the lowest median price ($168,600). Fifth on the list was San Antonio-New Braunfels, Texas with a median price of $230,400. Read the court decision
Read the full story...
Reprinted courtesy of

The Connecticut Appellate Court Decides That Construction Contractor Was Not Obligated To Continue Accelerated Schedule to Mitigate Its Damages Following Late Delivery of Materials by Supplier

April 11, 2022 — Robert M. Barrack - Gordon & Rees
In United Concrete Prods. v. NJR Constr., LLC, 207 Conn. App. 551, 263 A.3d 823 (2021), the Connecticut Appellate Court has issued a decision that should be of interest to the Connecticut construction industry and the construction bar. The lawsuit arose out of the late delivery of materials on a construction project, which is a frequent problem on construction projects. In United Concrete Products, the defendant general contractor, NJR Construction, LLC (“NJR”) was retained by the State of Connecticut Department of Transportation (“DOT”) to replace a bridge over the Hockanum River (“Project”). Id. at 555-58 (2021). The Prime Contract provided that NJR with an eight-week time-frame to perform the work, at which time the road would be closed to traffic. Id. The Prime Contract also provided for a bonus of $3,000 for each day the road was opened to traffic prior to the eight week deadline of August 8, 2016, and for liquidated damages of $3,000 for each day the road remained closed beyond the deadline. Id. NJR subsequently entered into a purchase order (“Subcontract”) with the plaintiff, United Concrete Products, Inc. (“United”), whereby United agreed to provide certain concrete components for the Project, including ten pre-stressed concrete beams. Id. The Subcontract required that United deliver the concrete beams by June 7, 2016, but, NJR did not actually schedule the delivery until June 29, 2016. Id. Nevertheless, even with that schedule NJR could have reopened the road by July 19, 2016, which would have allowed it to receive the full $60,000 incentive bonus. However, United did not deliver the concrete beams until July 26, 2016, which caused NJR to lose the incentive bonus, be assessed liquidated damages by the DOT, and to incur additional delay damages. Id. After deducting the amount of $179,500 in damages that it incurred due to United’s late delivery of the beams, NJR paid United the balance of $66,074.75. Id. Read the court decision
Read the full story...
Reprinted courtesy of Robert M. Barrack, Gordon Rees Scully Mansukhani, LLP
Mr. Barrack may be contacted at rbarrack@grsm.com

Policy Lanuage Expressly Prohibits Replacement of Undamaged Material to Match Damaged Material

March 09, 2020 — Tred R. Eyerly - Insurance Law Hawaii
Construing an all-risk Businessowners Policy, the court found that the policy language did not required replacement of undamaged material match materials that were damaged. Pleasure Creek Townhomes Homeowners' Ass'n v. Am. Family Ins. Co., 2019 Minn. App. Unpub. LEXIS 1095 (Minn. Ct. App. Nov. 25, 2019). The policy covered the Association's 14 townhome buildings. In June 2017, a hail storm damaged siding on all 14 buildings. An appraisal panel included the cost to replace the undamaged, faded siding in its appraisal award so that it would match the new siding. American Family refused to pay this component - which was appraised at about $211,382 - of the award. An exclusion in the policy provided,

We will not pay to repair or replace undamaged material due to mismatch between undamaged material and new material used to repair or replace damaged material.

We do not cover the loss in value to an property due to mismatch between undamaged material and new material used to repair or replace damaged material.

Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

NY Appeals Court Ruled Builders not Responsible in Terrorism Cases

January 13, 2014 — Beverley BevenFlorez-CDJ Staff
In a ruling on a case related to the September 11, 2001 attacks, New York federal appeals court stated that builders and developers could not be held responsible for losses linked to terrorism, Reuters reports. Circuit Judge Rosemary said the building “would have collapsed regardless of any negligence ascribed by plaintiffs' experts.” Scott Sweeney writing for the Schinnerer's RM Blog explained, “This decision should make it harder for constructors and designers to be held responsible for damages resulting from major acts of terrorism and unforeseeable events that can be nearly impossible to prepare for.” Read the full story at Reuters... Read the full story at Schinnerer's RM Blog... Read the court decision
Read the full story...
Reprinted courtesy of

School District Settles Over Defective Athletic Field

December 11, 2013 — CDJ STAFF
The Hillsboro, Oregon School District has settled a lawsuit with Mahlum Architects of Portland, one of the four companies sued by the school district over problems with a soccer field. The total lawsuit was for $1.7 million. The architects have settled for $25,000. The manufacturer of Astro Turf also settled with the school for an as-yet undisclosed amount. What the school describes as the “primary defendants” have yet to settle. The school had to close the soccer field when drainage problems lead to large holes in the playing field. Read the court decision
Read the full story...
Reprinted courtesy of

Before Collapse, Communications Failed to Save Bridge Project

December 30, 2019 — Scott Judy - Engineering News-Record
The National Transportation Safety Board’s Oct. 8 release of documents related to its FIU bridge collapse investigation raises questions but provides no definitive conclusions about why the partially built structure suddenly crashed to the ground on March 15, 2018, killing six. The last official word on the cause of the fatal collapse will have to await the agency’s final report, scheduled to be released on Oct. 22. Scott Judy, Engineering News-Record Mr. Judy may be contacted at judys@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES