Fairfield Connecticut Building Expert Directory

Boilerplate Contract Language on Permits could cause Problems for Contractors

March 19, 2014 — Beverley BevenFlorez-CDJ STAFF
Craig Martin on his blog Construction Contractor Advisor discusses the potential problems for a contractor that a “boilerplate contract” could cause: “A recent case revealed the problems a contractor had with permits when the contractor’s estimate contemplated an easy permitting process and compliance, but in actuality it was much, much more difficult.” Martin cites the case Bell/Heery v. United States, where a contractor discovered that the permit process would be much more time-consuming and expensive than originally planned. When Bell/Heery asked for additional funds to cover the additional costs, the “contracting officer rejected the request, finding that Bell/Heery had assumed the risk of the permitting process and it was liable for any costs associated with the permitting process and construction methods required by the permitting process.” “Bell/Heery appealed to the Court of Claims,” but lost the battle. The contractor had to absorb $7 million in costs to comply with the required permits. Read the court decision
Read the full story...
Reprinted courtesy of

Construction Cybercrime Is On the Rise

May 26, 2019 — Tom Sawyer & Jeff Rubenstone - Engineering News-Record
At the end of April, just as St. Ambrose Roman Catholic Church in Brunswick, Ohio, neared the close of a five-month-long, $5.5-million renovation, Father Bob Stec, the parish pastor, was surprised to hear that the contractor, Marous Brothers Construction, Willoughby, Ohio, had not received a $1.7- million payment. Reprinted courtesy of Tom Sawyer, Engineering News-Record and Jeff Rubenstone, Engineering News-Record Mr. Sawyer may be contacted at sawyert@enr.com Mr. Rubenstone may be contacted at rubenstonej@enr.com Read the court decision
Read the full story...
Reprinted courtesy of

Quick Note: Mitigation of Damages in Contract Cases

October 02, 2018 — David Adelstein - Florida Construction Legal Updates
In an earlier article, I discussed an owner’s measure of damages when a contractor breaches the construction contract. This article discussed a case where the contractor elected to walk off a residential renovation job due to a payment dispute when he demanded more money and the owners did not bite. This case also discussed the commonly asserted defense known as mitigation of damages, i.e., the other party failed to properly mitigate their own damages. In the breach of contract setting, mitigation of damages refers to those damages the other side could have reasonably avoided had he undertaken certain (reasonable) measures. This is known as the doctrine of avoidable consequences. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Protect Your Right To Payment By Following Nedd

August 03, 2022 — Denise Motta - Gordon & Rees Construction Law Blog
In order to preserve your right to payment, you must satisfy the contractual requirements supporting a change order for the increased costs or time due to the delay. The key to the successful presentation of change order claims is educating your team on the following: 1. NOTICE

Review the change order and notice provisions of your contracts. Make your contract searchable and insert the term “Noti” and look for the items listed below.
Who: Check the designated representative for notice.

It may not be the project manager.
Confirm who can authorize the change order.

Is owner approval required?
Ensure that the party approving the change order has authority to do so.

What: Check for specific information required by the contract.

Provide ALL information available.
If certain information is not yet available, state that the information will be provided when available.
Reserve all rights to amend and submit additional information.
Request both an increase to the Contract Sum and Contract Time.

Make the request even if you do not believe the delay or time necessary will cause a significant impact.

Read the court decision
Read the full story...
Reprinted courtesy of Denise Motta, Gordon Rees Scully Mansukhani, LLP
Ms. Motta may be contacted at dmotta@grsm.com

Yet ANOTHER Reason not to Contract without a License

October 25, 2021 — Christopher G. Hill - Construction Law Musings
Remember when I stated that you cannot lawfully perform construction work in Virginia without a contractor’s license? Remember when I said that you risk non-payment if you do so? If you needed another reason, a relatively recent Virginia Court of Appeals decision upholding a criminal conviction for performing construction work without a license should be that reason. In Riddel v. Commonwealth, the Court took up an appeal from the conviction of Jeff Riddel where Mr. Riddel was verbally asked by homeowners to inspect and then repair their septic system. Mr. Riddel then contracted with Fairfax Suburban Septic to pump out and repair the system. Mr. Riddel then delivered the homeowners an invoice from Fairfax Suburban Septic and instructed the homeowners to pay Fairfax Suburban Septic directly. After payment, the homeowners became aware that the work was not completed and that neither Mr. Riddel nor his subcontractor was licensed to perform septic work in Virginia. During the trial, Mr. Riddel argued on a Motion to Strike the Commonwealth’s evidence that (1) he merely arranged for licensed contractors to perform the repairs to the septic system, arguing that Virginia Code §§ 54.2-801 to 802 permitted Riddel to arrange the work without a contractor’s license and (2) no written contract to perform a septic inspection or repairs existed. The Circuit Court denied the motion and Mr. Riddel was convicted under Va. Code 54.1-111 for performing the work without a license. Needless to say, he appealed. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

English v. RKK. . . The Saga Continues

December 16, 2019 — Christopher G. Hill - Construction Law Musings
Remember back in 2018 when I thought I’d told you the end of the English Construction story regarding its various consultants, etc.? I was wrong. The matter went up on appeal to the 4th Circuit Court of Appeals where the Appeals Court considered the summary judgment granted to the defendant Rummel, Klepper & Kahl (“RKK”) based upon what came down to a contributory negligence reading of the indemnity clause that was allowed to survive in the first district court opinion relating to these ambiguous contracts finding that English was negligent so couldn’t recover. The 4th Circuit also considered the finding that defendant CDM Smith did not breach its contract as a matter of law and that English’s negligence was the cause of the damages. The Court of Appeals reversed both of the holdings by the Western District of Virginia court, essentially stating that there was enough of a factual dispute to render any summary judgment to be premature. As to English’s arguments regarding the indemnity scheme in the contracts, the court found that the interpretation was at least ambiguous enough that summary judgment was inappropriate, stating:

While we are not prepared to settle conclusively these interpretation disputes at the summary judgment stage, English’s proffered interpretation is, at the very least. reasonable. Indeed, of the two interpretations, English’s seems to be more closely aligned with the actual language in the contract. The district court thus erred in rejecting English’s interpretation and adopting RK&K’s interpretation as a matter of law.

[A]t bottom, while the district court was authorized to construe unambiguous language as a matter of law, it could not resolve genuine disputes regarding the meaning of ambiguous contractual language against the nonmoving party on summary judgment. We therefore vacate the court’s grant of summary judgment to RK&K and remand for further proceedings.

Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

2019 Legislative Session

June 03, 2019 — Steve Heisdorffer – Colorado Construction Litigation
Two bills under consideration as the end of the session nears contain significant changes to Colorado’s Consumer Protection Act (“CCPA”). The bills broaden remedies, make more conduct a breach of the CCPA, and include purely private transactions in the type of conduct that falls within the scope of the CCPA. The bills are House Bill 19-1289 (“House Bill”) and Senate Bill 19-237 (“Senate Bill”). As of April 29, 2019, the House Bill has passed the House. The Senate Bill has not progressed past introduction. It is unclear if both houses of the legislature will have an opportunity to vote on either or both bills before the session ends. The House Bill makes a person liable for CCPA violations based on conduct engaged in “recklessly,” not just knowing conduct. No definition of the term “recklessly” is provided in the House Bill, but Colorado’s attorney general testified “recklessly” “means a company or person acted with reckless disregard for the truth.” (Page 2). No explanation was given of what the word “reckless” in the definition of “recklessly” meant in this context. Another provision of the House Bill adds a “catch all” prohibition that labels as a deceptive trade practice knowingly or recklessly engaging in any unfair, unconscionable, deceptive, deliberately misleading, false or fraudulent act or practice. There is no indication how a person could “recklessly” engage in “deliberately misleading” acts or practices. Read the court decision
Read the full story...
Reprinted courtesy of Steve Heisdorffer, Higgins, Hopkins, McLain & Roswell
Mr. Heisdorffer may be contacted at heisdorffer@hhmrlaw.com

Couple Claims Poor Installation of Home Caused Defects

December 30, 2013 — CDJ STAFF
Robert and Tracy Samosky of Spanishburg, West Virginia have filed a lawsuit claiming that the improper delivery of their modular home caused defects and damages, preventing them from actually using their home. The couple purchased a modular home from J&M Quality Construction for a home designed and built by Mod-U-Kraf Homes. They are suing the two firms for $50,000 in damages, reports the West Virginia Record. Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES