Fairfield Connecticut Building Expert Directory

Coverage For Advertising Injury Barred by Prior Publication Exclusion

July 01, 2014 — Tred R. Eyerly – Insurance Law Hawaii
The Ninth Circuit held that a claim for advertising injury was properly denied under the prior publication exclusion. Street Surfing, LLC v. Great Am. E&S Ins. Co., 2014 U.S. App. LEXIS 10737 (9th Cir. June 10, 2014). Street Surfing began selling a two-wheeled, inline skateboard called the "Wave" in December 2004. By 2007, Street Surfing also sold and advertised accessories for the Wave, such as "Lime Green Street Surfing Wheels for The Wave," and the "New Ultimate Street Surfer Wheel Set." Rhyn Noll, who owned the registered trademark "Streetsurfer," sued Street Surfing in June 2008, claiming trademark infringement, unfair competition and unfair trade practices. Street Surfing had known that Noll owned the "Streetsurfer" trademark since early 2005. In September 2008, Street Surfing submitted a claim for coverage to Great American and tendered Noll's complaint. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

County Sovereign Immunity Invokes Change-Order Ordinance

December 20, 2017 — Lizbeth Dison - AHC Contruction Law Blog
The recent case of Fulton County v. Soco Contracting Company, Inc. addresses two very interesting questions for local government attorneys. First, can a county ordinance bolster a defense of sovereign immunity against a contractor’s claims? Second, can a county waive sovereign immunity by failing to respond to Requests for Admission? Facts: County hired Contractor to construct a facility near the airport. The contract provided that change orders must satisfy a county ordinance, which required approval by the Board of Commissioners. But in emergency situations, the County Manager could approve change orders, as long as the contractor executes a proposed modification and the purchasing agent approves it. The project suffered substantial delays, which Contractor attributed to weather, design delays, delays by the County in providing decisions on changes, and delays in obtaining permits during the federal government’s shutdown. As a result of these issues, Contractor comes County changed the scope of the contract. Contractor asserted claims against County for the delays and the changes to the work. The appellate opinion addresses the change order claims. Read the court decision
Read the full story...
Reprinted courtesy of Lizbeth Dison, Autry Hall & Cook, LLP

Faulty Workmanship an Occurrence in Iowa – as Long as Other Property Damage is Involved

November 30, 2016 — Austin D. Moody – Saxe Doernberger & Vita, P.C.
The Eighth Circuit recently weighed in on one of the more contentious issues in insurance coverage litigation: is faulty workmanship an occurrence? In Decker Plastics Inc. v. West Bend Mut. Ins. Co., the Eighth Circuit ruled that, under Iowa law, faulty workmanship is an occurrence – as long as it leads to other property damage. Read the court decision
Read the full story...
Reprinted courtesy of Austin D. Moody, Saxe Doernberger & Vita, P.C.
Mr. Moody may be contacted at adm@sdvlaw.com

Protect Your Right To Payment By Following Nedd

August 03, 2022 — Denise Motta - Gordon & Rees Construction Law Blog
In order to preserve your right to payment, you must satisfy the contractual requirements supporting a change order for the increased costs or time due to the delay. The key to the successful presentation of change order claims is educating your team on the following: 1. NOTICE

Review the change order and notice provisions of your contracts. Make your contract searchable and insert the term “Noti” and look for the items listed below.
Who: Check the designated representative for notice.

It may not be the project manager.
Confirm who can authorize the change order.

Is owner approval required?
Ensure that the party approving the change order has authority to do so.

What: Check for specific information required by the contract.

Provide ALL information available.
If certain information is not yet available, state that the information will be provided when available.
Reserve all rights to amend and submit additional information.
Request both an increase to the Contract Sum and Contract Time.

Make the request even if you do not believe the delay or time necessary will cause a significant impact.

Read the court decision
Read the full story...
Reprinted courtesy of Denise Motta, Gordon Rees Scully Mansukhani, LLP
Ms. Motta may be contacted at dmotta@grsm.com

Construction Litigation Roundup: “Ursinus is Cleared!”

March 11, 2024 — Daniel Lund III - Lexology
Ursinus University in Pennsylvania – a “private, nonprofit liberal arts college” – funded a construction project for a new building utilizing monies loaned by the Montgomery County Health and Higher Education Authority, a public economic development authority “formed by the Board of County Commissioners… authorized to issue bonds relative to projects for eligible educational institution such as Ursinus.” Loans up to the amount of $23,000,000 became available to the University, and construction proceeded using the loans as construction funds. At issue: whether a project was to be considered publicly funded project such that prevailing wage rates were required to be paid. IBEW filed a related grievance with the Pennsylvania Department of Labor and Industry’s Bureau of Labor Law Compliance, which was refused by the Bureau, on the basis that because work was “financed completely by loans from the Authority, which Ursinus was required to repay in their entirety, the Project was ultimately funded through private sources and exempt from coverage under the [Pennsylvania Prevailing Wage Act].” A grievance to the Prevailing Wage Appeals Board ensued, and the Board took a different position. Read the court decision
Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

Nuclear Energy Gets a Much-Needed Boost

August 05, 2024 — The Editorial Board - Bloomberg
President Joe Biden, as you’ve no doubt heard, has had a rough few weeks. Yet on Tuesday, he signed a bill into law that could well prove transformative for America’s energy future. Here’s hoping — whatever happens in November’s election — that more progress lies ahead. Known as the Advance Act, the bill seeks to remedy some long-standing flaws in nuclear-energy regulation. To reach net zero, the world will need to roughly double its nuclear capacity by 2050, according to the International Energy Agency. Yet constructing new nuclear plants in the US is expensive, time-consuming and encumbered by red tape. Partly as a result, the industry has stagnated: The share of electricity generated by nuclear is projected to decline to about 12% by 2050, from about 18% today. The Advance Act should help reverse that trend. As a start, it makes useful reforms to the Nuclear Regulatory Commission, allowing the agency to hire more staff, reduce licensing fees, speed application processing and ease the burden of environmental reviews. It also makes a small but consequential change to the commission’s mission, requiring it — after decades of focusing on potential threats — to also consider the vast public benefits of nuclear energy when making regulatory decisions. Read the court decision
Read the full story...
Reprinted courtesy of The Editorial Board, Bloomberg

The Partial Building Collapse of the 12-Story Florida Condo

June 28, 2021 — Beverley BevenFlorez – CDJ Staff
On Thursday, the Champlain Towers South Condo building in Surfside, Florida suffered a partial collapse. As of Monday morning, the official death toll stood at 10 with 151 persons unaccounted for, according to the Miami Herald. NPR uncovered minutes from a November 15th, 2018 Chaplain Tower South Condominium Association board meeting where the inspector made assurances that “the building was ‘in very good shape.’” However, “an engineering report from five weeks earlier” alleged “that failed waterproofing in a concrete structural slab needed to be replaced ‘in the near future.’” Daniella Levine Cava, the Miami-Dade County mayor, told reporters that “officials ‘knew nothing’ about the report.” The New York Times on Sunday reported that experts looking at video footage of the incident believe that the cause is centered on a location “in the lowest part of the condominium complex — possibly in or below the underground parking garage — where an initial failure could have set off a structural avalanche.” The cause of the incident remains unclear, however. This “progressive collapse” could have been caused by a number of different factors “including design flaws or the less robust construction allowed under the building codes of four decades ago.” A witness, according to the New York Times, saw a hole appear near the pool: “Michael Stratton said his wife, Cassie Stratton, who is missing, was on the phone with him and was looking out through the window of her fourth-floor unit when, she told him, the hole appeared. After that, the call cut off.” Possible reasons for the “initial failure at the bottom of the building could include a problem with the deep, reinforced concrete pilings on which the building sits — perhaps set off by an unknown void or a sinkhole below — which then compromised the lower columns. Or the steel reinforcing the columns in the parking garage or first few floors could have been so corroded that they somehow gave way on their own. Or the building itself could have been poorly designed, built with substandard concrete or steel — or simply with insufficient steel at critical points.” "It will take many months to complete the analysis necessary to understand the cause or causes of the collapse,” Eric Ruzicka, a partner at the international law firm Dorsey & Whitney and a commercial litigator who specializes in the area of construction and real estate litigation, stated in a media release. “Often, information that comes out early can be very misleading or misunderstood unless the full context of the information is known.” Ruzicka explained that Florida’s statues of limitations and repose may be relevant. “These statutes will likely eliminate the liability of those involved in the original development, design and construction of the building. Rather, victims and their families' recovery will be limited to those involved in the building's maintenance and those assessing the condition of the building over the past four years.” Miami and Sunny Isles Beach have announced they will audit older structures in their communities “ahead of the mandatory 40-year recertification,” the Miami Herald reported. Read the full story (Miami Herald)... Read the full story (NPR)... Read the full story (NY Times)... Read the court decision
Read the full story...
Reprinted courtesy of

Gaps in Insurance Created by Complex Risks

January 22, 2024 — The Hartford Staff - The Hartford Insights
From slips, trips and falls to extreme weather and cyberattacks, businesses are regularly confronted with risks to operations and profitability. In 2023, elevated building costs, increased flooding, and growing ransomware attacks made it compelling for business owners to make sure they had adequate insurance to stay ahead of property and liability exposures. However, if left unchecked, these trends can lead to gaps in coverage. As 2024 approaches, now is the time to assess your risk and collaborate with the right resources to fill any potential voids in insurance. Economic inflation for example has changed property valuations, which can result in coverage gaps if policyholders have not examined their replacement costs recently. Read the court decision
Read the full story...
Reprinted courtesy of The Hartford Staff, The Hartford Insights

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES