FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Recovering Time and Costs from Hurricane Helene: Force Majeure Solutions for Contractors

November 18, 2024 — Matthew DeVries - Best Practices Construction Law
When Hurricane Helene struck North Carolina, it caused severe disruptions to construction projects across the state. Baxter International’s North Cove facility in Marion, N.C., was completely shut down after floodwaters damaged the site and bridges leading to it. Elsewhere, landslides and floods wiped out large sections of Interstate 40, making transportation of materials and equipment nearly impossible. Many contractors in western North Carolina found their projects halted, and their schedules thrown off by this force majeure event. In situations like these, contractors and subcontractor need a plan to mitigate the impact of such natural disasters on their projects. Here are five practical tips to help you secure time extensions and/or compensation for delays: 1. Include a Robust Force Majeure Clause in Your Contract When disaster strikes, your contract is your first line of defense. A well-drafted force majeure clause can make the difference between bearing the costs yourself and getting an extension or compensation. The clause should clearly list specific events such as hurricanes, floods, and road closures as qualifying force majeure events. Read the court decision
Read the full story...
Reprinted courtesy of Matthew DeVries, Buchalter
Mr. DeVries may be contacted at mdevries@buchalter.com

---

American Arbitration Association Revises Construction Industry Rules and Mediation Procedures

April 08, 2024 — Dennis Cavanaugh & Larry Grijalva - Construction Law Zone
The American Arbitration Association (AAA), one of the longest-standing and experienced alternative dispute resolution (ADR) administrators, has unveiled a significant update to its Construction Industry Rules and Mediation procedures. This update, last revised in 2015, became effective March 1, 2024. Changes to the AAA Construction Industry Rules are significant as these rules are incorporated by default in American Institute of Architects standard construction forms, which are widely used in the industry. Advancements in remote access technology drive a substantial number of new changes. Others are designed to streamline the arbitrator appointment process and certain prehearing procedures and to make arbitration more cost-efficient by enhancing the arbitrator’s case management authority. Some of the more notable changes are: Fast Track F-1: The limit for cases eligible for AAA’s Fast Track Procedures has been increased from $100,000 to $150,000 so long as no claim or counterclaim exceeds that amount. Reprinted courtesy of Dennis Cavanaugh, Robinson & Cole and Larry Grijalva, Robinson & Cole Mr. Cavanaugh may be contacted at dcavanaugh@rc.com Mr. Grijalva may be contacted at lgrijalva@rc.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Florida Lawmakers Fail to Reach Agreement on Condominium Safety Bill

March 14, 2022 — Community Associations Institute
Falls Church, March 11, 2022 (GLOBE NEWSWIRE) -- Members of the Florida legislature did not reach an agreement on legislation that would require building inspections and mandatory reserve studies for certain condominium and cooperative communities prior to this session's adjournment, despite the tireless efforts from Sen. Jennifer Bradley (R-Orange Park) and Rep. Daniel Perez (R-Miami) as well as CAI advocates to pass legislation that would contribute to condominium safety after the tragic collapse of Champlain Towers South in Surfside, Fla., last June. The Virginia General Assembly recently passed legislation introduced by Sen. Scott Surovell (D-Fairfax, VA) that requires the Virginia Housing Commission to study condominium safety issues, specifically building inspections. The Maryland legislature is considering funding for condominium buildings in need of critical repairs, while Hawaii is considering building inspection requirements for condominiums. Learn more about CAI's efforts to improve condominium safety by visiting www.caionline.org/condosafety. About Community Associations Institute Since 1973, Community Associations Institute (CAI) has been the leading provider of resources and information for homeowners, volunteer board leaders, professional managers, and business professionals in the more than 355,000 homeowners associations, condominiums, and housing cooperatives in the United States and millions of communities worldwide. With more than 42,000 members, CAI works in partnership with 36 legislative action committees and 63 affiliated chapters within the U.S., Canada, South Africa, and the United Arab Emirates as well as with housing leaders in several other countries, including Australia, Spain, and the United Kingdom. A global nonprofit 501(c)(6) organization, CAI is the foremost authority in community association management, governance, education, and advocacy. Our mission is to inspire professionalism, effective leadership, and responsible citizenship—ideals reflected in community associations that are preferred places to call home. Visit us at www.caionline.org, and follow us on Twitter and Facebook @CAISocial. Read the court decision
Read the full story...
Reprinted courtesy of

---

Appellate Court Endorses Discretionary Test for Vicarious Disqualification of Law Firms Due To New Attorney’s Conflict

February 07, 2018 — David W. Evans and Stephen M. Tye – Publications & Insights
In California Self-Insurer’s Security Fund et al. v. The Superior Court of Orange County (1/26/2018 – No. G054981), the Fourth Appellate District considered whether vicarious disqualification of a law firm is mandatory or discretionary where an attorney with a conflict joins a firm and the firm enacts an ethical screen to prevent transmission of confidential information between the new attorney and the rest of the firm. This case arose from an effort by the California Self-Insurer’s Security Fund (the “Fund”) to be reimbursed for workers’ compensation benefits advanced on behalf of the Healthcare Industry Self-Insurance Program (the “Program”). The Fund hired Nixon Peabody LLP (“Nixon Peabody”) to represent it in connection with this matter. In November 2013, represented by members of Nixon Peabody’s San Francisco office, the Fund filed a lawsuit naming 304 members of the Program as defendants. Approximately 170 defendants have since settled. Two of the non-settling defendants (“Moving Parties”), were represented by Michelman & Robinson, LLP (“M&R”). From approximately 2009 until February 1, 2017, attorney Andrew Selesnick served as Chair of M&R’s Health Care Department at the firm’s Los Angeles office, managing a team of attorneys who represented clients in the healthcare industry. Commencing in 2014, a team of four attorneys at M&R, including Selesnick, represented the Moving Parties and four other defendants, the latter of whom have since settled. Selesnick was actively involved, including participating in a confidential discussion pertaining to Moving Parties’ liability and damages and receiving many e-mails containing communications about the common defense of the remaining 170 defendants. Reprinted courtesy of David W. Evans, Haight Brown Bonesteel and Stephen M. Tye, Haight Brown Bonesteel Mr. Evans may be contacted at devans@hbblaw.com Mr. Tye may be contacted at stye@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Citigroup Pays Record $697 Million for Hong Kong Office Tower

June 18, 2014 — Michelle Yun – Bloomberg
Citigroup Inc. (C) paid a record HK$5.4 billion ($697 million) to a unit of Wheelock & Co. for a Hong Kong office tower that will bring most of its 5,000 employees under one roof. The price for the 512,000 square-foot property in Kowloon is the largest ever office transaction in Hong Kong, the New York-based bank said in a statement yesterday. The tower, scheduled for completion by the end of 2015, will be used to house staff currently spread out across offices in the city, said Weber Lo, the bank’s chief executive officer for Hong Kong and Macau. Citigroup joins banks and insurers in buying buildings in the city as falling vacancies pose a challenge for companies looking for large office spaces, realtor CBRE Group Inc., which advised the deal, said in a first-quarter review report. Read the court decision
Read the full story...
Reprinted courtesy of Michelle Yun, Bloomberg
Ms. Yun may be contacted at myun11@bloomberg.net

---

Court Holds That Trimming of Neighbor’s Trees is Not an Insured Accident or Occurrence

June 10, 2015 — Christopher Kendrick and Valerie A. Moore – Haight Brown & Bonesteel LLP
In Albert v. Mid-Century Insurance Co. (No. B257792, filed 4/28/15, ord. pub. 5/20/15), a California Court of Appeal held that an insured’s trimming of a neighbor’s trees which allegedly damaged the trees was not an accident or occurrence covered by her homeowners insurance, despite a mistaken and good faith belief as to where the property line lay. Ms. Albert was sued by her adjoining neighbor, who alleged damage to his property when she erected an encroaching fence and pruned nine mature olive trees on his property. The two parcels shared a reciprocal roadway easement providing for access to the main public road. At some point, Ms. Albert erected a fence that was subsequently determined to be on the neighbor’s land, and which enclosed a grove of nine mature olive trees. Ms. Albert claimed that the trees straddled the property line and were mutually owned. She pointed out that she had regularly been notified by the Los Angeles Fire Department to clear the area, and that she had been trimming the trees for years. Thus, she claimed a good faith belief that the trees were hers and that she was required to trim them. Contending that her trimming had caused severe damage by reducing the aesthetic and monetary value of the trees, the neighbor sued alleging causes of action for trespass to real property and trees; abatement of private nuisance; declaratory relief; and for quiet title. He sought treble damages under Civil Code sections 733 and 3346, for injury to timber or trees. Reprinted courtesy of Christopher Kendrick, Haight Brown & Bonesteel LLP and Valerie A. Moore, Haight Brown & Bonesteel LLP Mr. Kendrick may be contacted at ckendrick@hbblaw.com; Ms. Moore may be contacted at vmoore@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Struggling Astaldi Announces Defaults on Florida Highway Contracts

April 22, 2019 — Scott Judy - Engineering News-Record
Astaldi Construction Corp. announced on March 28 that it was voluntarily defaulting on four contracts with the Florida Dept. of Transportation. Included among those was a $108.3-million contract covering the 3.5-mile-long Section 7A for the $1.6-billion Wekiva Parkway project. Astaldi’s default on that project comes nearly a year after the contractor commenced work on April 1, 2018. Read the court decision
Read the full story...
Reprinted courtesy of Scott Judy, ENR
Mr. Judy may be contacted at judys@enr.com

---

New Change Order Bill Becomes Law: RCW 39.04.360

July 08, 2024 — Brett M. Hill - Ahlers Cressman & Sleight PLLC
A new statute (RCW 39.04.360) became effective on June 6, 2024, and it applies to extra work performed by contractors and subcontractors on public and private projects in Washington State. The intent of the original bill was to allow contractors and subcontractors to get paid sooner for undisputed additional work. The statute does not apply to private residential projects of 12 units or less. The statute allows for recovery of interest for contractors/subcontractors at 1% per month (12% per year) on the value of the additional work if the statute is violated. Here are the requirements of the new statute:

• Public and private owners must issue a change order for the undisputed amount of additional work performed by a contractor, subcontractor, or supplier no later than 30 days after the work is satisfactorily completed and the change is requested by the contractor.
• General contractors, and subcontractors with lower-tier subs, must issue a change order to their subcontractors impacted by the change within 10 days after receipt of the approved change order from the owner/upper-tier contractor.

Read the court decision
Read the full story...
Reprinted courtesy of Brett M. Hill, Ahlers Cressman & Sleight PLLC
Mr. Hill may be contacted at brett.hill@acslawyers.com

---