FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

When Construction Defects Appear, Don’t Choose Between Rebuilding and Building Your Case

October 11, 2021 — Curtis Martin - ConsensusDocs
When construction defects occur during construction, they intensify pressure from a schedule that may already be tight. Defects must be analyzed, confirmed, removed, and replaced and this can be time consuming. Or course, a construction schedule rarely anticipates defects, demolition, and rework and the owner will still expect the project to be completed on time; however, pressing forward with immediate remediation may have unintended consequences. Before starting demolition, consider the evidentiary doctrine of spoliation. Spoilation occurs when a party destroys or unreasonably deprives another party of evidence and courts have imposed sanctions on a party that deprives an opponent of evidence. The doctrine has historically concerned documents, but its application has extended to electronic data, and courts also apply it to building conditions in construction defects cases. So, before tearing out or fixing defective work, consider the need to allow the opposing party to inspect, test and document it. Imagine this scenario. The concrete in a slab placed by your subcontractor shows low compressive strength results in the 28-day cylinder tests. Tearing out the slab and replacing it will put you at least a month behind schedule and you don’t want to waste any time before removing and replacing it. Nevertheless, while you’re rebuilding the defective slab, be mindful that you are also building a case. If you plan to recover the costs you incur because of the defective concrete from the responsible parties, you should allow the subcontractor (and possibly the concrete supplier and other implicated parties) to examine, preserve, and/or test the work in question. Failure to do so may subject you to spoliation sanctions and jeopardize your right to recover damages. Read the court decision
Read the full story...
Reprinted courtesy of Curtis Martin, Peckar & Abramson
Mr. Martin may be contacted at cmartin@pecklaw.com

---

Serving Notice of Nonpayment Under Miller Act

January 20, 2020 — David Adelstein - Florida Construction Legal Updates
Under the federal Miller Act, if a claimant is NOT in privity with the prime contractor, it needs to serve a “notice of nonpayment” within 90 days of its final furnishing. In this manner, 40 U.S.C. 3133 (b)(2) states: A person having a direct contractual relationship with a subcontractor but no contractual relationship, express or implied, with the contractor furnishing the payment bond may bring a civil action on the payment bond on giving written notice to the contractor within 90 days from the date on which the person did or performed the last of the labor or furnished or supplied the last of the material for which the claim is made. The action must state with substantial accuracy the amount claimed and the name of the party to whom the material was furnished or supplied or for whom the labor was done or performed. The notice shall be served–

(A) by any means that provides written, third-party verification of delivery to the contractor at any place the contractor maintains an office or conducts business or at the contractor’s residence; or (B) in any manner in which the United States marshal of the district in which the public improvement is situated by law may serve summons.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Differing Site Conditions: What to Expect from the Court When You Encounter the Unexpected

September 05, 2022 — Margarita Kutsin - Ahlers Cressman & Sleight
[1]Seattle Tunnel Partners (“STP”), a joint venture of Dragados USA and Tutor Perini, entered into a $1.4 billion contract with the Washington State Department of Transportation (“WSDOT”) to replace the Highway 99 viaduct. In December 2013, a tunnel boring machine (“TBM”) bearing the moniker “Bertha,” then the largest TBM ever built, measuring 425 feet long and 57 feet in diameter, struck an underground pipe. Shortly after the impact, Bertha overheated and eventually could no longer make forward progress. A massive repair effort ensued causing a 2.5-year delay in reaching substantial completion. WSDOT sued STP for the delay, seeking liquidated damages of $57 million. In response, STP argued its delay was excusable because it was caused by Bertha’s impact with the pipe, and the steel well casing was a Differing Site Condition (DSC) undisclosed in the contract documents. STP asserted counterclaims against WSDOT, alleging breach of contract and seeking $300 million in damages. Ultimately, a jury found that the steel well casing on the pipe was not a DSC, foreclosing STP’s excusable delay defense and counterclaims, and resulting in a $57 million verdict, plus interest, in favor of WSDOT. Read the court decision
Read the full story...
Reprinted courtesy of Margarita Kutsin, Ahlers Cressman & Sleight
Ms. Kutsin may be contacted at margarita.kutsin@acslawyers.com

---

As Evidence Grows, Regions Prepare for Sea Level Rise

July 02, 2018 — Pam Radtke Russell - Engineering News Record
Cities, states and regions are taking steps to prepare their buildings, infrastructure and homes for the impacts of climate change as bad news continues to mount about rising sea levels. Read the court decision
Read the full story...
Reprinted courtesy of Pam Radtke Russell, ENR
Ms. Russell may be contacted at Russellp@bnpmedia.com

---

HHMR Lawyers Recognized by Best Lawyers

December 27, 2021 — David M. McLain – Colorado Construction Litigation
For over twenty years, Higgins, Hopkins, McLain & Roswell has embodied and exemplified the principles of service and stewardship. In everything we do, we focus on serving our clients selflessly and to the best of our ability. In doing so, we always have in the forefront of our minds our obligation to act as the stewards of our clients’ trust, confidences, and resources. The firm itself, along with Carin Ramirez (in the area of Litigation - Insurance), and Dave McLain (in the area of Construction) were all recognized in this year's edition of the U.S. News Best Lawyers Journal. We could not be more proud of the firm we have created, or the service we are able to provide to Colorado's construction industry and its insurers. Reprinted courtesy of David McLain, Higgins, Hopkins, McLain & Roswell Mr. McLain may be contacted at mclain@hhmrlaw.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

---

Georgia Amends Anti-Indemnity Statute

June 02, 2016 — David R. Cook Jr. – AHHC Construction Law Blog
In its most recent session, the Georgia General Assembly passed HB 943, which amends Georgia’s Anti-Indemnity Statute. The amendment expands the Anti-Indemnity Statute beyond construction contracts to include contracts for engineering, architectural, and land surveying services (“A/E Contracts”). In a prior post, we discussed Georgia’s Anti-Indemnity Statute, which generally prohibits indemnity clauses in construction contracts that require one party (the “Indemnitor”) to indemnify another party (the “Indemnitee”) if property damage or bodily injury results from the Indemnitee’s sole negligence. The prior post, discussed the Supreme Court of Georgia’s broad interpretation of the Anti-Indemnity Statute. HB 943 adds subpart (c), which states:

A covenant, promise, agreement, or understanding in or in connection with or collateral to a contract or agreement for engineering, architectural, or land surveying services purporting to require that one party to such contract or agreement shall indemnify, hold harmless, insure, or defend the other party to the contract or other named indemnitee, including its, his, or her officers, agents, or employees, against liability or claims for damages, losses, or expenses, including attorney fees, is against public policy and void and unenforceable, except for indemnification for damages, losses, or expenses to the extent caused by or resulting from the negligence, recklessness, or intentionally wrongful conduct of the indemnitor or other persons employed or utilized by the indemnitor in the performance of the contract. This subsection shall not affect any obligation under workers’ compensation or coverage or insurance specifically relating to workers’ compensation, nor shall this subsection apply to any requirement that one party to the contract purchase a project specific insurance policy or project specific policy endorsement.

(Emphasis added.) Read the court decision
Read the full story...
Reprinted courtesy of David R. Cook Jr., Autry, Hanrahan, Hall & Cook, LLP
Mr. Cook may be contacted at cook@ahclaw.com

---

Get Construction Defects in Writing

December 11, 2013 — CDJ STAFF
Sometimes, even if a developer is willing to make a repair, sometimes the repair doesn’t get to the actual problem, according to Nicholas D. Cowie of Cowie & Mott, writing on his blog. He notes that “getting it ‘right’ the first time is important and written documentation is key.” He gives the example of “when a developer agrees to informally repair a window or roof leak, the ‘repair,’ as far as the developer is concerned, may consist merely of sending out a worker with a caulk gun to seal gaps that should have been protected with a solid flashing material during the original installation.” As a better course, he says that homeowner associations should “request a written description of the proposed repair” in order that it can be evaluated. This also allows follow-up to determine if the agreed-upon repair was done properly. And, although some homeowners associations would rather not have the original subcontractor repair their own work, here warranties often come into play. Read the court decision
Read the full story...
Reprinted courtesy of

---

Alaska Supreme Court Finds Insurer Owes No Independent Duty to Injured Party

December 14, 2020 — Tred R. Eyerly - Insurance Law Hawaii
After the victim incurred injury inflicted by an insured party, the Alaska Supreme Court determined that the insurer owed no duty to the injured party. Martinez v. Government Employees Ins. Co., 2020 Alaska LEXIS 111 (Alaska Sept. 4, 2020). Joshua Martinez lost control of his truck and crashed into Charles Burnett's cabin. The cabin's heating fuel tank was damaged, and fuel drained onto the property and under the cabin. Burnett further alleged he suffered bodily injuries. Martinez was insured by GEICO under an auto policy. Two days after the accident, the state Department of Environmental Conservation (DEC) advised GEICO to hire a qualified environmental consultant and crew to clean up the fuel spill. Burnett told GEICO he wanted to do the cleanup himself and offered to do so for $25,000, the approximate amount of the consultant retained by GEICO. DEC did not consider Burnett qualified to handle the cleanup. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---