Quick Note: COVID-19 Claim – Proving Causation
August 03, 2020 —
David Adelstein - Florida Construction Legal UpdatesIn certain jurisdictions, the number of people testing positive for COVID-19 is on the rise. As this occurs, there is the possibility that a construction project will have to deal with one or more workers testing positive. That is the current reality. If the dialogue has not occurred before, now is the time to discuss any enhanced measures—above OSHA guidelines—that could be implemented to address this reality and mitigate the risk. Part of the reality, though, is that regardless of the enhanced measures and mitigation, it is impossible to truly prevent this risk.
No one disputes COVID-19. There may be a dispute as to whether COVID-19 constitutes a force majeure event or some other event, however, before you start labeling it, you still NEED TO PROVE the impact caused by COVID-19. There needs to be a cause-and-effect relationship so you can address (i) how this impacted the critical path of your schedule and/or (ii) how this impacted labor productivity. In other words, you need to prove causation. Stating there was a delay or loss of productivity without establishing the cause-and-effect relationship (i.e, causation) provides no value because it does not support the production impact or time extension and, without either, there is no basis for additional compensation (even if you establish it should be deemed an excusable, compensable delay).
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
The Association of Southern California Defense Counsel (ASCDC) and the Construction Defect Claims Managers Association (CDMA) Annual Construction Defect Seminar
December 04, 2013 —
CDJ STAFF
The Association of Southern California Defense Counsel (ASCDC) and the Construction Defect Claims Managers Association (CDMA) Jointly Present the 2013 Construction Defect Seminar and Holiday Party to be Held Thursday, December 5, at the Hilton Hotel, Costa Mesa
Professional development activities will include panel discussions including “What Happened to Simple HOA Actions – Litigating Commercial Projects,” a roundtable discussion by Ross Hart, Keith Koeller, Alex Robertson, Les Robertson, Todd Schweitzer, Wendy Wilcox, and Brian D. Kahn. A timely discussion of California’s “right to repair” laws “SB800 – Is It Still Worth Fighting For?,” will be presented by Nick Cammarota, Timothy Earl, Luke Ryan, Dave Simons, Dave Stern, John Terry, and Adrienne Cohen is also on the the agenda.. Additionally, Assemblyman Donald P. Wagner will serve as the event’s Special Guest Speaker.
Bert L. Howe & Associates, Inc. is pleased to return this year as an event sponsor. BHA will be exhibiting our latest inspection data collection system and forensic analysis platforms newly optimized for the new iOS 7. Visitors of the BHA exhibit booth can enter into our drawing for a 16 GB iPad Air with WiFi.
Professional development activities will be followed by a holiday party and reception honoring the Orange County Judiciary. The reception will be hosted by Glenn Barger, Adrienne Cohen, and Brian Kahn. It will place from 5:30 p.m. through 7.00 p.m.
For further information for the event, please visit http://www.ascdc.org/Events.asp.
Read the court decisionRead the full story...Reprinted courtesy of
Insurer’s Broad Duty to Defend in Oregon, and the Recent Ruling in State of Oregon v. Pacific Indemnity Company
January 02, 2024 —
Keith Sparks - Ahlers Cressman & Sleight PLLCOregon law mandates a broad duty to defend, requiring insurers to provide legal representation to their policyholders whenever there is a potential for coverage under the policy. The significance of this broad interpretation means that an insurer has a duty to defend an insured even in situations where the alleged facts only imply a covered claim, and even in situations where the underlying claim is ultimately not covered by the policy. The insurer’s duty to defend is triggered if the allegations of the complaint, reasonably interpreted, could result in the insured being held liable for damages covered by the policy. This is referred to as the “four-corners” rule; it is also sometimes referred to as the eight-corners rule (for the four corners of the complaint plus the four corners of the policy). Oregon’s adoption of a broad interpretation of the duty to defend affirmatively places the onus on insurers to err on the side of coverage.
This broad duty to defend is based on the principle that an insured should not have to bear the expense of defending a lawsuit that the insurer may ultimately have to pay for. The duty to defend is also important because it helps ensure that insureds have access to legal representation when faced with a lawsuit.
Read the court decisionRead the full story...Reprinted courtesy of
Keith Sparks, Ahlers Cressman & Sleight PLLCMr. Sparks may be contacted at
keith.sparks@acslawyers.com
Truck Hits Warning Beam That Falls, Kills Motorist at Las Vegas Bridge Project
July 11, 2022 —
Doug Puppel - Engineering News-RecordA truck carrying an oversized load in northwest Las Vegas on Friday struck a steel beam near a bridge construction site, sending the beam crashing onto a following vehicle and killing its driver, according to the Nevada Dept. of Transportation.
Reprinted courtesy of
Doug Puppel, Engineering News-Record
ENR may be contacted at enr@enr.com
Read the full story... Read the court decisionRead the full story...Reprinted courtesy of
Arbitration Clause Found Ambiguous in Construction Defect Case
October 28, 2011 —
CDJ STAFFThe California Court of Appeals ruled on September 28 in the case of Burch v. Premier Homes. Ms. Burch bought a home after negotiating various addendums to the contract. The contract was a standard California Association of Realtors contract to which both the buyer and seller made additions. At issue in this case was paragraph 17 of the contract which included that “Buyer and Seller agree that any dispute or claim in Law or equity arising between them out of this Agreement or resulting transaction, which is not settled through mediation, shall be decided by neutral, binding arbitration.”
The seller/defendant’s Addendum 2 “included provisions relating to the arbitration of disputes that may arise.” Ms. Burch’s realtor, Lisa Morrin, told Burch that “she had never seen a proposed contractual provision that would require a home buyer to agree to arbitrate with a builder over construction defects.” Ms. Burch told Morrin that she did not want to buy the property if she would have to give up her rights under California law.
As part of Addendum 2, the buyer had to buy a warranty from the Home Buyers Warranty Corporation. The sale was held up for a while, as Ms. Burch waited for a copy of the warranty. When she received it, she took further exception to Addendum 2. Scott Warren of Premier Homes said he could not sell the property without Addendum 2. Ms. Burch told her realtor that despite the claims made by Mr. Warren that this was for her benefit, she felt it was more to the benefit of Premier Homes. Don Aberbrook of HBW agreed to the clause, contained in the final sentence of Addendum 2, being struck.
Subsequent to buying the home, Burch submitted a claim concerning construction defects. HBW denied the claim and Burch began an action against the defendants. Premier filed a motion to compel arbitration which Burch opposed.
The trial court ruled that the striking out of the arbitration clause at the end of Addendum 2 “created a conflict with respect to the parties’ intent as to the scope of arbitration.” The trial court found that “the parties’ intention was to preserve Burch’s right to make state law claims including her right to a jury trial for any non-warranty claims against the builder.”
The appeals court in their ruling looked at the standard of review and concluded that the purchase agreement was ambiguous and that extrinsic evidence was required to resolve that ambiguity. As the contract contained contradictory provisions as to whether or not arbitration was required, it was necessary for the trial court to examine these claims. The appeals court found that the evidence supported the conclusions of the trial court.
Finally, the appeals court found that “there was no valid agreement to arbitrate disputes.” The court noted that arbitration can only happen by mutual consent and “it is clear that Burch did not enter into an agreement to arbitrate any construction defect disputes she might have.”
Read the court’s decision…
Read the court decisionRead the full story...Reprinted courtesy of
The California Legislature Return the Power Back to the People by Passing the California Consumer Privacy Act of 2018
January 02, 2019 —
Richard H. Glucksman, Esq., David A. Napper, Esq., & Lana Halavi – Chapman Glucksman Dean Roeb & BargerIntroduction
Data breaches and social media hacks are becoming increasingly common stories on the news cycle. Meanwhile, companies have made fortunes on unsuspecting individuals by selling information gathered on the user. Every internet user has wondered why a pop-up ad or banner on an unrelated website relates to something you purchased or searched for "that one time. The California legislature has decided to return some power back to the people with the California Consumer Privacy Act of 2018. California is the first state to introduce privacy protection for individuals personal data and could pave the way for other states to follow suit in the near future.
The California Consumer Privacy Act of 2018
On June 28, 2018, California Governor Jerry Brown signed into law the California Consumer Privacy Act of 2018 ("the Act"). The California Legislature eagerly passed the Act, which comes into effect on January 1, 2020, granting broad new privacy rights to "consumers" and enforcing requirements on the protection of their personal data allowing consumers the right to take back control of their personal information.
A "consumer" is defined as a "resident of California as defined by California's personal income tax regulations. "Personal information" pursuant to the Act is defined as "information that identifies, relates to, describes, is capable of being associated with, or could reasonably be linked, directly or indirectly, with a particular consumer or household." Personal information is generally recognized in California as information that can identify a specific individual. The Act also includes information that can be used to identify a household.
Provisions of the Act
Pursuant to the Act, consumers are given the right to know upon request if their personal information is disclosed, and to whom it is disclosed, the right to know what personal information has been collected about them by a business, the right to object to the sale of their personal information, the right to obtain data collected about them, the right to require businesses to obliterate their personal information, and the right to be given equal service and pricing from businesses, including equal prices and quality of goods or services. The Act forbids discrimination by businesses against consumers for exercising their privacy rights pursuant to the Act.
Businesses are, however, permitted to charge different prices or provide different quality of service to consumers if the difference is "reasonably related to the value provided to the consumer by the consumer’s data." Additionally, businesses must allow consumers to exercise their rights by providing to consumers toll-free telephone numbers and/or websites to request such information or privacy. If a consumer sends a verified request for information to a business, the business subsequently has 45 days to give the consumer the requested information from the preceding 12 months with no charge to the consumer.
Who Must Comply with the Act
The Act will apply to for-profit businesses that do business in the State of California, deal with personal information of California residents, and either·(1) have more than $25 million in annual gross revenues, or (2) receive or disclose more than 50,000 California residents' personal information, or(3) derive 50% or greater of California residents' annual revenues from selling their personal information.
Who is Exempted from Compliance with the Act
A for-profit company, a small company, and/or a company that does not derive large amounts of personal information and does not share a brand with an affiliate covered by the Act is exempted from complying with the Act. Additionally, a company is exempted from compliance with the Act "if every aspect of . . . commercial conduct takes place wholly outside of California," meaning: (1) the personal information was collected from the consumer while they were outside California, (2) no sale of their personal information took place in California, and (3) there was no sale of personal information that was collected while the consumer was in California.
Impact
According to 2017 estimates, California's population totaled approximately 39 million people. Clearly the Act will affect an incredibly large amount of people considering it concerns the most populous state in America. The California Consumer Privacy Act of 2018, which is being compared to the EU General Data Protection Regulation for its all-encompassing method and resilient privacy protections is also speculated to have an impact on businesses throughout the nation and around the world. While the costs will likely go up for companies to do business in California, the transparency and trust earned by business and gained by consumers in this new landscape could potential overcome the initial costs to provide these required services. Perhaps most importantly however, is if California consumers decide to take advantage of the new protections, they will no longer have to wonder what for-profit businesses are doing with their data.
Reprinted courtesy of Chapman Glucksman Dean Roeb & Barger attorneys
Richard H. Glucksman,
David A. Napper and
Lana Halavi
Mr. Glucksman may be contacted at rglucksman@cgdrblaw.com
Mr. Napper may be contacted at dnapper@cgdrblaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Erdogan Vows to Punish Shoddy Builders Ahead of Crucial Election
April 25, 2023 —
Selcan Hacaoglu - BloombergTurkish President Recep Tayyip Erdogan vowed to punish breakers of construction-safety regulations in the wake of February’s deadly earthquakes, a move to distance himself from the devastation brought by tens of thousands of building collapses.
“We will squeeze them into a corner,” Erdogan said in an interview with with CNN-Turk television late Wednesday. “It will be included in crimes that can’t be pardoned.”
The aftermath of the Turkey earthquakes, which killed at least 50,000 people, has become a major talking point ahead of May 14 presidential elections. Erdogan is looking to extend his two-decade rule and is facing his toughest test yet from a united opposition, and critics say he is responsible for allowing builders to skip safety rules to win support in previous votes.
Read the court decisionRead the full story...Reprinted courtesy of
Selcan Hacaoglu, Bloomberg
Federal Government Partial Shutdown – Picking Up the Pieces
February 27, 2019 —
Jacob W. Scott - Now that the partial shutdown has ended (though with the specter of another just around the corner), contractors are asking, “What now?” and “What did that cost me?” Although every case is fact-specific, following are some guidelines for moving forward after the shutdown.
Following up on our previous guidance, contractors should make sure that any court, board, or agency filings made during the shutdown were received and properly docketed. If there is any question whether a filing was received, file it again as soon as possible with proof of the earlier attempt to file. The busiest tribunals, such as the federal courts, the Court of Federal Claims, the Boards of Contract Appeals, and the Government Accountability Office, remained open, or at least open to accept filings, and all indications are that filings made during the shutdown were received and acknowledged. But for some of the other tribunals or agencies, such as the Small Business Administration (“SBA”) Office of Hearings and Appeals and the SBA Office of Government Contracting and Business Development, prudence dictates double-checking that all filings were received. In many cases, non-statutory deadlines have been or will be adjusted by the court, board, or agency.
Read the court decisionRead the full story...Reprinted courtesy of
Jacob W. Scott, Smith CurrieMr. Scott may be contacted at
jwscott@smithcurrie.com
