Fairfield Connecticut Building Expert Directory

Graham & Who May Trigger The Need To Protest

December 23, 2023 — Hugo Fraga - Ahlers Cressman & Sleight PLLC
On May 30, 2023, the Washington Court of Appeals, Division I, issued a decision that appears to expand a contractor’s obligation with respect to WSDOT notice and claim procedures. In Graham Contracting, Ltd. v. City of Federal Way, No. 83494-1-I, 2023 WL 3721171 (Wash. Ct. App. May 30, 2023) (Unpublished), the Court held that under the 2016 WSDOT Standard Specifications for Road, Bridge, and Municipal Construction (“Standard Specifications”), a Contractor must protest the actions of not only the “Engineer” but also the actions of any person or organization acting on behalf of the Owner. This case arises out of a public construction contract in which Graham Contracting Ltd (“Graham”) built a multi-million dollar roadway improvement for the City of Federal Way along a stretch of Pacific Highway. The appeal was from the trial court’s granting of the City’s motion for summary judgment to dismiss claims by Graham for extra time and money due to delays and impacts to Graham’s construction of the Project. Read the court decision
Read the full story...
Reprinted courtesy of Hugo Fraga, Ahlers Cressman & Sleight PLLC
Mr. Fraga may be contacted at hugo.fraga@acslawyers.com

Ben L. Aderholt Joins Coats Rose Construction Litigation Group

February 25, 2014 — Beverley BevenFlorez-CDJ STAFF
According to a press release on PR Newswire, “Ben Aderholt has joined Coats Rose law firm's Houston office as Of Counsel.” Aderholt was a “past President of the Houston Bar Association, past Chair of the Mayor's Council and a Director of the State Bar of Texas.” Furthermore, he “has taught commercial law at the University of Houston” and “continues to be active on the Editorial Board of the Construction Law Journal.” Coats Rose has offices in Houston, Clear Lake, Dallas, Austin, San Antonio, and New Orleans. Read the court decision
Read the full story...
Reprinted courtesy of

Digital Twins for a Safer Built Environment

November 24, 2019 — Cristina Savian - AEC Business
As a native of Turin Italy, I was horrified at the Ponte Morandi bridge collapse last year. As a child and as an adult I have travelled over that bridge more times than I can imagine and have often pondered the what-if scenarios. What if it had happened when I or my loved ones were travelling on that bridge? As a chartered construction professional, I ask myself, what could have been done, what should have been done and what can we do to prevent this from happening in the future? Having access to a digital twin with an integrated understanding of the way the bridge was designed, built and performed over the last 50 years and being able to run “what if” scenarios would have allowed us to have a much greater understanding of the structure and its limitations in its context. This is where I believe a digital twin of any built asset is a step in the right direction. The digital twin has been proclaimed by many as a milestone innovation in the construction industry, with huge benefits to constructors and owners of assets through efficiencies in manufacturing and operation but also to attracting users of the spaces they replicate. However, digital replicas can take a broad range of forms depending on its purpose, use and application sparking debates among professionals on what they actually are and what represents a ‘true’ twin. Read the court decision
Read the full story...
Reprinted courtesy of Cristina Savian, AEC Business

South Carolina Law Clarifies Statue of Repose

July 11, 2011 — CDJ STAFF

A new law in South Carolina, H 3375, fixes a loophole in that state’s statute of repose. State law puts a cap of eight years on construction defects, but the 2008 law that set that limit had a loophole that would allow for construction defect claims to start thirteen years after construction. The law also provides a cap on punitive damages.

The measure was backed by the Carolinas Association of General Contractors. Their spokesperson said that the legislation “increases our state’s ability to be economically competitive and helps protect our members from frivolous lawsuits.”

Read the full story…

Read South Carolina H 3375…

Read the court decision
Read the full story...
Reprinted courtesy of

Allegations Confirm Duty to Defend Construction Defect Claims

June 11, 2014 — Tred R. Eyerly – Insurance Law Hawaii
Relying upon the same case cited by the Hawaii Supreme Court in its seminal decision on duty to defend, the federal district court determined the allegations sufficiently established a duty to defend construction defect claims. Voeller Constr. v. Southern-Owners Ins. Co., 2014 U.S. Dist. LEXIS 61862 (M. D. Fla. May 5, 2014). The Bay Harbor Clearwater Condominium Association, Inc. sued Voeller Construction for statutory breach of warranty and building code violations which allegedly caused damage to the condominium structure. The complaint alleged that the damage was unknown to the unit owners at the time they purchased their units. The project was completed in 2007. Expert reports attached to the complaint listed July 7, 2010, as the earliest date of discovery of the damage to the property. The CGL policies were effective from January 24, 2007 to May 9, 2009. Therefore, the insurer argued there was no coverage because the alleged "property damage" was discovered for more than one year after the policies expired. The court determined there was a duty to defend. Citing Trizec Props., Inc. v. Biltmore Constr. Co., 767 F.2d 810 (11th Cir. 1985), the court noted that if the complaint alleged facts which created potential coverage under the policy, the duty to defend was triggered. The Hawaii Supreme Court relied on Trizec and made the same ruling in Dairy Road Partners v. Island Ins Co., Ltd., 92 Haw. 398, 412, 992 P.2d 93, 107 (2000). Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

It Ain’t Over Till it’s Over. Why Project Completion in California Isn’t as Straightforward as You Think

May 07, 2015 — Garret Murai – California Construction Law Blog
Baseball legend Yogi Berra was famous for his pithy quotes such as “the future ain’t what it used to be,” “half the lies they tell about me aren’t true,” and what is probably his most famous, “it ain’t over till it’s over.” The last, of course, begs the question of when over is over? And, on California construction projects when over is over, or more accurately, when a project is complete, can be as paradoxical as a “yogiism.” Why “Completion” is Important in California In California, project “completion,” is important not only for getting paid, but for knowing the deadlines associated with California’s statutory construction payment remedies. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Key Economic & Geopolitical Themes To Monitor In 2024

January 16, 2024 — Global Insights Center Staff - The Hartford
Slowing US Economic Growth and Flattening Interest Rates Growth in the first half of 2023 averaged approximately 2.0%, driven mainly by private sector investments outside of the residential housing sector, government spending, and strong consumer demand. In 2024, The Hartford’s Global Insights Center is expecting investments and government spending to continue and may support growth in the year. However, consumer health may start to weaken due to elevated leverage, higher interest rates, and sticky inflation. Since the Federal Reserve began to increase interest rates, consumer activity and household finances have not been tremendously affected. However, as revolving interest rates (credit card loans) continue to reset that may change, especially since household savings rates fell below pre-pandemic levels and may affect consumer demand. Read the court decision
Read the full story...
Reprinted courtesy of Global Insights Center Staff, The Hartford

Melissa Pang Elected Vice President of APABA-PA Board of Directors

December 21, 2016 — White and Williams LLP
Melissa Pang has been elected Vice President of the Asian Pacific American Bar Association of Pennsylvania's (APABA-PA) Board of Directors. She will serve a one-year term in the position, beginning January 1, 2017. As part of her responsibilities, Melissa will co-chair the National Asian Pacific American Bar Association Northeast Regional Conference, which will be hosted by the APABA-PA in Philadelphia. Melissa has been a member of the APABA-PA since 2010 and has served on the board since 2015. Her involvement includes participation on the Law Student Outreach Committee as well as the Annual Banquet Committee. In 2016, she chaired the organization's Lunar Banquet. Read the court decision
Read the full story...
Reprinted courtesy of Melissa Pang, White and Williams LLP
Ms. Pang may be contacted at pangm@whiteandwilliams.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES