Fairfield Connecticut Building Expert Directory

Formal Request for Time Extension Not Always Required to Support Constructive Acceleration

April 25, 2022 — David Adelstein - Florida Construction Legal Updates
Does a constructive acceleration claim require the contractor to always request an extension of time which is then denied by the owner? While this is certainly the preference and the contractor should be requesting an extension of time as a matter of course for an excusable delay, the answer is NO! in certain circumstances. This is conveyed in the factually detailed case discussed below where a formal request for an extension of time was not required for the contractor to support its constructive acceleration claim. But first, what is constructive acceleration: Constructive acceleration “occurs when the government demands compliance with an original contract deadline, despite excusable delay by the contractor.” The Federal Circuit in Fraser defined the elements of constructive acceleration as follows: (1) that the contractor encountered a delay that is excusable under the contract; (2) that the contractor made a timely and sufficient request for an extension of the contract schedule; (3) that the government denied the contractor’s request for an extension or failed to act on it within a reasonable time; (4) that the government insisted on completion of the contract within a period shorter than the period to which the contractor would be entitled by taking into account the period of excusable delay, after which the contractor notified the government that it regarded the alleged order to accelerate as a constructive change in the contract; and (5) that the contractor was required to expend extra resources to compensate for the lost time and remain on schedule. Nova Group/Tutor-Saliba v. U.S., 2022 WL 815826, *42 (Fed.Cl. 2022) quoting Fraser Constr. Co. v. U.S., 384 F.3d 1354, 1361 (Fed. Cir. 2004) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

To Arbitrate or Not to Arbitrate? That is the Question

April 28, 2016 — Garret Murai – California Construction Law Blog
It’s been the fodder of debate of philosophers, academics and the rest of us for ages:

Do we have free will or are our actions predetermined and the result of preceding events?
Are human beings fundamentally selfless or self preserving?
Coca-Cola or Pepsi?
iOs or android?

And for litigators and their clients, including us construction lawyers, arbitration or litigation? Or, in short, if a project goes sideways, in what forum will you resolve your dispute? It’s an important question the answer to which could mean the difference between winning or losing. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Contractor Prevails on Summary Judgment To Establish Coverage under Subcontractor's Policy

June 07, 2021 — Tred R. Eyerly - Insurance Law Hawaii
When sued for construction defects caused by the subcontractor, the general contractor was granted summary judgment on the issue of coverage under the subcontractor's policy. Meritage Homes of Ga. v. Grange Ins. Co., 2021 U.S. Dist. LEXIS 84591 (N.D. Ga. March 23, 2021). Meritage built a home for the owners. Easterwood Excavating, Inc. was the subcontractor for excavation and grading work. Meritage was named an additional insured under Easterwood's policy with Grange. After construction was completed, the owners were experiencing severe flooding after rain storms purportedly due to defects in the grading, site preparation and excavation. The owners filed an arbitration against Meritage for damages. The owners alleged that Meritage improperly excavated and graded their lot, causing water to collect and pool in their yard. Meritage denied all liability and looked to Easterwood and Grange for defense and indemnification. Grange denied coverage, contending there was no occurrence which resulted in property damage. The arbitrator found that the folding of water was caused by Meritage's improper grading of the lot. A Final Award in the amount of $129,530.93 was issued against Meritage. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Key Economic & Geopolitical Themes To Monitor In 2024

January 16, 2024 — Global Insights Center Staff - The Hartford
Slowing US Economic Growth and Flattening Interest Rates Growth in the first half of 2023 averaged approximately 2.0%, driven mainly by private sector investments outside of the residential housing sector, government spending, and strong consumer demand. In 2024, The Hartford’s Global Insights Center is expecting investments and government spending to continue and may support growth in the year. However, consumer health may start to weaken due to elevated leverage, higher interest rates, and sticky inflation. Since the Federal Reserve began to increase interest rates, consumer activity and household finances have not been tremendously affected. However, as revolving interest rates (credit card loans) continue to reset that may change, especially since household savings rates fell below pre-pandemic levels and may affect consumer demand. Read the court decision
Read the full story...
Reprinted courtesy of Global Insights Center Staff, The Hartford

Kiewit Selected for Rebuild of Collapsed Baltimore Bridge

September 02, 2024 — Jim Parsons - Engineering News-Record
Kiewit Infrastructure Co. has been tapped to rebuild Baltimore’s I-695/Francis Scott Key Bridge under a progressive design-build procurement announced Aug. 29 by the Maryland Transportation Authority (MDTA). Work on the expected four-year reconstruction effort is scheduled to begin next year. Reprinted courtesy of Jim Parsons, Engineering News-Record ENR may be contacted at enr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Lead Paint: The EPA’s Renovation, Repair and Painting Rule

September 09, 2019 — Christopher G. Hill - Construction Law Musings
For this week’s Guest Post Friday here at Musings, we welcome Joshua Glazov for the first time. Josh has been a construction lawyer since 1995. He practices at Much Shelist in Chicago and focuses on negotiating and preparing design and construction contracts for owners, contractors, and lenders, as well as preparing for, and confronting, construction related insolvency when a project participant goes bankrupt or a lender goes into FDIC receivership. Josh publishes on these topics at his blogs: Construction Law Today and the Bank Failure Blog. Last month the EPA finally issued their Renovation, Repair and Painting Rule (PDF), the one that sets up new requirements for work on projects that may involve lead paint. The requirements are many complex. You’ll need to become familiar with this rule if you do any renovation , repair, or painting work, especially of your work is on buildings built before lead paint was banned in 1978.

You’ll need to become a certified by the EPA as a Certified Renovation Firm

Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

West Coast Casualty’s Quarter Century of Service

May 03, 2018 — Beverley BevenFlorez-CDJ STAFF
West Coast Casualty's Construction Defect Seminar has been promoting charitable work for the past twenty-five years. Each year, they promote different charities, and provide multiple ways for individuals and companies to contribute. Whether it’s Buy a Banner, Tennis Shoe Thursday, or Flip Flop Friday, industry members are given opportunities to support worthwhile causes. This year, West Coast Casualty is supporting Hawaii’s Children’s Cancer Foundation , St. Jude Children’s Research Hospital, and Shriners Hospital for Children. WCC also supports charitable organizations through every award that they present each year. Donations are made in the winner’s name: For Jerrold S. Oliver Award of Excellence awardees, Habitat for Humanity as well as a local California and Nevada charity; For Legend of an Era Award, the designated charity of West Coast Casualty’s Construction Defect Seminar; and for The Larry Syhre Commitment to Service Award, a donation to The Larry Syhre Foundation. Read the court decision
Read the full story...
Reprinted courtesy of

Don’t Assume Your Insurance Covers A Newly Acquired Company

February 19, 2019 — Patrick M. McDermott & Michael S. Levine - Hunton Insurance Recovery Blog
The Supreme Court of Virginia’s decision yesterday finding no coverage for fire damage to a building is a cautionary tale for companies acquiring other companies. Erie Ins. Exch. v. EPC MD 15, LLC, 2019 WL 238168 (Va. Jan. 17, 2019). In that case, Erie Insurance issued a property insurance policy to EPC. The policy covered EPC only and did not cover any subsidiaries of EPC. EPC then acquired the sole member interest in Cyrus Square, LLC. Following the acquisition, fire damaged a building that Cyrus Square owned. EPC sought coverage under its property insurance policy. Because the policy did not cover Cyrus Square, EPC argued that a provision extending coverage to “newly acquired buildings” applied, contending that EPC had newly acquired Cyrus Square’s building by virtue of becoming the sole member interest in the LLC. Based on the law relative to LLCs and its interpretation of the policy, the Supreme Court of Virginia ruled against EPC. It found that although EPC had acquired Cyrus Square, it had not “newly acquired” the building and so the “newly acquired buildings” coverage extension did not apply. Reprinted courtesy of Patrick M. McDermott, Hunton Andrews Kurth and Michael S. Levine, Hunton Andrews Kurth Mr. McDermott may be contacted at pmcdermott@HuntonAK.com Mr. Levine may be contacted at mlevine@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES