Submitting Claims on Government Projects Can Be Tricky
March 19, 2015 —
Craig Martin – Construction Contractor AdvisorThe Federal Circuit Court of Appeals opinion in K-Con Building Systems, Inc. v. United States illustrates the difficulties a contractor may face when pursuing a claim before a Contracting Officer. After nearly 10 years of litigation, the court found that the contractor’s claim to the Contracting Officer did not contain enough detail to allow the claim to proceed. That’s a lot of time and resources wasted on a claim that was dead from the start.
K-Con was awarded a $582,000 job to design and build a Coast Guard support building in Michigan. K-Con was unable to complete the project by the finish date and the Coast Guard assessed liquidated damages of $109,554. K-Con contested the assessment of liquidated damages by submitting a one paragraph letter asserting that it was not the sole cause of the alleged delays; that the government was at fault for the delay; and the liquidated damages were an impermissible penalty. The Contracting Officer ultimately denied K-Con’s claim and K-Con appealed to the Court of Claims.
Read the court decisionRead the full story...Reprinted courtesy of
Craig Martin, Lamson, Dugan and Murray, LLPMr. Martin may be contacted at
cmartin@ldmlaw.com
Settlement Ends Construction Defect Lawsuit for School
October 02, 2013 —
CDJ STAFFThe school district in the Chicago-area town of Lake Zurich has made last settlement in a construction defect lawsuit. The $80,000 settlement from Terra Group of Chicago brings the total settlement with the Community Unit School District 95 to about $1.9 million. Other firms included Bovis Lend Lease, Legat Architects, Larson Engineering, and Illinois Masonry Corporation.
The school district had contracted for work on several schools in the district. The buildings opened in 2004, with defect claims made in 2007. Defect claims included the failure of a retaining wall and need for reinforcement of stairwells. The settlement with Terra Group was made under the agreement that it was a compromise with no concession of liability.
Read the court decisionRead the full story...Reprinted courtesy of
Does Your U.S. Company Pull Data From European Citizens? Fall In Line With GDPR by May 2018 or Suffer Substantial Fines
November 15, 2017 —
Jeff Dennis & Ivo Daniele – Newmeyer & Dillion, LLPThe European Union (“EU”) has enacted a strict, comprehensive framework of security regulations aimed to protect its citizens. These regulations, known as the General Data Protection Regulation (“GDPR”), provide a blueprint for a combination of required legal, technological and work habits within an organization. Although this is an EU regulation, the new laws will apply to any organization within or outside the EU that collects or processes data of EU citizens. Therefore, U.S. companies must analyze their data and processes to determine whether compliance with the GDPR is necessary. A quickly-approaching deadline of May 25, 2018 must be met to avoid massive fines.
What is the GDPR?
In order to address the creation of social networking sites, cloud computing, and location-based services, the EU set in motion a process to implement a vigorous set of rules to ensure the right to personal data protection for all European citizens. In April 2016 the European Parliament, the Council, and the Commission adopted a new GDPR, which will take affect on May 25, 2018.
This GDPR will streamline cooperation between the data protection authorities on personal data issues allowing companies to deal with one authority - not each of the 28 EU member states. This will allow for quicker decisions by the data protection authorities and greatly reduce the red tape in both compliance and enforcement under the GDPR. This will also create a level playing field by forcing non-EU companies to comply with the same strict regulations - regardless of whether or not the company is established in the EU.
Territorial scope of the GDPR
The GDPR applies directly to the processing of personal data in the context of the activities of an establishment of a controller or a processor in the EU - regardless of whether the processing takes place in the EU. Additionally, there are specific provisions under the GDPR that apply to non-EU companies if their processing activities relate to (a) the offering of goods or services (irrespective of whether a payment of the data subject is required) or (b) monitoring the behavior of individuals within the EU. Therefore, all companies must determine whether they process or monitor information of EU citizens. If a company falls within one of these categories, compliance with the GDPR is mandatory.
What happens if a company fails to comply with the GDPR?
Failure to comply with the GDPR could subject a company to crushing administrative fines.
The supervisory authority has the power to impose administrative fines under the GDPR. The following violations and breaches would subject a company to administrative fines:
- Not adhering to the core principles of processing personal data,
- Breach of notification to EU citizens by controllers and processors,
- Wrongful transfer of personal data to non-EU countries,
- Breach of obligations regarding certification,
- Ignoring the mandates asserted by the supervisory authority,
- Breach by those responsible for impact assessment, and
- Wrongful processing of employee data.
The extent of the violation and type of personal data involved will dictate the severity of the administrative fines imposed on a company. For example, under the GDPR, a company could be subject to administrative fines up to 20,000,000 EUR, or up to 4% of the total worldwide annual revenue of the preceding financial year. Obviously, these fines would be financially crippling to any company.
Preparing for May 25, 2018
The May 25, 2018 deadline is fast approaching and preparing for full compliance with the GDPR is paramount. Simple steps should be taken to ensure compliance including to:
(1) Review and analyze data repositories for sensitive data,
(2) Perform an analysis/accounting of procedure for data collection, and
(3) Create an oversite committee dedicated to data activities and compliance.
Most importantly, however, is to determine whether compliance with the GDPR is necessary, and strictly follow the requirements of the GDPR to protect from potentially massive fines.
Jeffrey M. Dennis currently serves as Newmeyer & Dillion’s Managing Partner and as a business leader, advises his clients on cybersecurity related issues, introducing contractual and insurance opportunities to lessen their risk. You can reach Jeff at jeff.dennis@ndlf.com.
Ivo Daniele is a seasoned associate in Newmeyer & Dillion’s Walnut Creek office. His practice includes representing private and public companies with both their transactional and litigation needs. You can reach Ivo at ivo.daniele@ndlf.com.
About Newmeyer & Dillion
For more than 30 years, Newmeyer & Dillion has delivered creative and outstanding legal solutions and trial results for a wide array of clients. With over 70 attorneys practicing in all aspects of business, employment, real estate, construction and insurance law, Newmeyer & Dillion delivers legal services tailored to meet each client’s needs. Headquartered in Newport Beach, California, with offices in Walnut Creek, California and Las Vegas, Nevada, Newmeyer & Dillion attorneys are recognized by The Best Lawyers in America©, and Super Lawyers as top tier and some of the best lawyers in California, and have been given Martindale-Hubbell Peer Review's AV Preeminent® highest rating. For additional information, call 949-854-7000 or visit www.ndlf.com.
Read the court decisionRead the full story...Reprinted courtesy of
Does Your U.S. Company Pull Data From European Citizens? Fall In Line With GDPR by May 2018 or Suffer Substantial Fines
Courthouse Reporter Series: Two Recent Cases Address Copyright Protection for Architectural Works
January 16, 2024 —
Stu Richeson - The Dispute ResolverRecent decisions by the Seventh Circuit and the Eight Circuit have addressed the scope of protection afforded to architectural works under copyright law. The Seventh Circuit case of Design Basics, LLC v. Signature Constr., Inc., 994 F.3d 879 (7th Cir. 2021), took a somewhat narrow view of the copyright protection afforded to the design of an “affordable, multipurpose, suburban, single-family home.” In Designworks Homes, Inc. v. Columbia House of Brokers Realty, Inc., 9 F.4th 803 (8th Cir. 2021), cert. denied, 142 S. Ct. 2888, 213 L. Ed. 2d 1103 (2022) the Eight Circuit held that the publication of floor plans of a house in a real estate listing was not protected from claims of copyright infringement.
Design Basics, LLC v. Signature Constr., Inc., involved a plaintiff that the court described as holding registered copyrights in thousands of floor plans for suburban, single-family homes that are basic schematic designs, largely conceptual in nature, and depict layouts for one- and two-story single-family homes that include the typical rooms: a kitchen, a dining area, a great room, a few bedrooms, bathrooms, a laundry area, a garage, stairs, assorted closets, etc. The court described the plaintiff as a “copyright troll” and noted that litigation proceeds had become the principal revenue stream for the plaintiff. The plaintiff sued a contractor and related businesses contending hat the defendants had infringed plaintiff’s copyrighted floor plans.
