Hawaii Appellate Court Finds Duty to Defend Group Builders Case
May 10, 2013 —
Tred EyerlyOn May 19, 2010, the Hawaii Intermediate Court of Appeals determined construction defect claims did not constitute an occurrence under a CGL policy.Group Builders, Inc. v. Admiral Ins. Co., 123 Haw. 142, 231 P.3d 67 (Haw. Ct. App. 2010) ("Group Builders I"). The appeal in Group Builders I, however, only addressed the duty to indemnify. The ICA has now issued a second decision (unpublished), holding that there is was duty to defend Group Builders on the construction defect claims under Hawaii law, based upon the policy language and the allegations in the underlying complaint. Group Builders, Inc. v. Admiral Ins. Co., 2013 Haw.App. LEXIS 207 (Haw. Ct. App. April 15, 2013).
The underlying suit involved allegations by Hilton Hotels Corp. that Group Builders, a subcontractor working on an addition to the hotel, was responsible for mold found after completion of the project. Hilton alleged that the "design, construction, installation, and/or selection of the . . . building exterior wall finish . . . did not provide an adequate air and/or moisture barriers." The counts alleged against Group Builders included breach of contract and negligence.
Read the court decisionRead the full story...Reprinted courtesy of
Tred EyerlyMr. Eyerly can be contacted at
te@hawaiilawyer.com
Contractor Prevailing Against Subcontractor On Common Law Indemnity Claim
June 29, 2020 —
David Adelstein - Florida Construction Legal UpdatesCommon law indemnity is not an easy claim to prove as the one seeking common law indemnity MUST be without fault:
Indemnity is a right which inures to one who discharges a duty owed by him, but which, as between himself and another, should have been discharged by the other and is allowable only where the whole fault is in the one against whom indemnity is sought. It shifts the entire loss from one who, although without active negligence or fault, has been obligated to pay, because of some vicarious, constructive, derivative, or technical liability, to another who should bear the costs because it was the latter’s wrongdoing for which the former is held liable.
Brother’s Painting & Pressure Cleaning Corp. v. Curry-Dixon Construction, LLC, 45 Fla. L. Weekly D259b (Fla. 3d DCA 2020) quoting Houdaille Industries, Inc. v. Edwards, 374 So.2d 490, 492-93 (Fla. 1979).
Not only must the one seeking common law indemnity be without fault, but there also needs to be a special relationship between the parties (indemnitee and common law indemnitor) for common law indemnification to exist. Brother’s Painting & Pressure Cleaning Corp., supra (citation omitted). A special relationship has been found to exist between a general contractor and its subcontractors. Id. at n.2.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Employees in Construction Industry Entitled to Compensation for Time Spent Complying with Employer-Mandated Security Protocols
August 19, 2024 —
Garret Murai - California Construction Law BlogWage and hour laws dictating how employers must compensate their employees for time worked can, given the innumerable ways that employees perform their jobs, raise a number of questions. The next case, Huerta v. CSI Electrical Contractors, 15 Cal.5th 908 (2024) – which I won’t spend a lot of time discussing since I think it applies in somewhat limited situations – addresses whether employees are entitled to be paid while waiting to enter and exit worksites and for meal periods when they are not allowed to exit a worksite.
The Huerta Case
The 9th Circuit Court of Appeals requested that the California Supreme Court address three questions related to whether employees should be compensated under California wage and hour laws for time spent waiting to enter and exit worksites and for meal periods when they are not allowed to exit a worksite:
- Whether employees should be paid for time spent waiting in a personal vehicle to be scanned in and out of a worksite;
- Whether employees should be paid for time spent traveling in a personal vehicle from a security gate to employee parking lots; and
- Whether employees should be paid during meal periods if they are not permitted to leave a worksite.
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Nomos LLPMr. Murai may be contacted at
gmurai@nomosllp.com
Why 8 Out of 9 Californians Don't Buy Earthquake Insurance
August 27, 2014 —
Alyssa Abkowitz – BloombergEarly estimates suggest the economic losses from Sunday’s 6.0-magnitude earthquake in Northern California, the largest quake to hit the Golden State in 25 years, could hit $1 billion. When it comes to rebuilding, much of the cost will come out of people’s own pockets.
The percentage of homeowners with earthquake insurance in California and across the U.S. has declined, despite rising estimates of the risk of an earthquake. A survey by the Insurance Information Institute, a nonprofit that’s funded by the insurance industry, found that 7 percent of U.S. homeowners have earthquake insurance, down from 13 percent just two years ago. In the West, ground zero for U.S. quakes, 10 percent of homeowners have coverage, down from 22 percent a year ago; in California, about 12 percent do, according to the California Earthquake Authority.
But as fewer people opt for earthquake insurance, the government is upping its assessment of the risk of a sizable shake. Last month, the U.S. Geological Survey updated its seismic hazard maps for the first time since 2008. The update showed an increased earthquake risk for almost half the country. Parts of Washington, Oregon, Oklahoma, and Tennessee, among others, moved into the top two hazard zones. The San Francisco Bay area, for example, shows a 63 percent chance of one or more major earthquakes before 2036, according to the agency.
Read the court decisionRead the full story...Reprinted courtesy of
Alyssa Abkowitz, Bloomberg
Delays and Suspension of the Work Under Fixed Price Government Contract
July 22, 2024 —
David Adelstein - Florida Construction Legal UpdatesHere is an interesting fact pattern and case decided by the Civilian Board of Contract Appeals dealing with (1) force majeure type events and epidemics (Covid-19); (2) suspension of the work; and (3) delays. These are three topics important to all contractors including federal contractors.
In Lusk Mechanical Contractors, Inc. v General Services Administration, 2024 WL 1953697, CBCA 7759 (CBCA 2024), a contractor entered into a fixed price contract with the government to repair, replace, and modernize site and building systems at a federal building. The contractor commenced work right before Covid-19. When Covid-19 hit, the government issued the contractor a two-week suspension of work notice on March 27, 2020. The suspension of work allowed off-site administrative work to continue but suspended on-site physical work. The government extended the suspension of work three more times. The contractor could resume work on the exterior on June 1, 2020, but was not permitted to resume work on the interior until July 20, 2020. On the same date that the contractor was able to commence interior work, it submitted a modification for delay caused by the suspension – 64 days for the time period the entire site shutdown, and 51 days for the interior work shutdown.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
If You Don’t Like the PPP Now, Wait a Few Minutes…Major Changes to PPP Loan Program as Congress Passes Payroll Protection Program Flexibility Act
July 27, 2020 —
Ryan J. Udell & Adam J. Chelminiak - White and Williams LLPOn June 5, 2020, President Trump signed into law the Payroll Protection Program Flexibility Act of 2020 (the Flexibility Act). The Flexibility Act provides much-needed flexibility for the Paycheck Protection Program (PPP) and its millions of business participants.
The PPP offers loans to small businesses that have been adversely impacted by the COVID-19 pandemic and the measures taken by various governmental authorities to stem the spread of the virus so that they could keep their employees on the payroll during an eight-week period after receiving the funds. The PPP was particularly alluring to borrowers because the loans could be forgiven. But as the duration of lockdown orders and the accompanying economic aftershocks have extended longer than initially anticipated, particularly in those sectors that depend on in-person business such as restaurants, hospitality and other “main street” retail establishments, many recipients of PPP loans have found it challenging to use the PPP funds for payroll and other authorized purposes within the eight-week period after they had received the PPP funds, as is necessary to preserve eligibility for forgiveness. The Flexibility Act makes several key changes to the PPP program in order to allow borrowers who need a longer re-opening runway to do so without jeopardizing their ability to qualify for loan forgiveness.
This alert outlines the key changes to the PPP made by the Flexibility Act.
Reprinted courtesy of
Ryan J. Udell, White and Williams LLP and
Adam J. Chelminiak, White and Williams LLP
Mr. Udell may be contacted at udellr@whiteandwilliams.com
Mr. Chelminiak may be contacted at chelminiaka@whiteandwilliams.com;
Read the court decisionRead the full story...Reprinted courtesy of
The Secret to Success Is Doing Things a Little Bit Differently
November 16, 2020 —
Charlie Kimmel - Construction ExecutiveThroughout the 1960s and 1970s, Rick Barry made his mark on the world of college and professional basketball. He was a skilled small forward who averaged 37.4 points per game during his senior year at the University of Miami, and he was the second overall pick in the 1965 NBA draft. But he’s best remembered as a prolific free-throw shooter: he led the NBA in free-throw percentage for several consecutive years. When he retired in 1980, his free-throw percentage (.900) was the highest in NBA history.
So what was the secret to his success? He did things a little bit differently. While the vast majority of basketball players shoot overhand free throws, Barry was famous for his unorthodox underhanded shots. This technique was not only incredibly effective, but it also set him apart as a player and contributed to his popularity.
Construction companies can learn a lot from Barry’s strategy of doing things a little bit differently to achieve success. Most companies don’t need to worry about their employees’ free-throw techniques. But all of them need to set themselves apart from their competition and establish strong reputations in today’s highly competitive market.
Reprinted courtesy of
Charlie Kimmel, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Read the court decisionRead the full story...Reprinted courtesy of
Supreme Court of Oregon Affirms Decision in Abraham v. T. Henry Construction, et al.
April 20, 2011 —
Beverley BevenFlorez CDJ STAFFAfter reviewing the decision in Abraham v. T. Henry Construction, et al., the Oregon Supreme Court affirmed that a tort claim for property damage arising from construction defects may exist even when the homeowner and the builder are in a contractual relationship.
When the case was initially filed, the plaintiffs alleged breach of contract and negligence. The defendants moved for summary judgment arguing that one, the claim was barred by the six-year statute of limitations and two, no special relationship (such as one between a doctor and patient) existed. The court agreed with the defendants. However, the Court of Appeals while affirming the trial court’s decision on breach of contract reversed the decision on negligence. The Court of Appeals stated that an administrative or statute rule could establish a standard of care independent from the contract.
The Oregon Supreme Court gave an example of cases where a tort claim could exist when a contract is present: “If an individual and a contractor enter into a contract to build a house, which provides that the contractor will install only copper pipe, but the contractor installs PVC pipe instead (assuming both kinds of pipe comply with the building code and the use of either would be consistent with the standard of care expected of contractors), that failure would be a breach of contract only. […] If the failure to install the copper pipe caused a reduction in the value of the house, the plaintiff would be able to recover that amount in an action for breach of contract. […] On the other hand, if the contractor installed the PVC pipe in a defective manner and those pipes therefore leaked, causing property damage to the house, the homeowner would have claims in both contract and tort. […] In those circumstances, the obligation to install copper instead of PVC pipe is purely contractual; the manner of installing the pipe, however, implicates both contract and tort because of the foreseeable risk of property damage that can result from improperly installed pipes.”
Read the court’s decision…
Read the court decisionRead the full story...Reprinted courtesy of
