FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Team Temporarily Stabilizes Delaware River Bridge Crack

February 02, 2017 — Justin Rice - Engineering News-Record
The team temporarily stabilizing the Delaware River Bridge and planning its permanent repair also are trying to find a precedent for the bridge’s uncommon fracture. Connecting the Pennsylvania and New Jersey turnpikes, the 61-year-old symmetrical truss bridge was shut down indefinitely on Jan. 20, when a complete fracture in a steel truss was discovered below the bridge deck. Read the court decision
Read the full story...
Reprinted courtesy of Justin Rice, ENR
Mr. Rice may be contacted at ricej@enr.com

---

A Relatively Small Exception to Fraud and Contract Don’t Mix

April 01, 2015 — Christopher G. Hill – Construction Law Musings
Remember all of my posts about how fraud and contract claims don’t usually play well in litigation? Well, as always with the law, there are exceptions. For instance, a well plead Virginia Consumer Protection Act claim will survive a dismissal challenge. A recent opinion out of the Alexandria division of the U. S. District Court for the Eastern District of Virginia sets out another exception, namely so called fraudulent inducement. In XL Specialty Ins. Co. v. Truland et al, the Court considered the question of whether both a tort and contract claim can coexist in the same lawsuit when the tort claim is based upon the information provided to the plaintiff when that information proves false. As the courts of Virginia have held for years, only certain information and statements made pre-contract can be the basis for a fraud claim in the face of a contractual duty to perform. One type of statement that is not properly the subject of a fraud in the inducement type claim is sales talk or opinion. Such sales talk (for example claiming that your company is the best for the job) is not the subject of a fraud claim because it is not meant to be relied upon and that such talk is an opinion about future performance, not a false statement of present fact or intent. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, Law Office of Christopher G. Hill, PC
Mr. Hill may be contacted at chrisghill@constructionlawva.com

---

NTSB Cites Design Errors in Fatal Bridge Collapse

November 28, 2018 — Scott Judy - Engineering News-Record
Design errors may have played a role in the collapse of the 174-foot-long bridge span that was under construction at Florida International University, according to a Nov. 15 investigative update from the National Transportation Safety Board (NTSB). The structure, which was being constructed over live traffic along SW 8th Street, killed six when it suffered a sudden, catastrophic collapse on March 15. Read the court decision
Read the full story...
Reprinted courtesy of Scott Judy, ENR
Mr. Judy may be contacted at judys@enr.com

---

Pacing in Construction Scheduling Disputes

September 14, 2017 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway. However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

---

The Word “Estimate” in a Contract Matters as to a Completion Date

February 12, 2024 — David Adelstein - Florida Construction Legal Updates
Language in a contract matters. The word “estimates” or “estimated” matters particularly when it comes to a date certain such as a substantial completion or completion date. Remember this. Here is an example. In Parque Towers Developers, LLC v. Pilac Management, Ltd., 49 Fla.L.Weekly D190a (Fla. 3d DCA 2024), a trial court held that the developer did not complete the construction of five condominium units by the date in the purchase agreements. The developer appealed because “[t]he agreements contain no date certain for the completion of the units, but rather include a clause that ‘Seller estimates it will substantially complete construction of the Unit, in the manner specified in this Agreement, by December 31, 2017, subject to extensions resulting from ‘Force Majeure (the ‘Outside Date’).’” Parque Towers, supra. Another provision in the purchase agreements stated, “[w]henver this Agreement requires Seller to complete or substantially complete any item of construction, that item will be understood to be complete or substantially complete when so completed or substantially completed in Seller’s opinion. Id. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Florida Property Bill Passes Economic Affairs Committee with Amendments

April 14, 2011 — Beverley BevenFlorez CDJ STAFF

The Florida Property Bill (HBB 803) was passed by the Economic Affairs Committee by a vote of 11-7, according to Property Casualty 360, after adopting nine new amendments. The additions to the bill included limiting notice of claims to a set number of years, extending the statute of limitation on property claims from five years to six years, among others.



HB 803 and SB 408, the Senate companion bill, focus primarily on residential property insurance. They make changes to the Florida Hurricane Catastrophe Fund, while also promoting increased notification of policy changes to policyholders. Sections of the bills provide minor fixes such as renaming Citizens Property Insurance Corporation to Taxpayer-Funded Property Insurance Corporation. However, other sections of the bills contain more significant policy changes such as sinkhole coverage and hurricane claims.



The bills’ intent, according to the SunSentinel.com, is to reduce fraudulent claims and to bring new insurers into the insurance market. However, SunSentinel.com also reports that the bills may drastically increase property insurance premiums.



Read the full Property Casualty 360 article...



Read the full Sun Sentinel article...

Read the court decision
Read the full story...
Reprinted courtesy of

---

Consequential Damages Can Be Recovered Against Insurer In Breach Of Contract

July 22, 2019 — David Adelstein - Florida Construction Legal Updates
In a favorable case for insureds, the Fifth District Court of Appeal maintained that “when an insurer breaches an insurance contract, the insured is entitled to recover more than the pecuniary loss involved in the balance of the payments due under the policy in consequential damages, provided the damages were in contemplation of the parties at the inception of the [insurance] contract.” Manor House, LLC v. Citizens Property Insurance Corp., 44 Fla. L. Weekly D1403b (Fla. 5thDCA 2019) (internal citations and quotation omitted). Thus, consequential damages can be recovered against an insurer in a breach of contract action (e.g., breach of the insurance policy) if the damages can be proven and were in contemplation of the parties at the inception of the insurance contract. In Manor House, the trial court entered summary judgment against the insured holding the insured could not seek lost rental income in its breach of contract action against Citizens Property Insurance because the property insurance policy did not provide coverage for lost rent. However, the Fifth District reversed this ruling because the trial court denied the insured the opportunity to prove whether the parties contemplated that the insured, an apartment complex owner, would suffer lost rental income (consequential damages) if the insurer breached its contractual duties. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

U.S. Department of Defense Institutes New Cybersecurity Maturity Model Certification

July 13, 2020 — Joseph N. Frost - Peckar & Abramson
Contractors doing business with the Federal Government, particularly with the Department of Defense (“DoD”), commonly handle sensitive information that is not intended to be disseminated. Controlled Unclassified Information (“CUI”) is one such type and is more specifically defined as “information that requires safeguarding or dissemination controls pursuant to and consistent with laws, regulations and government-wide policies.”1 Because some DoD contracts require contractors to handle CUI, certain safeguards have been put in place to ensure its security. This article briefly touches on the current cybersecurity protocols, followed by a discussion of the new system being developed by the DoD, and what contractors most need to know about the new system. The Defense Federal Acquisition Regulation Supplement (“DFARS”) has long required contractors to comply with certain cybersecurity standards, as published by the National Institute of Standards and Technology (“NIST”). Specifically, DFARS sought to implement the cybersecurity framework found in NIST Special Publication (“SP”) 800-171, entitled “Protecting Controlled Unclassified Information in Nonfederal Systems and Organizations.” NIST SP 800-171 sets forth fourteen (14) families of recommended security requirements for protecting the confidentiality of CUI in nonfederal systems and organizations, including, among others, access control, audit and accountability, incident response, personnel security, and system and information integrity. However, after a series of data breaches, the DoD reassessed the efficacy of the continued use of NIST SP 800-171 and ultimately decided to institute a new methodology to ensure the security of CUI. Read the court decision
Read the full story...
Reprinted courtesy of Joseph N. Frost, Peckar & Abramson
Mr. Frost may be contacted at jfrost@pecklaw.com

---