Read the court decisionRead the full story...Reprinted courtesy of
Stu Richeson, PhelpsMr. Richeson may be contacted at
stuart.richeson@phelps.com
Everybody Is Going to End Up Paying for Texas' Climate Crisis
March 29, 2021 —
David R Baker & Mark Chediak - BloombergFallout from last month’s deadly deep freeze in Texas has quietly spread to people living hundreds of miles away. Minnesota utilities have warned that monthly heating bills could spike by $400, after the crisis jacked up natural gas prices across the country. Xcel Energy’s Colorado customers could face a $7.50 per month surcharge for the next two years.
This is a subtle demonstration of the way Americans already share the collective financial burden of climate change, even if we don’t realize it. The national bill for global warming is here, and it’s rising.
Perhaps it’s easier to see this dynamic playing out beyond February’s Texas cold snap. That disaster left dozens dead, stranded millions in dark homes, and sent a shockwave of higher gas prices across the nation. But since there remains scientific uncertainty over the role of global warming, let’s examine two other calamities for which the climate link is clearer: wildfires and tropical storms.
Read the court decisionRead the full story...Reprinted courtesy of
David R Baker & Mark Chediak, Bloomberg
Withdrawal Liability? Read your CBA
July 10, 2018 —
Wally Zimolong – Supplemental Conditions Withdrawal liability is a huge issue facing unionized employers. According to Bloomberg, 93% of the Top 200 largest pension plans are underfunded by a combined $382 billion. Contractors that withdraw from a multi-employer pension plan can face hundreds of thousands or millions of dollars in assessed withdrawal liability. However, employers may be able to avoid that liability, plus the legal and consulting fees to fight it, by simply reading their collective bargaining agreement.
Read the court decisionRead the full story...Reprinted courtesy of
Wally Zimolong, Zimolong LLCMr. Zimolong may be contacted at
wally@zimolonglaw.com
Halliburton to Pay $1.1 Billion to Settle Spill Lawsuits
September 03, 2014 —
David Wethe, Margaret Cronin Fisk and Laurel Calkins – BloombergHalliburton Co. agreed to pay $1.1 billion to settle a majority of lawsuits brought over its role in the largest offshore oil spill in U.S. history.
The agreement is subject to court approval and includes legal fees, the Houston-based company said in a statement today. Halliburton was accused by spill victims and BP Plc of doing defective cementing work on the Macondo well before the April 2010 Gulf of Mexico oil spill. Halliburton blamed the incident on decisions by BP, which owned the well.
The settlement comes as the judge overseeing oil-spill cases weighs fault for the disaster. An agreement now averts the company’s risk of a more costly judgment for some spill victims and removes much of the uncertainty that has plagued Halliburton for the past four years as investors waited to see the payout tally. With its biggest piece of liability resolved, Halliburton can refocus its attention on developing new oilfield technology that will help it boost profits worldwide.
Reprinted courtesy of Bloomberg journalists
David Wethe,
Margaret Cronin Fisk and
Laurel Calkins
Mr. Wethe may be contacted at dwethe@bloomberg.net; Ms. Fisk may be contacted at mcfisk@bloomberg.net; and Ms. Calkins may be contacted at lcalkins@bloomberg.net
Read the court decisionRead the full story...Reprinted courtesy of
An Upward Trend in Commercial Construction?
March 28, 2012 —
Melissa Brumback, Construction Law in North CarolinaYear-end economic indicators demonstrate that private commercial construction may be increasing in 2012, primarily as demand grows for new projects built in the United States.
According to an article in Businessweek, the Architecture Billings Index held at 52 in December, indicating a modest expansion in the market. The American Institute of Architects said that the commercial and industrial component of the number climbed to 54.1 in December, the highest in 10 months.
The monthly survey of U.S.-based architecture firms is one of the main indicators of nonresidential construction, and these numbers suggest that modest improvement may be on the horizon.
The information is confirmed by data from the Census Bureau that shows that spending on lodging, office, commercial and manufacturing buildings grew 8.2 percent in November to $9.2 billion from a year ago. These types of commercial and industrial projects are historically canaries in the mine and are usually the first part of the industry to improve as the economy expands.
Read the full story…
Reprinted courtesy of Melissa Dewey Brumback of Ragsdale Liggett PLLC. Ms. Brumback can be contacted at mbrumback@rl-law.com.
Read the court decisionRead the full story...Reprinted courtesy of
