Seattle Washington Building Expert Directory

Late Progress Payments on Local Public Works Projects Are Not a Statutory Breach of Contract

May 10, 2022 — Ted Senet & Christopher Trembley - Gibbs Giden
California local public agencies and their contractors should take note of a recent appellate decision pertaining to late progress payments on public works projects. In Clark Bros., Inc. v. North Edwards Water Dist., 2022 Cal. App. LEXIS 331, filed on April 22, 2022, the Court of Appeal for the Fourth Appellate District held that a local agency’s late progress payments to a general contractor did not constitute breach of contract under the prompt payment penalty statute, Public Contract Code § 20104.50. Notwithstanding this holding, the contractor recovered damages, interest, fees, and costs in excess of its contract amount. In 2013, the North Edwards Water District awarded a $6.2 million contract to Clark Bros., Inc. to construct a water treatment facility. The District’s water contained excessive levels of arsenic, and the project was sponsored by the State of California with funds earmarked to provide safe drinking water. The State agreed to disburse funds to the District during construction upon the State’s review and approval of the contractor’s progress payment applications. The contract required completion of the work within one year following the District’s issuance of a notice to proceed to the contractor. As a result of factors arguably outside the control of the contractor, including unforeseen site conditions and the failure of the District’s equipment supplier to meet delivery deadlines, the project was significantly delayed beyond the deadline for completion. The District nonetheless terminated the contractor, which in turn filed suit against the District and the State. The contractor asserted claims for breach of contract, including breach of contract for the District’s failure to pay the contractor’s progress payment applications within the time specified under Public Contract Code § 20104.50. Subsection (b) of the statute provides:

Any local agency which fails to make any progress payment within 30 days after receipt of an undisputed and properly submitted payment request from a contractor on a construction contract shall pay interest to the contractor equivalent to the legal rate set forth in subdivision (a) of Section 685.010 of the Code of Civil Procedure.

Reprinted courtesy of Ted Senet, Gibbs Giden and Christopher Trembley, Gibbs Giden Mr. Senet may be contacted at tsenet@gibbsgiden.com Mr. Trembley may be contacted at Ctrembley@gibbsgiden.com Read the court decision
Read the full story...
Reprinted courtesy of

Cooperation and Collaboration With Government May Be on the Horizon

September 17, 2018 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel
In Is the Pendulum Swinging on Agency and Government Contractor Cooperation?, Pillsbury attorneys Mike Rizzo, Glenn Sweatt and Kevin Massoudi discuss comments from the Department of Defense as well as recent good faith and fair dealing court decisions that point to and encourage improved contractor/government relationships. Their key takeaways include

Government officials are actively encouraging collaboration with, and less antagonism of, industry contractors.

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

Mississippi Supreme Court Addresses Earth Movement Exclusion

December 09, 2019 — Anthony Hatzilabrou - Traub Lieberman
Recently, the Mississippi Supreme Court held that structural damages to the foundation of an insured’s home came within the earth movement exclusion in a homeowner’s policy, notwithstanding a provision in the policy which provided coverage for water damage resulting “from accidental discharge or overflow of water … from within … [p]lumbing, heating, air condition or household appliance.” In Mississippi Farm Bureau Cas. Ins. Co. v. Smith, 264 So. 3d 737 (Miss. 2019), the appellee, Smith, filed a lawsuit against her homeowner's insurance company, Mississippi Farm Bureau Casualty Insurance Company (“Farm Bureau”) for its refusal to pay for repairs to the foundation of Smith’s home. Smith alleged that the refusal to pay for repairs amounted to breach of contract and asserted claims for bad faith and tortious breach of contract. In response, Farm Bureau filed a motion for summary judgment on the basis of the policy’s earth-movement exclusion, which provided that Farm Bureau “did not insure for loss caused directly or indirectly by…Earth Movement…[which] means…[a]ny other earth movement including earth sinking, rising or shifting... caused by or resulting from human or animal forces.” Smith filed a cross-motion for partial summary judgment on the basis that the earth-movement exclusion did not preclude coverage because her insurance policy also contained a clause expressly covering water damage. Read the court decision
Read the full story...
Reprinted courtesy of Anthony Hatzilabrou, Traub Lieberman
Mr. Hatzilabrou may be contacted at thatzilabrou@tlsslaw.com

Condominium Association Responsibility to Resolve Construction Defect Claims

July 23, 2014 — Nicholas D. Cowie – Maryland Condo Construction Defect Law Blog
The Maryland Court of Special Appeals recently issued an opinion in Greenstein v. Council of Unit Owners of Avalon Court Six Condominium Inc. finding that an association can be sued by its unit owner members if it fails to take timely legal action against a developer. In that case, the association was aware of construction defects, but failed to take action to preserve its claim and then filed a lawsuit against the developer too late, after the statute of limitations expired. As a result, the suit against the developer was dismissed and the association was forced to assess its unit owner members for the $1 million in repair costs. Some of the unit owners then sued their association, seeking to recover the cost of their assessments on the ground that the association was negligent in failing to pursue a timely legal action against the developer. On appeal, the court was asked to decide whether state law permits owners to sue their condominium association for negligently failing to sue a developer for common element construction defects. The court, in an unpublished opinion, found that an association could be held liable to its members. The court said: “The duty to maintain, repair and replace the common elements together with the exclusive right to initiate litigation regarding the common elements [which was stated in a provision of the association’s bylaws] creates a concomitant obligation on the part of the [association] to pursue recovery from [the developer] on behalf of [the unit owners] for damage to the common elements caused by [the developer’s] negligence, breach of contract or violation of any applicable law.” Read the court decision
Read the full story...
Reprinted courtesy of Nicholas D. Cowie, Maryland Condo Construction Defect Law Blog
Mr. Cowie may be contacted at ndc@cowiemott.com

Claim for Vandalism Loss Survives Motion to Dismiss

October 02, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The court ruled that the insured's claim for vandalism of his house by a renter and for bad faith survived the insurer's motion to dismiss. Wehrenberg v. Metro. Prop. & Cas. Ins. Co., 2015 U.S. Dist. LEXIS 103758 (W.D. Pa. Aug. 7, 2015). The insured's home was insured by a homeowner's policy issued by Metropolitan. The insured rented his home to Alphonso Hyman in October 2011. In lieu of rent, Hyman was to pay the mortgage company the equivalent of his rent each month. In early 2012, Hyman stopped making the monthly rent/mortgage payments. The insured went to the home and found the locks had been changed. Looking in the windows, he saw the interior had been gutted. When the insured reached Hyman, Hyman said he was a contractor and was fixing the structural problems and would put the house back together. He also promised to make up late payments to the mortgage company. The insured did not report what he found to Metropolitan. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Megaproject Savings Opportunities

April 15, 2014 — Beverley BevenFlorez-CDJ STAFF
Joel Levy in Construction Digital interviewed Christopher Dann, a Partner of Booz & Company’s Energy, Chemicals and Utilities practice, regarding how to be more efficient and save money when managing billion dollar construction megaprojects. According to Construction Digital, “Booz & Company, (recently rebranded as Strategy&), is celebrating its 100th anniversary this year, and over a century of working with huge clients in several sectors, has gathered the knowledge to identify what it terms a $40 trillion opportunity for savings in construction megaprojects over the next 20 years as clients combat a 30 percent average figure of overrun in schedule and cost.” Dann cited several reasons for inefficiencies in megaprojects, including “inefficient advance planning and analysis” and “lack of completion of detail design engineering prior to the start of construction,” reported Construction Digital. The inefficiencies can be countered, according to Dann, “when following a clear strategy.” Read the court decision
Read the full story...
Reprinted courtesy of

Reminder: Your Accounting and Other Records Matter

July 30, 2015 — Christopher G. Hill – Construction Law Musings
Recently, I’ve posted on mechanic’s lien changes, mediation and other more “legal” topics here at Construction Law Musings. Today’s post is a practical one and one that will help your friendly neighborhood construction attorney greatly should a dispute arise. The tip for this week? Keep clean accounting and other records by construction job and in an organized fashion. This tip seems like a simple one, but I run into situations where the accounting on jobs, contracts, invoices and other key documents for a project are either missing or haphazardly kept. In the best of these cases, I have to spend additional time (read attorney fees) to attempt a recreation of the job costs and flow of the project. In the worst, I have had to either release or avoid filing what could have been a valid mechanic’s lien because timing could not be determined from the records. I also thank my friend Craig Martin for another unfortunate horror story of poor accounting that should be a warning to us all. Read the court decision
Read the full story...
Reprinted courtesy of Christopher G. Hill, Law Office of Christopher G. Hill, PC
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Florida Federal Court to Examine Issues of Alleged Arbitrator Conflicts of Interests in Panama Canal Case

May 24, 2021 — Sarah B. Biser & Philip Z. Langer - ConsensusDocs
The parties in a $238-million dispute over the construction of the third set of locks for the Panama Canal are raising issues concerning alleged conflicts of interest on the part of the International Chamber of Commerce (“ICC”) arbitrators in the United States District Court for the Southern District of Florida.[2] The case may address rarely litigated issues concerning whether arbitrators who sit on multiple arbitration panels together or who support appointment of each other to lead arbitration panels have disabling conflicts of interest. The case pits Grupo Unidos por el Canal, S.A. (“Grupo”), a consortium of Spanish, Italian, Belgian, and Panamanian construction firms, against Autoridad del Canal de Panama (“ACP”), the Panamanian entity that operates the Panama Canal and that sponsored the multi-billion-dollar, decade-long project to expand the Canal’s capacity by building a new set of locks (the “Project”). The current dispute (the “Panama 1 Arbitration”), which centers on the suitability of the rock coming from the excavations to be used to produce concrete aggregates for the Project, was arbitrated before a three-member ICC Tribunal and resulted in a $238-million award to ACP and against Grupo. The ICC Tribunal reversed a decision of the dispute review board established in the parties’ contract. Reprinted courtesy of Sarah B. Biser, Fox Rothschild LLP and Philip Z. Langer, Fox Rothschild LLP Ms. Biser may be contacted at sbiser@foxrothschild.com Mr. Langer may be contacted at planger@foxrothschild.com Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES