Seattle Washington Building Expert Directory

Colorado Drillers Show Sensitive Side to Woo Fracking Foes

September 03, 2014 — Zain Shauk and Bradley Olson – Bloomberg
A fight over fracking is looming in Texas. Another stand-off is shaping up in Colorado. Yet drillers’ reactions couldn’t be more different. In Texas, drillers are doing their noisy in-your-face fracking as usual. Meanwhile, on a small farm about an hour from the Colorado Rocky Mountains, the oil industry is giving fracking a makeover, cutting back on rumbling trucks and tamping down on pollution. Oil companies in Colorado are responding to a rising tide of resentment as local communities and environmental activists vie to impose measures to ban fracking or restrict drilling. A series of ballot initiatives and other grass roots opposition around the country is seen as threatening the booming shale industry, even in oil-friendly Texas, where the U.S. energy renaissance began. Reprinted courtesy of Zain Shauk, Bloomberg and Bradley Olson, Bloomberg Mr. Shauk may be contacted at zshauk@bloomberg.net; Mr. Olson may be contacted at bradleyolson@bloomberg.net Read the court decision
Read the full story...
Reprinted courtesy of

California Appeals Court Remands Fine in Late Completion Case

November 18, 2011 — CDJ STAFF

The California Court of Appeals in Stanislaus County has reversed the decision of the lower court in Greg Opinski Construction Inc. v. City of Oakdale. The earlier court had awarded the city of judgment of $54,000 for late completion, $3,266 for repair of construction defects and interest, and $97,775 in attorneys’ fees. The late completion of the project was due to actions by the City of Oakdale, however, the court rejected Opinski’s argument that the California Supreme Court decision in Kiewit did not allow this, as his contract with the city established a procedure for claiming extensions.

The appeals court noted that the Kiewit decision has been “criticized as an unwarranted interference in the power of contracting parties to shift the risk of delays caused by one party onto the other party by forcing the second party to give the first notice of any intention to claim an extension of time based on delays caused by first.” They cited Sweet, a professor at Boalt Hall, UC Berkeley’s law school, that Kiewit “gutted” the “provision that conditions the contractor’s right to claim an extension of time for delays beyond his control.”

Further changes in California law in response to the Kiewit decision lead to the current situation which the court characterized as “if the contractor wished to claim it needed an extension of time because of delays caused by the city, the contractor was required to obtain a written change order by mutual consent or submit a claim in writing requesting a formal decision by the engineer.”

Opinski also argued that the lower court misinterpreted the contract. The Appeals court replied that “Opinski is mistaken.” He cited parts of the contract regarding the increase of time, but the court rejected these, noting that “an inability to agree is not the same as an express rejection.”

The court also rejects Opinski’s appeal that “the evidence the project was complete earlier than September 30, 2005, is weightier than the evidence to the contrary,” which they describe as “not a winning appellate argument.” The court points out that the role of an appeals court is not to reweigh the evidence, but to determine “whether the record contains substantial evidence in support of the judgment.”

The court did side with Opinski on one question of the escrow account. They rejected most of his arguments, repeating the line “Opinski is mistaken” several times. They decided that he was mistaken on the timing of the setoff decision and on whether the city was the prevailing party. However, the appeals court did find that Opinski was not liable for interest on the judgment.

The appeals court rejected the awarding of prejudgment interest to the city as the funds from which the judgment was drawn was held in an escrow account. The court noted that the city had access to the funds and could “access the funds when it determined that Opinski had breached the contract.” The appeals court noted that the judgment exhausted the escrow balance and remanded the case to the lower court to determine the amount own to Opinski.

Read the court’s decision…

Read the court decision
Read the full story...
Reprinted courtesy of

AGC Seeks To Lead Industry in Push for Infrastructure Bill

May 01, 2019 — Jennifer Seward - Engineering News-Record
The ongoing call for better infrastructure funding, along with workforce innovation and an enhanced focus on diversity and inclusivity, is taking center stage at the Associated General Contractors of America. The association’s leaders emphasized that these issues are crucial to the industry’s future as more than 2,800 attendees gathered for AGC’s annual convention in Denver April 1-4. Read the court decision
Read the full story...
Reprinted courtesy of Jennifer Seward, ENR
ENR may be contacted at ENR.com@bnpmedia.com

Hunton Insurance Coverage Group Ranked in National Tier 1 by US News & World Report

December 21, 2020 — Hunton Insurance Recovery Blog
The Hunton Andrews Kurth Insurance Coverage Practice Group has been awarded Tier 1 ranking by US News Media Group and Best Lawyers, placing them among the top practitioners nationally for policyholder insurance coverage representation. In addition to its Tier 1 ranking nationally, the Firm also received a regional Tier 1 ranking in Washington, DC and a Tier 2 ranking in Atlanta, GA. Reprinted courtesy of Hunton Andrews Kurth LLP Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

The Construction Lawyer as Counselor

June 10, 2019 — Christopher G. Hill - Construction Law Musings
It’s been a while since I discussed the role that I believe a construction lawyer should serve. Back in 2013, I discussed how those of us that practice construction law are seen as “necessary evils.” I was thinking over the weekend about certain clients and matters (as I often do, particularly in the shower) and came to the conclusion that the best role for me as a Virginia construction attorney is that of counselor and sounding board for my clients. Sure I come from a litigation background, enjoy working with other construction lawyers here in the Commonwealth, and often the first contact that I have with clients is when there is a problem, but I enjoy my practice, and I believe clients are more satisfied with their interactions with me when I try and provide a more cost effective and pragmatic solution than that which litigation or arbitration provides. The six years of solo construction practice since 2013 (yes, I’m close to the 9 year mark with my practice) has only served to cement the fact that construction professionals need and want the “counselor” portion of “attorney and counselor at law.” Working as a sort of “in house counsel” to various construction companies, as opposed to simply dealing with the litigation, allows me to better understand their businesses and assist them in avoiding problems through contract review, discussions of situations that come up short of claims, and general risk management. I also get to know these mostly small business owners on a more personal level (sometimes even resulting in a fishing trip or two). Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Jet Crash Blamed on Runway Construction Defect

December 11, 2013 — CDJ STAFF
The Old Republic Insurance Company is suing Macon, Georgia, claiming that the runway was improperly built, leading to the crash of the corporate jet of one of their clients. The insurer paid out $1 million to the owner of the jet. Now it seeks to recover that from the city, claiming the runway was both too short and built in a manner that caused rainwater to pool. Read the court decision
Read the full story...
Reprinted courtesy of

South Carolina “Your Work” Exclusion, “Get To” Costs

July 30, 2014 — Scott Patterson - CD Coverage
In Precision Walls, Inc. v. Liberty Mutual Fire Insurance Co., No. 2013-000787 (S.C. Ct. App. July 23, 2014), SYS was the general contractor for a project. SYS contracted with Precision for the supply and installation of exterior insulation board, to include the taping of all joints. After Precision completed its work, another subcontractor began construction of the brick veneer wall over the insulation board. During construction of the brick wall, some of the joint sealing tape installed by Precision began to come loose. To correct the problem, the existing portion of the brick veneer wall had to be torn down, all of the joint sealing tape removed and replaced, and the brick veneer wall rebuilt. SYS deducted the cost of tearing down and rebuilding the brick veneer wall from Precision’s contract. Precision sought reimbursement for this amount from its CGL policy issued by Liberty Mutual. Read the court decision
Read the full story...
Reprinted courtesy of Scott Patterson, CD Coverage

Late Notice Bars Insured's Claim for Loss Caused by Hurricane

October 24, 2022 — Tred R. Eyerly - Insurance Law Hawaii
The court found that the failure to provide prompt notice of damage caused by Hurricane Irma barred plaintiff's claim for coverage. Garcia v. Scottsdale Ins. Co., 2022 U.S. Dist. LEXIS 149312 (S.D. Fla. Aug. 18, 2022). On September 10, 2017, plaintiff's property allegedly suffered damage due to Hurricane Irma. Shortly thereafter, plaintiff observed a water stain on the ceiling of the bedroom which was painted over. She did not take any pictures of the water stain before repainting. Plaintiff reported to her experts that she observed other water stains in various areas in 2017, 2018 and 2019, and that she painted over them each time. She again observed water stains in several rooms in 2020, at which time she became aware of the magnitude of the problem and went to an attorney. Plaintiff did not report her claim until May 27, 2020. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES