Fairfield Connecticut Building Expert Directory

Pacing in Construction Scheduling Disputes

September 14, 2017 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway. However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

Jobsite Safety Should Be Every Contractors' Priority

December 09, 2019 — Ray Reese - Construction Executive
Any general contractor understands the range of factors that go into building and sustaining a successful jobsite: hiring the right team, maintaining cutting-edge equipment, ensuring constant communication with clients and effectively leveraging the newest building technologies, just to name a few. But any good general contractor understands that there is one factor that should always be considered as top priority: jobsite safety. The health and wellbeing of a project’s team is paramount for obvious reasons, and it isn’t a lighthearted matter. Injuries and fatalities have too often been a piece of our industry’s story. In 2017 alone, there were 971 reported deaths on construction sites, which accounted for 20% of total worker fatalities, according to a report from the Occupational Safety and Health Administration. Of these 971 fatalities, 582 were the result of construction’s “fatal four”—falls, workers being struck by objects, electrocutions and workers being caught between equipment. For members of the industry, these are difficult numbers to read and to process; yet, it is extremely important to consider the injuries and lives lost when we take into consideration the seriousness of jobsite safety. Often, general contractors’ and superintendents’ greatest challenge isn’t being convinced of the necessity of jobsite safety practices in protecting employees or the value of safety in creating a productive work environment. Instead, the focus should be providing industry leaders tips on exactly how to improve safety measures on their own jobsites. Understanding that safety is everyone’s responsibility is paramount. Reprinted courtesy of Ray Reese, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Reese may be contacted at rreese@rives.com

Real Estate & Construction News Roundup (6/18/24) – Cannabis’ Effect on Real Estate, AI’s Capabilities for Fund Managers and CRE’s Exposure on Large Banks

July 15, 2024 — Pillsbury's Construction & Real Estate Law Team - Gravel2Gavel Construction & Real Estate Law Blog
In our latest roundup, hotel-to-apartment conversions take big leap, state governments pass squatting legislation, US regional banks risk having debt ratings downgraded, and more!

Reclassifying cannabis as a lower-risk substance could bring significant changes to the real estate sector associated with cannabis. (Margaret Jackson, Yahoo)
More than 60 of the largest banks in the country are at increased risk of failure due to their commercial real estate (CRE) exposures. (Florida Atlantic University).
As extreme weather grows in frequency and intensity, the nation’s patchwork of building codes have not kept up with modern conditions and if something goes wrong, contractors are not off the hook if they simply build to code. (Julie Strupp, Construction Dive)

Read the court decision
Read the full story...
Reprinted courtesy of Pillsbury's Construction & Real Estate Law Team

Palo Alto Considers Fines for Stalled Construction Projects

November 20, 2013 — CDJ STAFF
The city of Palo Alto, California is considering adopting a law that would fine residents with expired building permits. The City Council took up the issue in response to complaints from residents about stalled construction projects in their neighborhoods. In the public testimony, one resident noted that a site near her home was fenced off in 2007, with the home demolished in 2008, after which nothing has happened. The City Council is proposing fines of $200 per day, after a 30-day grace period, increasing to $400 per day two months after that, going to $800 per day on the 121st day. Read the court decision
Read the full story...
Reprinted courtesy of

Unesco Denies Claim It Cleared Construction of Zambezi Dam

November 06, 2023 — Antony Sguazzin - Bloomberg
Unesco denied that it cleared Zimbabwe and Zambia to proceed with the construction of a $5 billion hydropower dam downstream from the Victoria Falls, which it has designated as a World Heritage Site. Munyaradzi Munodawafa, chief executive officer of the Zambezi River Authority, said in an earlier interview that Unesco’s World Heritage Committee “agreed that Batoka could go ahead,” referring to the planned dam and 2,400-megawatt power plant on the Zambezi River. Munodawafa didn’t answer calls or text messages to his mobile phone. “The decision taken by the committee raises several concerns regarding the site, including the inevitable negative impacts of the Batoka Gorge” project, Unesco said in a response to queries. Read the court decision
Read the full story...
Reprinted courtesy of Antony Sguazzin, Bloomberg

The EPA’s Renovation, Repair, and Painting Rule: Are Contractors Aware of It?

March 12, 2015 — Beverley BevenFlorez-CDJ STAFF
Remodeling Magazine reported recently that some remodelers are unaware of the U.S. Environmental Protection Agency’s (EPA) Renovation, Repair and Painting (RRP) rule despite that it took effect back in April of 2010. “There are still quite a few remodelers who have never heard of RRP,” Mark Schlager, president of Access Training Services, an EPA and Occupational Safety and Health Administration (OSHA) trainer in Pennsauken, N.J. told Remodeling Magazine. According to the article, “The RRP rule applies to homes, apartments, and child-occupied commercial facilities built before 1978.” There are two RRP certifications required on every job: “a “Firm” certification for the company that contracts to do the work, and a “Renovator” certification for the person overseeing the work. A solo operator needs both certifications, which are good for five years.” Read the court decision
Read the full story...
Reprinted courtesy of

Arctic Fires Are Melting Permafrost That Keeps Carbon Underground

December 27, 2021 — Eric Roston - Bloomberg
Few things signal something's gone haywire on the planet quite like frozen land on fire. Now scientists have determined that Arctic fires, even milder ones, can reshape a landscape for decades, in ways that may make it even harder to keep global heating from eclipsing international goals. It's mostly rising temperatures that are thawing out frozen Arctic ground but northern blazes — already increasing — are now understood to play a disproportionate role, according to a study published last week in the journal One Earth. Previous research has shown that higher temperatures, drier soil and more lightning storms will lead to more fires. That work, with the new paper, mean that “in the future we might expect to see an outsized influence on thaw from the fires that will likely increase," said Róisín Commane, a Columbia University assistant professor who studies atmospheric composition and wasn’t involved in the new study. Read the court decision
Read the full story...
Reprinted courtesy of Eric Roston, Bloomberg

What You Need to Know to Protect the Project Against Defect Claims

October 28, 2024 — Scott L. Baker - Los Angeles Litigation Blog
If a property owner claims there is a construction defect, that not only brings the project’s integrity into question but also your business’s reputation. So, how can you take steps to prevent these claims from causing such damage? Here are three things to know before beginning a project to effectively protect it and manage construction defect claims. 1. Documentation is key California and Los Angeles County require certain permits and documents in order for a construction project to move forward. Los Angeles County will also conduct plan checks to ensure everything is up to code. Detailed documentation will be important while making your plans. However, keeping notes throughout every step of the project will also be essential. Documenting all aspects of the project helps you:

Stay updated and aware of the project’s progress
Proactively catch and handle issues that could result in disputes
Create a record of evidence that can help manage defect claims

Read the court decision
Read the full story...
Reprinted courtesy of Scott L. Baker, Baker & Associates
Mr. Baker may be contacted at slb@bakerslaw.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES