SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Waiving Consequential Damages—What Could Go Wrong?

March 19, 2024 — Curtis W. Martin & Kellie M. Ros - Peckar & Abramson, P.C.
You are inexcusably late with construction of a football stadium, a casino, or similar project that generates large income for the owner. The indirect damages, often referred to as consequential damages, that flow from the delay can be astronomical to the point of breaking your company if it must pay them. As a result, many construction contracts, at every tier, contain a provision that waives consequential damages. By this waiver, a party seeks to limit its risk for these damages. Over the years, courts have interpreted these provisions in a widely variable and inconsistent manner. The courts typically start with the specific language of the waiver to discern the parties’ intent. Thus, the language of the provision itself is critical. But construction professionals should not overlook other provisions in the contract that may have an impact on a court’s analysis of the parties’ intent. As one of my colleagues likes to say, “the large print giveth and the small print taketh away.” Reprinted courtesy of Curtis W. Martin, Peckar & Abramson, P.C. and Kellie M. Ros, Peckar & Abramson, P.C. Mr. Martin may be contacted at cmartin@pecklaw.com Ms. Ros may be contacted at kros@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Unfinished Building Projects Litter Miami

November 18, 2011 — CDJ STAFF

Buildings born in ambitious development plans that were never brought to completion form a grim reminder of the building bust in Miami, according to an article in the Miami Herald. One project started in 2007 as a residential project, later there were hopes to develop it as a hotel. These plans are ten months old with no work done.

Another project was projected as a 30-story office and commercial tower. Four were built before the project was abandoned. The article describes the site as “squalid.” Another project completed the planned 17 stories, but no work has been done beyond constructing the shell. Once planned as luxury condos, the owner owes more than $30,000 in property taxes.

Each of the three sites profiled in the Miami Herald have become dumping grounds for trash. The building skeletons have also become damaged by the elements. Some abandoned projects have been taken over by homeless people. Businesses near the abandoned properties have been hurt. The buildings also represent failed obligations to subcontractors who have put liens on the properties for work they performed but were never paid for.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

---

Mexico's Richest Man Carlos Slim to Rebuild Collapsed Subway Line

November 01, 2021 — The Associated Press - Bloomberg
Mexico City (AP) -- Mexico’s richest man reached an agreement with Mexico City authorities Wednesday to rebuild or reinforce an elevated subway line that collapsed in May, killing 26 people. Telecom and construction magnate Carlos Slim said his Grupo Carso’s construction subsidiary would pay the cost of rebuilding the span that collapsed, and reinforcing other parts of the elevated line to meet higher standards in a city plagued with severe earthquakes. Grupo Carso said in a statement to the country’s stock market that the outlay did not constitute any admission of responsibility for the collapse, and would not “materially affect” the company’s business. Read the court decision
Read the full story...
Reprinted courtesy of Bloomberg

---

Think Before you Execute that Release – the Language in the Release Matters!

June 17, 2024 — David Adelstein - Florida Construction Legal Updates
If you execute a release in exchange for payment or other consideration, remember the language in the release means something. THE RELEASE LANGUAGE MATTERS! And the meaning in the release may be way more than you intended so please make sure you truly digest and consider release language before executing. This sentiment could not be truer than in the 2009 decision Bell BCI Company v. United States, 570 F.3d 1337 (Fed. Cir. 2009). In this case, a contractor entered into a modification (change order) with the government. The modification included the following language: increase the contract amount by $2,296,963 … as full and equitable adjustment for the remaining direct and indirect costs of the Floor 4 Fit-out (EWO 240–R1) and full and equitable adjustment for all delays resulting from any and all Government changes transmitted to the Contractor on or before August 31, 2000. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

With VA Mechanic’s Liens Sometimes “Substantial Compliance” is Enough (but don’t count on it) [UPDATE]

October 14, 2019 — Christopher G. Hill - Construction Law Musings
Virginia mechanic’s liens are a powerful and tricky beast that in most cases require absolute precision in their preparation. However, an interesting opinion recently came out of the Virginia Supreme Court that may provide a bit of a “safe harbor” from the total form over function nature of a mechanic’s lien. In Desai, Executrix v. A.R. Design Group Inc., the Court considered a lien memorandum that had what could be described as technical flaws in the preparation of the mechanic’s lien by A. R. Design Group. The basic facts are that A. R. Design Group used the form of lien found in Va. Code Sec. 43-5 (also found as Form CC-1512 at the Virginia Judiciary website) when it recorded two lien memoranda for two pieces of property owned by a trust. Relating to one of the two properties, the memorandum failed to identify the “Owner” as the trustee of the trust. On the memoranda relating to both properties the affidavit verifying the amounts claimed did not identify the signatory as agent for A. R. Design Group, instead listing the agent as the claimant and further failed to state a date from which interest is claimed or a date on which the debt was due. Needless to say, the owner argued that each of these technical defects invalidated the memoranda and therefore they should have been released. Somewhat surprisingly the Fairfax, Virginia Circuit Court disagreed and held the liens to be valid. On appeal, the Virginia Supreme Court affirmed the lower court. The held that the failure to add the word “Trustee” after Ulka Desai’s name did not invalidate the lien because the trustee had all of the rights of ownership and furthermore that naming Desai in the memorandum served the purpose of putting third parties on notice of the lien. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

---

Dave McLain named Barrister’s Best Construction Defects Lawyer for Defendants for 2019

January 20, 2020 — David M. McLain – Colorado Construction Litigation
The attorneys and staff at Higgins, Hopkins, McLain & Roswell are proud to announce that Law Week Colorado named Founding Member Dave McLain as the 2019 People’s Choice for Best Construction Defects Lawyer for Defendants. According to the publication:

Law Week Colorado asked its readership to weigh in on the best attorneys in just about every practice area we could think of. We received hundreds of responses and sifted through the votes for each category to determine the “People’s Choice” winner – the top attorney in each practice area according to other attorneys. And then we handed it to the “Barrister” (the hive mind of Law Week staff, supplemented by public votes and a healthy dose of additional research) to determine the Barrister’s Choice.

In recognizing Mr. McLain this year, Law Week Colorado stated:

Previously appearing in Law Week’s 2015 Barrister’s Best issue [in which he was recognized as the Barrister’s Choice as Best Construction Defects Lawyer for Defendants], David McLain participates in numerous speaking engagements on construction defects claims and is seen as a leader in the field. His extensive experience over the last two decades of practice speaks for itself.

Read the court decision
Read the full story...
Reprinted courtesy of David McLain, Higgins, Hopkins, McLain & Roswell
Mr. McLain may be contacted at mclain@hhmrlaw.com

---

Appetite for Deconstruction

July 02, 2024 — Patrick Sisson - Bloomberg
The death of 206 College Avenue was slow and painstaking. Over several days in January 2022, dozens of bundled-up volunteers swarmed over the three-story property, a tired wooden boarding house built in the early 1900s in Ithaca, New York. Long used as rental apartments for Cornell University students, the 13-bedroom house was set to be demolished, along with several neighboring structures of the same vintage, to make room for a new multi-use complex. But while those buildings were quickly reduced to rubble by trackhoes, the house at 206 was deconstructed, piece by piece, so that its elements could be used again. The Catherine Commons Deconstruction Project, an effort by Cornell’s Circular Construction Lab, was a large-scale pilot designed to show how building waste can be kept out of landfills. As volunteers pulled nails out of fir, oak, and walnut boards and hauled lumber off to be sorted and redistributed, a team of eight workers with heavy machinery began meticulously sawing, slicing and removing 8-by-18-foot panels of the old building. These were trucked off to a warehouse, where they’d be taken apart and recycled. The labor that went into this process was substantially more than a typical demolition. But it avoided the societal penalties left behind at nearly every building and demo site across the US. The sheer volume of waste generated by knocking down, adding to or renovating buildings in the US is stunning: 600 million tons of construction demolition waste annually, according to the most recent EPA estimate from 2018. Roughly 75% gets ground up into aggregate and fill, and only a small share is recycled and reused, necessitating production of new material for the next project. For scale, municipal solid waste only accounts for 300 million tons every year. Read the court decision
Read the full story...
Reprinted courtesy of Patrick Sisson, Bloomberg

---

Beware of Statutory Limits on Change Orders

February 18, 2015 — Craig Martin – Construction Contractor Advisor
While change orders are always part of construction projects, it’s important to know whether a public agency is limited on how much it can increase the scope of the work through change orders. A contractor in Virginia found out the hard way that the state agency did not have the authority to increase the scope of the project and thus the contractor could not collect for the extra work. In Carnell Construction Corp. v. Danville Redevelopment & Housing Authority, the contractor was hired by the housing authority to prepare a site for construction. The project did not go well and both sides blamed the other for delays and increased costs. After being removed from the project, the contractor sued the housing authority for, among other things, breach of contract. The jury awarded the contractor a total of $915,000 for the housing authority’s failure to pay for extra work and improper removal. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

---