Fairfield Connecticut Building Expert Directory

Think Twice Before Hedging A Position Or Defense On A Speculative Event Or Occurrence

July 13, 2020 — David Adelstein - Florida Construction Legal Updates
Sometimes, hedging a position on a potential occurrence is not prudent. Stated differently, hedging a position on a contingent event is not the right course of action. The reason being is that a potential occurrence or contingent event is SPECULATIVE. The occurrence or event may not take place and, even if it does take place, the impact is unknown. An example of hedging a defense on such a potential occurrence or contingent event can be found in a construction dispute involving a federal project out of the Eastern District of Virginia, U.S. f/u/b/o Champco, Inc. v. Arch Insurance Co., 2020 WL 1644565 (E.D.Va. 2020). In this case, the prime contractor hired a subcontractor to perform electrical work, under one subcontract, and install a security system, under a separate subcontract. The subcontractor claimed it was owed money under the two subcontracts and instituted a lawsuit against the prime contractor’s Miller Act payment bond. The prime contractor had issued the subcontractor an approximate $71,000 back-charge for delays. While the subcontractor did not accept the back-charge, it moved for summary judgment claiming that the liability for the back-charge can be resolved at trial as there is still over $300,000 in contract balance that should be paid to it. The prime contractor countered that the delays caused by the subcontractor could be greater than $71,000 based on a negative evaluation in the Contractor Performance Assessment Reporting System (“CPARS”). A negative CPARS rating by the federal government due to the delays caused by the subcontractor would result in a (potential) loss of business with the federal government (i.e., lost profit) to the prime contractor. The main problem for the prime contractor: a negative CPARs rating was entirely speculative as there had not been a negative CPARs rating and, even if there was, the impact a negative rating would have on the prime contractor’s future business with the federal government was unknown. To this point, the district court stated:

In this case, [prime contractor’s] claim for damages is wholly speculative. [Prime contractor] has not produced any evidence that its stated condition precedent—a negative CPARS rating—will actually occur and will have a negative impact on its future federal contracting endeavors. Specifically, [prime contractor] has not identified any facts that indicate that it will be subject to a negative CPARS rating or any indication of the Navy’s dissatisfaction with its work as the prime contractor on the Project… Further, a CPARS rating is only one aspect taken into consideration when federal contracts are awarded. In sum, there is no evidence of the following: (1) a negative CPARS rating issued to [prime contractor]; (2) [prime contractor’s] hypothetical negative rating will be the result of the delay [prime contractor] alleges was caused by [subcontractor]; or (3) [prime contractor’s] hypothetical negative CPARS rating will result in future lost profits.

U.S. f/u/b/o Champco, Inc., supra, at *2 (internal citation omitted).

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Bay Area Firm Offers Construction Consulting to Remodels

October 02, 2013 — CDJ STAFF
Homeowners sometimes aren’t too clear on questions of “building codes, permit process or where to find the right materials,” according to Benoni Mocanu, the owner of MB Development. He’s ready to step in an help by offering construction consulting to homeowners doing their own remodeling projects. In addition to providing the advice to help them through their projects, they’re ready to step in if a homeowner finds that they can’t finish the project. Read the court decision
Read the full story...
Reprinted courtesy of

Time To “Construct” New Social Media Policies

March 28, 2022 — Aaron C. Schlesinger, Lauren Rayner Davis & Jennifer Harris - ConsensusDocs
1. The Social Media Dilemma Social media has significantly impacted all facets of society, especially the way people communicate. Its impact and application to the construction industry is no different. TikTok, the video-sharing platform, is one of the world’s most popular platforms today, with over one billion active users monthly. From just one video, users can gain thousands—if not millions—of followers overnight. Social media has been used to present a narrative that the workplace can be fun, or that employees are enjoying working together. Social media can also, however, serve as a tool to document a perfect storm of events, such as a building collapse or crane malfunction, which can then be misconstrued and smeared throughout the internet, all with your company’s logo in the background. So, what happens when an incident on your jobsite is branded across social media as a #constructionfail, and the project owner ultimately initiates legal action? Can this video be used against your company? Can employers limit or otherwise restrict employees’ social media activity to avoid potential liability? How does the existence of social media posts affect dispute resolution procedures? Reprinted courtesy of Aaron C. Schlesinger, Peckar & Abramson, P.C. (ConsensusDocs), Lauren Rayner Davis, Peckar & Abramson, P.C. (ConsensusDocs) and Jennifer Harris, Peckar & Abramson, P.C. (ConsensusDocs) Mr. Schlesinger may be contacted at aschlesinger@pecklaw.com Ms. Davis may be contacted at ldavis@pecklaw.com Ms. Harris may be contacted at jharris@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Submitting Claims on Government Projects Can Be Tricky

March 19, 2015 — Craig Martin – Construction Contractor Advisor
The Federal Circuit Court of Appeals opinion in K-Con Building Systems, Inc. v. United States illustrates the difficulties a contractor may face when pursuing a claim before a Contracting Officer. After nearly 10 years of litigation, the court found that the contractor’s claim to the Contracting Officer did not contain enough detail to allow the claim to proceed. That’s a lot of time and resources wasted on a claim that was dead from the start. K-Con was awarded a $582,000 job to design and build a Coast Guard support building in Michigan. K-Con was unable to complete the project by the finish date and the Coast Guard assessed liquidated damages of $109,554. K-Con contested the assessment of liquidated damages by submitting a one paragraph letter asserting that it was not the sole cause of the alleged delays; that the government was at fault for the delay; and the liquidated damages were an impermissible penalty. The Contracting Officer ultimately denied K-Con’s claim and K-Con appealed to the Court of Claims. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

Supplement to New California Construction Laws for 2019

January 08, 2019 — Daniel F. McLennon - Smith Currie
A representative of the Contractors State License Board would like to emphasize a benefit of SB 1042 not mentioned in the report below that Smith Currie published recently. Importantly, the new law allows the CSLB to work with licensees, resolve complaints informally, and avoid a full Administrative Procedure Act hearing brought by the California Attorney General’s office. If the CSLB and licensee are unable to resolve a citation informally, the licensee is still entitled to the APA hearing. Contractors receiving CSLB citations are wise to avail themselves of this process. Read the court decision
Read the full story...
Reprinted courtesy of Daniel F. McLennon, Smith Currie
Mr. McLennon may be contacted at dfmclennon@smithcurrie.com

Congratulations to Wilke Fleury’s 2023 Super Lawyers and Rising Stars!!

July 10, 2023 — Wilke Fleury LLP
Wilke Fleury is extremely proud that 18 of its incredible attorneys have been selected as 2023 Northern California Super Lawyers or Rising Stars! Super Lawyers rates attorneys in each state using a patented selection process and publishes a yearly magazine issue that produces award-winning features on selected attorneys. Congratulations to this talented group: Super Lawyers of 2023 David A. Frenznick Steven J. Williamson Matthew W. Powell Daniel L. Egan George A. Guthrie Michael G. Polis Daniel J. Foster Stephen K. Marmaduke Neal C. Lutterman Trevor L. Stapleton Ronald R. Lamb Read the court decision
Read the full story...
Reprinted courtesy of Wilke Fleury LLP

Housing Inventory Might be Distorted by Pocket Listings

July 23, 2014 — Beverley BevenFlorez-CDJ STAFF
NBC News reported that pocket listings, or unadvertised listings, may be hiding the true number of homes on the market. “A so-called pocket listing is when the real estate agent signs a listing agreement with a seller but does not advertise it widely or put it in a multiple listing service, where other agents and buyers can see it,” according to NBC News. Lawrence Yun, chief economist for the Realtors, told NBC News that he believes the perceived shortage of inventory “is due to the prevalence of pocket listings in some markets." Pocket listings aren’t illegal. There aren’t any “hard numbers” for these unadvertised listings, and so the number of actual listings is based on conjecture by realtors. "The conditions are ripe for this kind of approach to take," Nela Richardson, chief economist at Redfin, a real estate brokerage, told NBC News. “When there is limited inventory, an agent is able to convince a seller, because there is so much demand for housing that maybe as many eyeballs don’t need to see your home as in a traditional market.” Read the court decision
Read the full story...
Reprinted courtesy of

Colorado’s Need for Condos May Spark Construction Defect Law Reform

January 29, 2014 — Beverley BevenFlorez-CDJ STAFF
On January 6th, Ed Sealover of the Denver Business Journal reported that Denver Mayor Michael Hancock has asked Colorado legislators “to pass a reform law that will make it easier to build condos without fear of getting sued.” Hancock is one of several mayors “to advocate for a construction defects reform proposal that was killed by Democrats in a committee last year.” The problem, Sealover notes, is that only “2 percent of new housing in the state is multifamily units made for ownership—far lower than the 20 to 25 percent of such housing stock in other states represented by condos.” There is some dissent as to whether reforming construction defect laws is the solution to the housing problem: “Taking away rights of homeowners to get shoddy construction fixed in what is likely the most expensive purchase in their life is not the way to fix the lack of affordable housing,” Lynea Hansen, spokeswoman for a group of construction defect homeowners told Sealover. Furthermore, on January 7th, Sealover reported that Democrats “expressed skepticism” about a need to reform the laws, saying “they need more data on what is causing owner-occupied multifamily housing to be such a small part of the new housing market.” Moreover, Senate President-elect Morgan Carroll stated that she “wants to look into issues like why it is so hard to get insurance for building condominiums or examine why some areas of Colorado are seeing condo development and others aren’t.” Read the full story, January 6th article... Read the full story, January 7th article... Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES