Seattle Washington Building Expert Directory

Washington State Supreme Court Issues Landmark Decision on Spearin Doctrine

September 29, 2021 — Cameron Sheldon - Ahlers Cressman & Sleight PLLC
The Washington State Supreme Court’s recent decision in Lake Hills Invs., LLC v. Rushforth Constr. Co. No. 99119-7, slip op. at 1 (Wash. Sept. 2, 2021) marks the first time in over 50 years that it has ruled on the Spearin doctrine. The Court’s opinion clarified the contractor’s burden when asserting a Spearin defense and affirmed the jury’s verdict in favor of contractor AP Rushforth Construction Company (AP). The decision is a major win for Ahlers Cressman & Sleight PLLC attorneys Scott Sleight, Brett Hill, and Nick Korst, who represented AP throughout its long-running dispute with Lake Hills Investments, LLC (LH), including the two-month jury trial and the appeal. Leonard Feldman of Peterson | Wampold | Rosato | Feldman | Luna and Stephanie Messplay of Van Siclen Stocks & Firkins also represented AP on appeal. At trial, the owner—Lake Hills Investments, LLC (LH)—asserted it was entitled to $3 million in liquidated damages and $12.3 million for defects it alleged were caused by AP’s deficient workmanship. AP denied responsibility for the delays and most of the defects and requested payment of $5 million. Regarding LH’s defect claims, AP argued as an affirmative defense that the defects were caused by deficiencies in the plans and specifications provided by LH. This affirmative defense was rooted in the Spearin doctrine, which states that when the contractor follows plans and specifications provided by the owner, the contractor is not responsible for defects caused by the plans and specifications. Read the court decision
Read the full story...
Reprinted courtesy of Cameron Sheldon, Ahlers Cressman & Sleight PLLC
Ms. Sheldon may be contacted at cameron.sheldon@acslawyers.com

Manhattan Vacancies Rise in Epicenter Shift: Real Estate

August 20, 2014 — David M. Levitt – Bloomberg
The luster is fading on some of midtown Manhattan’s shiniest skyscrapers. Buildings in Midtown, from 30th Street to Central Park South at 59th Street, have more vacant blocks of contiguous office space than at the height of the recession in 2009, as landlords face increased competition from buildings downtown and at Hudson Yards on the far west side, according to a study by Savills Studley Inc., a New York-based real estate brokerage. “The epicenter of this city has shifted several times before and is in the process of shifting again,” Michael Cohen, tri-state region president of brokerage Colliers International, said in an interview. Midtown is “the hole in the doughnut,” where landlords are vulnerable to extended vacancies and rents that probably won’t rise dramatically. Read the court decision
Read the full story...
Reprinted courtesy of David M. Levitt, Bloomberg
Mr. Levitt may be contacted at dlevitt@bloomberg.net

New Jersey Courts Sign "Death Knell" for 1979 Weedo Decision

October 21, 2015 — Jesse Howard Witt – Acerbic Witt
A new blog post from Kilpatrick Townsend & Stockton discusses two recent decisions limiting the holding of Weedo v. Stone-E-Brick, Inc., 405 A.2d 788 (N.J. 1979), a New Jersey case that has generated decades of commentary and debate, in my own writing as well as that of many others (at least 1880 citations, according to the blog). Read the court decision
Read the full story...
Reprinted courtesy of Jesse Howard Witt, Acerbic Witt
Mr. Witt welcomes comments at www.wittlawfirm.net

Harrisburg Sought Support Before Ruinous Incinerator Retrofit

September 20, 2017 — Jonathan Barnes & Richard Korman - Engineering News-Record
When former Harrisburg, Pa., Mayor Stephen Reed (D) and his aides set out to retrofit the city’s aging incinerator in late 2000, the project spun out of control over the coming years, enlarging the debt the city owed on the facility to $300 million and sinking Harrisburg into financial ruin. Reprinted courtesy of Jonathan Barnes, ENR and Richard Korman, ENR ENR staff may be contacted at ENR.com@bnpmedia.com Read the court decision
Read the full story...
Reprinted courtesy of

A Chicago Skyscraper Cements the Legacy of a Visionary Postmodern Architect

December 31, 2024 — Mark Byrnes - Bloomberg
A handsome and eclectic stretch of buildings along Michigan Avenue known as “Chicago’s Front Door” offers a view that reflects the city’s status as a destination for serious architecture. Louis Sullivan and Dankmar Adler’s Auditorium Building, where a young Frank Lloyd Wright designed interiors, is right there on Grant Park; so is Daniel Burnham’s Railway Exchange, where he drew up the 1909 Plan of Chicago. Now a glass-and-aluminum apartment tower anchors the southern end of this scene, filling in a rare gap within this landmarked streetwall and putting a bow on the career of another heroic figure in Chicago’s architectural history: Helmut Jahn. Read the court decision
Read the full story...
Reprinted courtesy of Mark Byrnes, Bloomberg

San Francisco Bucks U.S. Trend With Homeownership Gains

September 24, 2014 — Prashant Gopal – Bloomberg
Homeownership climbed in a small number of U.S. metropolitan areas last year including San Francisco; Nashville, Tennessee; and Austin, Texas, where strong job growth helped them buck the national trend. Of 100 metropolitan areas, 17 had an increase in the “true” ownership rate, which measures the number of owner-occupied households per 100 adult residents, according to an analysis by Trulia Inc. of Census Bureau data. Even in those areas, advances were small. San Francisco had the biggest gain in 2013, rising about 0.6 percentage points from a year earlier, the property-information company said today. The Gary, Indiana, region, made up mostly of suburbs, had a similar increase. The homeownership rate has been falling in much of the U.S. as incomes stagnate and rising prices make housing less affordable and more difficult to finance for entry-level buyers. The regions where the rate is up include strong job markets such as San Francisco and Austin, and areas with stable prices such as Albany, New York, that were spared the brunt of the nationwide foreclosure crisis, Trulia said. Read the court decision
Read the full story...
Reprinted courtesy of Prashant Gopal, Bloomberg
Mr. Gopal may be contacted at pgopal2@bloomberg.net

Defense Owed for Product Liability Claims That Do Not Amount to Faulty Workmanship

December 30, 2013 — Tred Eyerly — Insurance Law Hawaii
The trial court's holding that there was no occurrence based on claims from faulty workmanship was reversed by the appellate division of the Pennsylvania Superior Court. The underlying claims were based on product liability tort claims, not faulty workmanship. Indalex Inc. v. National Union Fire Insurance Co. of Pittsburgh, PA., 2013 Pa. Super. LEXIS 3186 (Pa. Superior Court Dec. 3, 2013). The underlying lawsuits claimed that the insureds' windows and doors were defectively designed or manufactured, which resulted in water leakage causing physical damage, such as mold and cracked walls. There were also personal injury claims. The insureds had a primary policy with OneBeacon Insurance Group, but the policy limits were exhausted. The insureds turned to their commercial umbrella policy issued by National Union. The policy defined occurrence as "an accident, including continuous or repeated exposure to conditions, which results in Bodily Injury or Property Damage neither expected nor intended from the standpoint of the Insured." Read the court decision
Read the full story...
Reprinted courtesy of Tred Eyerly
Tred Eyerly can be contacted at te@hawaiilawyer.com

Does a No-Damage-for-Delay Clause Also Preclude Acceleration Damages?

January 27, 2020 — Ted R. Gropman & Christine Z. Fan - ConsensusDocs
Construction contracts often include a “no damage for delay” clause that denies a contractor the right to recover delay-related costs and limits the contractor’s remedy to an extension of time for noncontractor-caused delays to a project’s completion date. Depending on the nature of the delay and the jurisdiction where the project is located, the contractual prohibition against delay damages may well be enforceable. This article will explore whether an enforceable no-damage-for-delay clause is also a bar to recovery of “acceleration” damages, i.e., the costs incurred by the contractor in its attempt to overcome delays to the project’s completion date. Courts are split as to whether damages for a contractor’s “acceleration” efforts are distinguishable from “delay” damages such that they may be recovered under an enforceable no-damage-for-delay clause. See, e.g., Siefford v. Hous. Auth. of Humboldt, 223 N.W.2d 816 (Neb. 1974) (disallowing the recovery of acceleration damages under a no-damage-for-delay clause); but see Watson Elec. Constr. Co. v. Winston-Salem, 109 N.C. App. 194 (1993) (allowing the recovery of acceleration damages despite a no-damage-for-delay clause). The scope and effect of a no-damage-for-delay clause depend on the specific laws of the jurisdiction and the factual circumstances involved. There are a few ways for a contractor to circumvent an enforceable no-damage-for-delay clause to recover acceleration damages. First, the contractor may invoke one of the state’s enumerated exceptions to the enforceability of the clause. It is helpful to keep in mind that most jurisdictions strictly construe a no-damage-for-delay clause to limit its application. This means that, regardless of delay or acceleration, courts will nonetheless permit the contractor to recover damages if the delay is, for example, of a kind not contemplated by the parties, due to an unreasonable delay, or a result of the owner’s fraud, bad faith, gross negligence, active interference or abandonment of the contract. See Tricon Kent Co. v. Lafarge N. Am., Inc., 186 P.3d 155, 160 (Colo. App. 2008); United States Steel Corp. v. Mo. P. R. Co., 668 F.2d 435, 438 (8th Cir. 1982); Peter Kiewit Sons’ Co. v. Iowa S. Utils. Co., 355 F. Supp. 376, 396 (S.D. Iowa 1973). Reprinted courtesy of Ted R. Gropman, Pepper Hamilton LLP and Christine Z. Fan, Pepper Hamilton LLP Mr. Gropman may be contacted at gropmant@pepperlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES