Fairfield Connecticut Building Expert Directory

Contractor’s Burden When It Comes to Delay

October 26, 2020 — David Adelstein - Florida Construction Legal Updates
When a contractor is challenging the assessment of liquidated damages, or arguing that it is entitled to extended general conditions, the contractor bears a burden of proof to establish there were excusable delays that impacted the critical path and, in certain scenarios, the delays were not concurrent with contractor-caused delay:

When delays are excusable, a contractor is entitled to a time extension, such that the government may not assess liquidated damages for those delays. The government bears the initial burden of proving that the contractor failed to meet the contract completion date, and that the period of time for which the government assessed liquidated damages was correct. If the government makes such a showing, the burden shifts to the contractor to show that its failure to timely complete the work was excusable. To show an excusable delay, a contractor must show that the delay resulted from “unforeseeable causes beyond the control and without the fault or negligence of the Contractor.” “In addition, the unforeseeable cause must delay the overall contract completion; i.e., it must affect the critical path of performance.” Further, the contractor must show that there was no concurrent delay.

Ken Laster Co., ASBCA No. 61292, 2020 WL 5270322 (ASBCA 2020) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

As Trump Visits Border, Texas Landowners Prepare to Fight the Wall

February 11, 2019 — Associated Press - Engineering News-Record
HIDALGO, Texas (AP) — As President Donald Trump traveled to the border in Texas to make the case for his $5.7 billion wall , landowner Eloisa Cavazos says she knows firsthand how the project will play out if the White House gets its way. The federal government has started surveying land along the border in Texas and announced plans to start construction next month. Rather than surrender their land, some property owners are digging in, vowing to reject buyout offers and preparing to fight the administration in court. Read the court decision
Read the full story...
Reprinted courtesy of Engineering News-Record
ENR may be contacted at ENR.com@bnpmedia.com

Builders Arrested after Building Collapses in India

July 01, 2014 — Beverley BevenFlorez-CDJ STAFF
Deaths from a building collapse in Chennai, India is currently at nineteen, while forty-two people have been rescued, according to the New York Times, and “40 others are feared trapped in the debris,” reported BBC News. The Chennai police arrested six people, “including the partners of the construction company, the architect and the structural engineer, and charged them with criminal negligence in connection with the building collapse there,” according to P. Subramniam, a Chaennai police officer, as quoted by the New York Times. "It appears they have not adhered to approved plans,” Tamil Nadu Chief Minister J Jayalalithaa told BBC News. “The building appears to have serious structural defects." Building collapses are frequent in India, and most are “blamed on lax safety and substandard materials,” reported BBC News. The New York Times pointed out that “municipal authorities rarely condemn buildings even when they appear to have dangerous defects.” Regardless, “even unsafe buildings attract people who want to live in them because the competition for shelter is fierce among millions of city residents.” Read the full story, New York Times... Read the full story, BBC News... Read the court decision
Read the full story...
Reprinted courtesy of

What Types of “Damages Claims” Survive a Trustee’s Sale?

February 28, 2018 — Ben Reeves – Real Estate Litigation blog / Snell & Wilmer
Introduction Arizona’s trustee’s sale statutory scheme provides for the waiver of all defenses and objections to a trustee’s sale that: (i) are not raised prior to the sale, and (ii) do not result in an injunction against the sale going forward. See A.R.S. § 33-811(C). In other words, if you have an objection to a trustee’s sale, you must seek and obtain an injunction prior to the sale or your objection will be waived. Arizona’s Court of Appeals previously held that notwithstanding this statutory waiver, “common law” defenses to repayment of the debt survive a non-judicial foreclosure even in the absence of an injunction prior to the sale. See Morgan AZ Financial, L.L.C. v. Gotses, 235 Ariz. 21, 326 P.3d 288 (Ct. App. 2014). Our analysis of the Morgan decision can be found here. In Zubia v. Shapiro, 243 Ariz. 412, 408 P.3d 1248 (2018), the Arizona Supreme Court revisited the issue of what claims survive a trustee’s sale, and clarified that if a person fails to enjoin a trustee’s sale prior to its occurrence, then that person waives any and all damages claims dependent upon a trustee’s sale. That person does not, however, waive damages claims that are independent of the sale. Thus, determining what types of claims are “dependent” versus “independent” of a trustee’s sale is of critical importance to lenders and borrowers alike. Read the court decision
Read the full story...
Reprinted courtesy of Ben Reeves, Snell & Wilmer
Mr. Reeves may be contacted at breeves@swlaw.com

Understanding the Real Estate and Tax Implications of Florida's Buyer Ban Law

July 16, 2023 — Kelly Erb - White and Williams LLP
Last month, Gov. Ron DeSantis (R) of Florida signed a new law that would prohibit people who are not U.S. citizens or permanent residents and whose "domicile" is in China from purchasing certain real property in the state. Generally, the prohibition applies to agricultural land and other land within ten miles of restricted areas, including military bases and infrastructure like airports and wastewater treatment plants. The law, which takes effect on July 1, 2023, would also impose criminal penalties on any person or real estate company that knowingly sells real estate in the Sunshine State to anyone impacted by the ban. Read the court decision
Read the full story...
Reprinted courtesy of Kelly Erb, White and Williams LLP
Ms. Erb may be contacted at erbk@whiteandwilliams.com

Precast Standards' Work Under Way as Brittle Fracture Warnings Aired

December 22, 2019 — Nadine M. Post - Engineering News-Record
The American Concrete Institute is gearing up to develop ACI’s first code requirements specifically for precast concrete. The recent announcement of the initiative comes on the heels of an article in the September issue of ACI’s monthly magazine, Concrete International, that sounds the alarm about the potential for brittle failures of precast, prestressed-concrete double-T parking decks, with flanges reinforced with a non-code-compliant polymer-coated carbon-fiber grid product, called C-Grid. Reprinted courtesy of Nadine M. Post, Engineering News-Record Ms. Post may be contacted at postn@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Trump Administration Issues Proposed 'Waters of the U.S.' Rule

December 19, 2018 — Pam Radtke Russell - Engineering News-Record
Construction contractors said a proposed revised definition of “Waters of the United States,” released by the Environmental Protection Agency and the Army Corps of Engineers on Dec. 11, would provide their firms with clarity about what types of permits they will need for their construction projects near various bodies of water. Read the court decision
Read the full story...
Reprinted courtesy of Pam Radtke Russell, ENR
Ms. Russell may be contacted at Russellp@bnpmedia.com

Contractors Prepare for a Strong 2021 Despite Unpredictability

April 05, 2021 — Kenny Ingram - Construction Executive
A recent IFS study found many construction and engineering companies are reimagining their business models to ensure a secure future, using the pandemic-induced lull in business to prepare themselves to get back to operations on a strong footing. The research shows 70% of businesses have increased or maintained digital transformation spend, despite the COVID-19 pandemic. In the infrastructure, engineering and construction sectors the figure is more than 75%. There are many challenges the industry will face in the new year following the unpredictability of 2020, but there are also many opportunities. Despite the uncertainties that lay ahead, here are the few trends predicted to impact the sector 2021 and beyond. Reprinted courtesy of Kenny Ingram, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES