Seattle Washington Building Expert Directory

Arizona Court Affirms Homeowners’ Association’s Right to Sue Over Construction Defects

October 15, 2024 — Melissa Kenney - White and Williams LLP
In Gallery Community Association v. K. Hovnanian at Gallery LLC, No. 1 CA-CV 23-0375, 2024 Ariz. App. Unpub. LEXIS 696 (Ct. App.), the Court of Appeals of Arizona (Court of Appeals) discussed whether a homeowners’ association can file an action for breach of the implied warranty of workmanship and habitability arising from construction defects. At issue was whether the implied warranty extended to the areas within the community that the association maintained, including the common areas. The Court of Appeals held that homeowners’ associations can sue builder-vendors for breach of the implied warranty arising from construction defects. In this case, a homeowners’ association, responsible for managing and maintaining a community of townhomes, sued the developer/builder for alleged construction defects in the common area and exteriors of homes that the association maintained for the homeowners in the community. The alleged defects included the pool cabana and staircase walls in the common areas and the exterior walls, roofs, and staircases on the separately owned townhomes in the community. The builder filed a motion for summary judgment, arguing that the implied warranty extended to dwelling actions initiated by homeowners – not homeowners’ associations – and that the alleged construction defects at issue were not related to a dwelling. The trial court granted the motion. The Court of Appeals vacated the trial court’s grant of summary judgment and remanded for further proceedings. In reaching its decision, the Court of Appeals determined that both common law and statutory law authorized the homeowners’ association’s breach of implied warranty claim. Read the court decision
Read the full story...
Reprinted courtesy of Melissa Kenney, White and Williams
Ms. Kenney may be contacted at kenneyme@whiteandwilliams.com

Disappearing Data: Avoid Losing Electronic Information to Avoid Losing the Case

February 01, 2022 — Daniel C. Wennogle & Jennifer Knight Lang - Construction Executive
It happens: A contractor on a delayed project ends up in litigation over liquidated damages, but the key communications regarding delays and approvals were sent and received by the project manager on a mobile device using text messages and personal email accounts. Unfortunately, the project manager left the company a year ago on bad terms and has changed phones. The information that would serve to mitigate the contractor’s liability has disappeared. With better awareness and policies for capturing and managing electronic information, this is avoidable. Proactive and effective management of electronically stored information on construction projects can not only reduce costs and discovery disputes should litigation arise but can also provide critical evidence in reducing liability exposure in such disputes. The Federal Rules of Civil Procedure (as well as most state rules, which often mirror federal rules), provide for sanctions if a party fails to preserve electronically stored information (ESI) that should have been preserved in anticipation of litigation but is lost due to the failure to take reasonable steps to preserve it. Even in arbitration, where discovery and disclosure obligations are often more limited than in the court setting, preservation of ESI can help strengthen claims and defenses, avoiding accusations of spoliation that can derail a case. Arbitrators can also fashion appropriate sanctions for destruction of relevant evidence, not to mention the impact that apparent spoliation can have on a party’s credibility. Reprinted courtesy of Daniel C. Wennogle & Jennifer Knight Lang, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Ms. Lang may be contacted at jennifer.lang@moyewhite.com Mr. Wennogle may be contacted at daniel.wennogle@moyewhite.com Read the court decision
Read the full story...
Reprinted courtesy of

Warren Renews Criticism of Private Equity’s Role in Housing

February 01, 2022 — Akayla Gardner - Bloomberg
Senator Elizabeth Warren is doubling down on her criticism of private equity’s involvement in the U.S. housing market as the nation grapples with an affordable-housing shortage. In letters sent Thursday, the Massachusetts Democrat asked housing firms Progress Residential LLC, Invitation Homes Inc. and American Homes 4 Rent about recent rent hikes, plans to acquire more properties and the number of evictions in recent years. Warren and other Democrats have scrutinized Wall Street’s role in the housing market since the 2008 financial crisis. During the pandemic, lawmakers have been on high alert for violations of eviction moratoriums and unfair treatment as Americans struggled financially to stay on their feet. Warren also expressed concern about automated homebuying practices, which allow companies to buy up properties using algorithms. Bloomberg reported that last year Zillow offloaded thousands of homes to institutional investors. Read the court decision
Read the full story...
Reprinted courtesy of Akayla Gardner, Bloomberg

My Top 5 Innovations for Greater Efficiency, Sustainability & Quality

October 25, 2020 — Cristina Savian - AEC Business
As a construction professional and British citizen, I genuinely could not have been any prouder and humbled to have opened UK Construction Week Virtual last week. 2020 is the year of disruptions, and we are all looking for this “New Normal”, and while this newfound regularity may have opened new opportunities, as we are now broadcasting to a much wider audience than previous in-person events, and indeed we have to thank technology for that. For us construction professionals, this pandemic has put our industry further under pressure, however, it has also taught us something extremely important. The pandemic has shown the world how vital the construction industry is. The world cannot function without it. This new extraordinary experience has given us the prospect to turn our industry around and transform it into one of the most productive industries in our society. How are we going to do it? I think you can guess what I am about to say, of course by leveraging technology! The panel discussion with leading construction experts across the UK with representatives from Skanska UK, Bryden Wood, and Innovate UK, focused on our top 5 innovations for greater efficiency, sustainability and quality in construction. Here are my top 5. Read the court decision
Read the full story...
Reprinted courtesy of Cristina Savian, AEC Business

Damp Weather Not Good for Wood

May 10, 2013 — CDJ STAFF
Cold and wet weather was not bad news for the lumber industry. The weather in the first quarter set or tied records for both precipitation and low temperatures. Not good weather for building. Construction was delayed as a result, leading to less call for lumber. In response, there was a 15 percent drop in lumber futures, continuing a decline. Read the court decision
Read the full story...
Reprinted courtesy of

Pacing in Construction Scheduling Disputes

September 14, 2017 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway. However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

Performance Bond Primer: Need to Knows and Need to Dos

February 01, 2022 — Rafael Boza - Gravel2Gavel Construction & Real Estate Law Blog
If you are a construction contractor, you deal with performance bonds as part of your business and daily work. They are necessary for almost every project you are participating or will participate in, and, along with other sister bonds, constitute a basic tool to be able to work in construction. However, how much do you really know about this tool? Who in your organization knows how to use it? Are you relying on your insurance broker to procure the bonds? Can your broker competently review the terms of the bond? Are you, as a contractor, relying on the surety to explain and determine what you need for the project—a fox guarding the hen house? To understand how a performance bond works and how to effectively tailor it to your needs, we need to understand the basics. What is a performance bond? Who are the parties to a performance bond? What does performance bond not do? What should be covered under a performance bond? How does a performance bond fit in a company’s overall risk management processes? A clear understanding of these and other basic topics will facilitate operations and reduce the risk of claims. Read the court decision
Read the full story...
Reprinted courtesy of Rafael Boza, Pillsbury
Mr. Boza may be contacted at rafael.boza@pillsburylaw.com

New Law Impacting Florida’s Statute of Repose

June 29, 2017 — Meredith N. Reynolds & K. Stefan Chin – Peckar & Abramson, P.C.
On June 14, 2017, Governor Scott signed House Bill 377 into law, clarifying that Florida’s ten-year Statute of Repose commences either when the work is completed or when final payment becomes due, whichever is latest. The new law resolves a problem for contractors created by a recent Florida court ruling that held the Statute of Repose to commence as late as when the owner made final payment. The applicable amendments to Florida Statute Section 95.11 take effect on July 1, 2017 and apply to all causes of action that accrue on or after that date. Perhaps the most critical component of a construction professional’s risk management program is the length of time that it is liable for the work performed on a project. While contractual warranty periods typically run one or two years from substantial completion, the true length of a contractor’s post-completion obligation is measured by the “Statute of Repose,” which establishes the period of time following the completion of construction that a lawsuit can be filed for construction defects. Reprinted courtesy of Meredith N. Reynolds, Peckar & Abramson, P.C. and K. Stefan Chin, Peckar & Abramson, P.C. Ms. Reynolds may be contacted at mreynolds@pecklaw.com Mr. Chin may be contacted at kschin@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES