SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

The Connecticut Appellate Court Decides That Construction Contractor Was Not Obligated To Continue Accelerated Schedule to Mitigate Its Damages Following Late Delivery of Materials by Supplier

April 11, 2022 — Robert M. Barrack - Gordon & Rees
In United Concrete Prods. v. NJR Constr., LLC, 207 Conn. App. 551, 263 A.3d 823 (2021), the Connecticut Appellate Court has issued a decision that should be of interest to the Connecticut construction industry and the construction bar. The lawsuit arose out of the late delivery of materials on a construction project, which is a frequent problem on construction projects. In United Concrete Products, the defendant general contractor, NJR Construction, LLC (“NJR”) was retained by the State of Connecticut Department of Transportation (“DOT”) to replace a bridge over the Hockanum River (“Project”). Id. at 555-58 (2021). The Prime Contract provided that NJR with an eight-week time-frame to perform the work, at which time the road would be closed to traffic. Id. The Prime Contract also provided for a bonus of $3,000 for each day the road was opened to traffic prior to the eight week deadline of August 8, 2016, and for liquidated damages of $3,000 for each day the road remained closed beyond the deadline. Id. NJR subsequently entered into a purchase order (“Subcontract”) with the plaintiff, United Concrete Products, Inc. (“United”), whereby United agreed to provide certain concrete components for the Project, including ten pre-stressed concrete beams. Id. The Subcontract required that United deliver the concrete beams by June 7, 2016, but, NJR did not actually schedule the delivery until June 29, 2016. Id. Nevertheless, even with that schedule NJR could have reopened the road by July 19, 2016, which would have allowed it to receive the full $60,000 incentive bonus. However, United did not deliver the concrete beams until July 26, 2016, which caused NJR to lose the incentive bonus, be assessed liquidated damages by the DOT, and to incur additional delay damages. Id. After deducting the amount of $179,500 in damages that it incurred due to United’s late delivery of the beams, NJR paid United the balance of $66,074.75. Id. Read the court decision
Read the full story...
Reprinted courtesy of Robert M. Barrack, Gordon Rees Scully Mansukhani, LLP
Mr. Barrack may be contacted at rbarrack@grsm.com

---

Design-Assist, an Ambiguous Term Causing Conflict in the Construction Industry[1]

December 02, 2019 — John P. Ahlers - Ahlers Cressman & Sleight PLLC
“Design-Assist” is one of the recent cost-saving trends being touted for construction projects and, in particular, construction projects utilizing alternative procurement methods. If an internet search for the term, “design-assist” is made, the result will be numerous construction industry articles and white papers lauding “design-assist” as a recent cost-saving trend in construction procurement. From a legal perspective, however, the term “design-assist” is notably absent from court opinions and most state licensing laws. With the exception of the ConsensusDocs, few standard form contracts even include the term “design-assist” in their text. The ConsensusDocs agreement provides examples of the Constructor’s obligations to perform “assisting activities” (the term “design-assist” is not used) and states that, notwithstanding the performance of such “assisting activities” by the Constructor, the responsibility of the design remains with the Designer unless otherwise stated in the Contract:

• Article 4.5 DESIGN PROFESSIONAL’S RESPONSIBIITIES The Designer shall furnish or provide all design and engineering services necessary to design the Project in accordance with the Owner’s objectives … the Designer shall draw upon the assistance of Constructor and others in developing the design, but the Designer shall retain overall responsibility for all design decisions….
• Article 4.6 CONSTRUCTOR’S RESPONSIBILITIES [T]he Constructor shall assist the Designer in the development of the Project Plan and Project Design but shall not provide professional services which constitute the practice of architecture or engineering unless the Constructor needs to provide such services in order to carry out its responsibilities … or unless specifically called for by the Contract Documents.

Read the court decision
Read the full story...
Reprinted courtesy of John P. Ahlers, Ahlers Cressman & Sleight PLLC
Mr. Ahlers may be contacted at john.ahlers@acslawyers.com

---

Subcontractors Have a Duty to Clarify Ambiguities in Bid Documents

August 19, 2015 — Craig Martin – Construction Contractor Advisor
Several months ago, I wrote about an escalator subcontractor that sued a general contractor, demanding payment for work completed based on approved shop drawings. The trial court agreed with the subcontractor, but the general contractor appealed. Ten months later, the Court of Appeals reversed, finding that the subcontractor had a duty to bring to the general contractor’s attention major discrepancies or errors they detect in the bid documents.

“The subcontractor failed to disclose ambiguities in the plans and must suffer the peril.”

Construction Difficulties The subcontractor installed 32 inch escalators throughout the project, but the plans called for 40 inch escalators. The general contractor and subcontractor could not reach agreement on how the dispute should be resolved. The subcontractor sued the general to get paid for replacing the escalators and the general sued to subcontractor for concessions it had to pay to the owner. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

---

Five Actions Construction and Energy Risk Managers Can Take to Avoid the Catastrophic Consequences of a Cyber Attack

June 27, 2022 — Eve-Lynn Gisonni - Saxe Doernberger & Vita
With the ever-increasing usage of technology in the construction and energy industries, risks to business operations have also increased. Property developers and construction contractors rely on electronic data and communications more than ever to streamline projects, ensure efficient and timely supply chain delivery, and facilitate immediate communications between parties. However, with this dependence upon technology comes the heightened risk of cyber criminals frustrating construction operations and driving up costs. Similarly, as the energy sector has grown more dependent upon online networks for deliverables, vulnerabilities have become more pronounced in trades dependent upon electrical grids. When an entire electricity network must be taken offline in defense of a cyber-attack, this impacts countless industries such as hospitals and health care operations, manufacturers and suppliers, and local and interstate traffic systems. Read the court decision
Read the full story...
Reprinted courtesy of Eve-Lynn Gisonni, Saxe Doernberger & Vita
Mr. Gisonni may be contacted at EGisonni@sdvlaw.com

---

Housing-Related Spending Makes Up Significant Portion of GDP

February 05, 2014 — Beverley BevenFlorez-CDJ STAFF
According to Molly Boesel on the Insight Blog, “housing-related spending makes up 17.3 percent of the GDP.” Boesel explained: “To calculate the portion of domestic spending that is related to housing, CoreLogic looks at three expenditures from the release: residential investment (the construction of new single- and multi-family houses), spending on housing services (rent, owner’s equivalent rent and utilities) and spending on furnishings and durable goods. Together, these expenditures made up 17.3 percent of total real GDP in the fourth quarter of 2013.” Read the court decision
Read the full story...
Reprinted courtesy of

---

New Home Construction Booming in Texas

October 24, 2022 — Jason Daniel Feld & Ron Raydon - Kahana Feld

With the rapid relocation trends of families moving to Texas, it was reported that new residential construction permits in Texas grew to a total value in excess of $2 billion and over 7,500 new construction permits in September 2022 alone. D.R. Horton lead the way with 1,139 new permits, while Lennar Homes clocked 696 new permits. Other leading homebuilders including KB Homes (239 permits) and Pulte Homes (253 permits) remained active heading into the 4th Quarter of 2022. The following is a breakdown of new permits and average home values in the 4 largest cities in Texas (Houston, Dallas, Austin and San Antonio) for September 2022:

Houston

Last month, there were approximately 340 home builders with new permits on record in the Houston area, and the following ranked as the top five total new permits:

Builder	Total Permits	Average Value
1-D.R. Horton	483	$ 129,812.00
2-Camillo Properties	190	$ 147,790.00
3-Lennar Homes	188	$ 195,503.00
4-Meritage Homes	124	$ 248,597.00
5-Wan Pacific Real Estate Development	117	$ 165,044.00

Dallas

In Dallas, there were more than 290 contractors with new residential construction activity on record with HBW last month, and the following ranked as the top five for total new permits:

Builder	Total Permits	Average Value
1-D.R. Horton	555	$ 179,430.00
2-Lennar Homes	232	$ 202,318.00
3-Trophy Signature Homes	111	$ 274,016.00
4-Bloomfield Homes	97	$ 405,235.00
5-Meritage Homes	92	$ 267,425.00

 Austin

Last month, there were nearly 125 home builders with new construction activity on record in the Austin area, and the following ranked as the top five for total new permits for the one-month period:

Builder	Total Permits	Average Value
1-Lennar Homes	150	$ 154,390.00
2-KB Homes	147	$ 253,606.00
3-D.R. Horton	99	$ 200,416.00
4-Taylor Morrison Homes	79	$ 365,183.00
5-David Weekley Homes	64	$ 436,978.00

 San Antonio

In San Antonio, there were nearly 120 contractors with new residential construction activity on record last month, and the following ranked as the top five for total new permits:

Builder	Total Permits	Average Value
1-Lennar Homes	126	$ 174,315.00
2-KB Homes	55	$ 254,109.00
3-Pulte Homes	52	$ 241,012.00
4-M/I Homes	51	$ 237,283.00
5-LGI Homes	30	$ 202,760.00

The residential construction boom is Texas does not appear to be slowing down anytime soon. With new corporations relocating corporate offices to the Lone Star State each year, we expect this trend to continue for the foreseeable future. And with increased home production, we will closely monitor the increase in construction related litigation over the next five to ten years.

The increase in market activity attracts new or inexperienced builders and tradesman, making the importance of a proactive approach to construction management all the more important. Given the labor shortages and supply chain issues. It is imperative that Texas homebuilders take extra precautions to ensure quality construction practices and oversight to minimize potential litigation.

Reprinted courtesy of Jason Daniel Feld, Kahana Feld and Ron Raydon, Kahana Feld

Mr. Feld may be contacted at jfeld@kahanafeld.com

Mr. Raydon may be contacted at rraydon@kahanafeld.com

Read the court decision
Read the full story...
Reprinted courtesy of

---

Construction Suit Ends with Just an Apology

February 10, 2012 — CDJ STAFF

After suing a contractor for failing to complete the remodeling of their home, an Orange County couple has settled for an apology. Douglas J. Pettibone represented the contractor, who had lost his business after a broken neck, multiple surgeries, and an addiction to pain medicine. Mr. Pettibone represented his client pro bone. The case was settled in arbitration by JAMS.



Mr. Pettibone noted that his client gave “a heartfelt and very moving apology.” The remodeling was completed by another contractor, two years after Thorp Construction stopped work on the project. After the apology, the case was dismissed.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

---

Fewer NYC Construction Deaths as Safety Law Awaits Governor's Signature

July 25, 2022 — Richard Korman - Engineering News-Record
The hoped-for progress in New York City construction safety is coming too late for laborer Jose Fortina Armenta Hernandez. At 8:37 a.m. on May 27, 2021, while jackhammering a roof section on a Brooklyn building, the section on which Armenta stood gave way and he fell 60 ft. When last year his family sent his body from New York City to Mexico to be buried, they used a GoFundMe page to raise money for the laborer's funeral. Reprinted courtesy of Richard Korman, Engineering News-Record Mr. Korman may be contacted at kormanr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

---