California Expands on Scope of Coverage for Soft Cost Claims
February 14, 2023 —
Caitlin N. Rabiyan - Saxe Doernberger & Vita, P.C.The California federal district court case of KB Home v. Illinois Union Insurance Co., No. 8:20-cv-00278-JLS-JDE, (C.D. Cal. August 23, 2022), provides much needed guidance for cases involving builder's risk insurance claims for soft cost coverage.
The case stems from damage to several of KB Home’s residential building sites caused by a severe rainstorm in January 2017. Each home site was a smaller part of a large housing development project. The damage caused significant delay in the completion of some individual home sites, although there was limited evidence of delay to the overall housing development project.
As a result, KB Home sought coverage under a builder’s risk policy purchased from Illinois Union for both hard costs and soft costs. “Hard costs” are the costs directly associated with repairing property damage to the sites. Conversely, “soft costs” are indirect expenses associated with project delays caused by such property damage and repair efforts. For example, hard costs would include labor and materials, whereas the soft costs claimed by KB Home included additional real estate taxes, construction loan interest, and advertising and promotional expenses incurred because of the delays. Illinois Union paid the claim for the hard costs, but denied the soft costs claim. KB Home filed suit and Illinois Union eventually filed a motion for summary judgment.
Read the court decisionRead the full story...Reprinted courtesy of
Caitlin N. Rabiyan, Saxe Doernberger & Vita, P.C.Ms. Rabiyan may be contacted at
CRabiyan@sdvlaw.com
Creeping Incrementalism in Downstream Insurance: Carriers are Stretching Standard CGL Concepts to Untenable Limits
October 17, 2023 —
Eric M. Clarkson - Saxe Doernberger & VitaIn the construction sector, the importance of closely vetting downstream parties’ insurance has never been more critical. The markets have been hardening with no seeming end in sight and carriers are looking for any way to get an edge. Owners and general contractors need to be on the lookout for ever broader carrier-specific expansions of standard insurance provisions that are perilous for risk transfer. We are seeing more and more terms that go against the intent of ISO standard which is what is almost universally required in construction contracts.
One area where carriers are deviating from standard concepts is within pre-existing injury or damage exclusions in Commercial General Liability (“CGL”) policies. It is almost a universal requirement that downstream parties provide additional insured coverage to owners and general contractors on ISO form CG 00 01. Generally, ISO standard language provides coverage for sums the insured becomes legally obligated to pay as damages because of bodily injury or property damage. One of the few main requirements to trigger coverage is that the injury or damage must occur during the policy period. Over the years, ISO standard language has evolved to exclude injury or damage if an insured or certain persons knew that it had occurred before the policy period. Additionally, injury or damage is deemed to have been known to have occurred under certain circumstances.
Read the court decisionRead the full story...Reprinted courtesy of
Eric M. Clarkson, Saxe Doernberger & VitaMr. Clarkson may be contacted at
EClarkson@sdvlaw.com
Another TV Fried as Georgia Leads U.S. in Lightning Costs
June 26, 2014 —
Kelly Gilblom – BloombergGeorgia tops a shocking list: most likely place to have property damaged by lightning.
Georgia residents were reimbursed for $56 million of lightning-related damage in homes last year tied to more than 11,000 claims, according to a top-10 list from the Insurance Information Institute. Texas ranked second at $54.2 million.
Once lightning is “in the wiring, it’s electrifying anything connected to that,” John Jensenius, a lightning-safety specialist at the National Weather Service, said today in a phone interview. “Televisions, and even things like microwaves, they all have little chips in them so they all can get fried pretty easily.”
Lightning cost insurers $5,869 per claim in the U.S. last year, more than double the average in 2004, as homeowners added electronics such as computers and high-definition televisions. Still, the total expense for the industry declined 8.4 percent nationwide in that span, to $673.5 million in 2013, because better lightning-protection systems and fewer storms decreased the frequency of claims, the industry group said.
Read the court decisionRead the full story...Reprinted courtesy of
Kelly Gilblom, BloombergMs. Gilblom may be contacted at
kgilblom@bloomberg.net
Supreme Court Opens Door for Challenges to Older Federal Regulations
August 05, 2024 —
Jane C. Luxton - Lewis BrisboisWashington, D.C. (July 1, 2024) – On July 1, 2024, the U.S. Supreme Court issued another end-of-term major decision limiting the scope of federal agency actions in Corner Post, Inc. v. Board of Governors of the Federal Reserve System. Adding to the tectonic shift in the regulatory landscape created by the Court’s June 27 and 28 rulings constraining the role of administrative law judges and overturning longstanding “Chevron deference” by courts to federal agency expertise, the decision in Corner Post establishes a newly expanded time frame for affected entities to challenge final agency action. Instead of confirming that final agency action is subject to a default six-year statute of limitations, the Court held that under the Administrative Procedure Act (APA), the time limit for appeal begins to run when a plaintiff is injured by the agency's action, not when the action becomes final. This decision has important implications for businesses and others affected by federal regulations.
The case arose when Corner Post, a truck stop and convenience store in North Dakota that opened in 2018, challenged a 2011 Federal Reserve Board regulation (Regulation II) that set maximum interchange fees for debit card transactions. Corner Post filed suit in 2021, arguing that Regulation II allowed higher fees than permitted by statute. The lower courts dismissed the suit as time-barred under 28 U.S.C. § 2401(a), which effectively requires APA claims to be filed "within six years after the right of action first accrues."
Read the court decisionRead the full story...Reprinted courtesy of
Jane C. Luxton, Lewis BrisboisMs. Luxton may be contacted at
Jane.Luxton@lewisbrisbois.com
Power of Workers Compensation Immunity on Construction Project
November 30, 2017 —
David Adelstein - Florida Construction Legal UpdatesOn construction projects, workers compensation immunity is real and it is powerful. (See also this article.) Workers compensation immunity is why all general contractors should have workers compensation insurance and they should ensure the subcontractors they hire have workers compensation insurance. Workers compensation insurance becomes the exclusive form of liability for an injured worker thereby immunizing an employer (absent an intentional tort, which is very hard to prove as a means to circumvent workers compensation immunity).
If a general contractor, with workers compensation insurance, hires a subcontractor without workers compensation insurance, the general contractor’s workers compensation insurance will be responsible in the event an injury occurs to a subcontractor’s employee. The general contractor becomes the statutory employer.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Florida Construction Legal UpdatesMr. Adelstein may be contacted at
dadelstein@gmail.com
Additional Insured Coverage Confirmed
February 23, 2016 —
Tred R. Eyerly – Insurance Law HawaiiThe Texas Court of Appeals found that Exxon Mobil Corporation was an additional insured under the CGL policy for Exxon's service provider. Liberty Surplus Ins. Corp. v. Exxon Mobil Corporation, 2015 Tex. App. LEXIS 12757 (Tex. Ct. App. Dec. 17, 2015).
Exxon contracted with Wyatt Field Service Company to perform "services" as set forth in various work orders from Exxon's affiliates. The contract also required Wyatt to maintain $5 million of commercial general liability insurance. The contract provided that the policies must cover Exxon and its affiliates "as additional insureds in connection with the performance of Services."
In 2008, Wyatt was assigned to work on a flexicoker unit at Exxon's refinery. Wyatt was to reinstall dummy nozzles and chains. It completed this service in October 2008. Three years later, one of the dummy nozzles pulled free, and the escaping steam and coke burned three individuals who were working on the unit. After the accident, it was discovered that the safety chain had been installed in the wrong location so that it did not properly secure the dummy nozzle.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Insurance Law HawaiiMr. Eyerly may be contacted at
te@hawaiilawyer.com
Withdrawal of an Admission in California May Shift Costs—Including Attorneys’ Fees—Incurred in Connection with the Withdrawal
January 24, 2018 —
Tony Carucci – Real Estate Litigation BlogUnder California Code of Civil Procedure section 2033.300, a court may permit a party to withdraw an admission made in response to a request for admission upon noticed motion. The court may only do so, however, “if it determines that the admission was the result of mistake, inadvertence, or excusable neglect, and that the party who obtained the admission will not be substantially prejudiced in maintaining that party’s action or defense on the merits.” Cal. Code Civ. Proc. § 2033.300(b). The court may also “impose conditions on the granting of the motion that are just, including, but not limited to . . . (2) An order that the costs of any additional discovery be borne in whole or in part by the party withdrawing or amending the admission.” Cal. Code Civ. Proc. § 2033.300(c).
Read the court decisionRead the full story...Reprinted courtesy of
Tony Carucci, Snell & WilmerMr. Carucci may be contacted at
acarucci@swlaw.com
The Woodland Hills Office Secures a Total Defense Award on Behalf of their High-End Custom Home Builder Client!
June 04, 2024 —
Dolores Montoya - Bremer Whyte Brown & O'Meara LLPPartner Daniel Crespo and Associate Theresa Mallen secured a total defense award in arbitration. Our client is a high-end custom home builder with a decades-long flawless record of museum quality construction. Our client was accused of performing substandard construction and the homeowners asserted a multiple million-dollar cost of repair. We took a zero-liability position and argued that the alleged defects were not defects at all but were rather mere reflections of an incomplete project. In sum, our client was forced to terminate the contract and cease construction due to the homeowners’ failure to make progress payments as they became due. The arbitration endured 16 days of testimony scattered over the course of 7 months.
Ultimately, the arbitrator ruled that there were no construction defects at the project and that the homeowners “shall take nothing.” The arbitrator also ruled in favor of our client on its affirmative claim for monies owed by the homeowners’ breach of contract plus interest. A total victory for our client.
Read the court decisionRead the full story...Reprinted courtesy of
Dolores Montoya, Bremer Whyte Brown & O'Meara LLP