Green Investigations Are Here: U.S. Department of Justice Turns Towards Environmental Enforcement Actions, Deprioritizes Compliance Assistance
January 10, 2022 —
Karen C. Bennett, R. Morgan Salisbury, Sean P. Shecter & Rose Quam-Wickham - Lewis BrisboisWashington, D.C. (January 4, 2022) - Two high-ranking Department of Justice (DOJ) officials announced that the Biden Administration is prioritizing environmental regulatory enforcement over compliance assistance. Todd Kim, Assistant Attorney General for the DOJ’s Environment and Natural Resources Division (ENRD), and Deborah Harris of the DOJ’s Environmental Crimes Section, indicated in mid-December 2021 that companies and individuals should expect more “vigorous enforcement,” with an emphasis on criminal enforcement. This new policy is in contrast to the Environmental Protection Agency’s (EPA) Office of Enforcement and Compliance Assurance (OECA)'s previous emphasis on compliance and pollution mitigation instead of enforcement actions under the prior administration.
DOJ’s new policy of promoting enforcement actions is consistent with the Biden Administration’s overall efforts to prioritize environmental justice. In April 2021, as explained in a previous Lewis Brisbois Client Alert, OECA released two memoranda directing enforcement teams to consider a variety of tools to resolve enforcement actions, including increased inspections, restitution, and reparation for victims of environmental crimes and overstepping state regulators where necessary.
Reprinted courtesy of
Karen C. Bennett, Lewis Brisbois,
R. Morgan Salisbury, Lewis Brisbois,
Sean P. Shecter, Lewis Brisbois and
Rose Quam-Wickham, Lewis Brisbois
Ms. Bennett may be contacted at Karen.Bennett@lewisbrisbois.com
Mr. Salisbury may be contacted at Morgan.Salisbury@lewisbrisbois.com
Mr. Shecter may be contacted at Sean.Shecter@lewisbrisbois.com
Ms. Quam-Wickham may be contacted at Rose.QuamWickham@lewisbrisbois.com
Read the court decisionRead the full story...Reprinted courtesy of
Montana Theater Threatened by Closure due to Building Safety
January 14, 2015 —
Beverley BevenFlorez-CDJ STAFFPhil Henderson, owner of Stevensville Hardware which is adjacent to the theater, has sued the Stevensville Playhouse, alleging that one of the theater building’s walls leans over into his property, according to the Bitterroot Star. Henderson stated that the leaning wall is interfering with construction plan, and he also alleges that the building is not safe and should be condemned.
A building inspector hired by Henderson declared that “…it seems necessary to notify the Stevensville Playhouse that their structure is to be immediately considered unsafe for entry, occupancy, etc.” However, another engineering firm presented a different view on the situation: “The playhouse has withstood many snow storms and earthquakes during its life and will likely continue to function well into the future. We do not mean to downplay the need to perform the recommended repairs, but we do not feel that the building needs to be condemned at this point.”
Read the court decisionRead the full story...Reprinted courtesy of
Nevada’s Home Building Industry can Breathe Easier: No Action on SB250 Leaves Current Attorney’s Fees Provision Intact
June 21, 2017 —
Aaron Lovaas – Newmeyer & Dillion LLPConstruction and design professionals in Nevada’s home building industry breathed a collective sigh of relief on June 5, 2017 when the 79th Session of the Nevada Legislature adjourned without entertaining Senate Bill 250, which sought to reinstate homeowner plaintiffs’ nearly automatic right to recover attorneys’ fees, expert costs, and costs of investigation when bringing suit for alleged constructional defects.
Until 2015, homeowners’ recovery of such damages was the reality of the construction defect landscape in Nevada. While Chapter 40 of the Nevada Revised Statutes specifically allowed for recovery of “reasonable” attorneys’ fees, expert costs, and costs of investigation, the trend in Nevada was that plaintiffs were all but guaranteed awards of all such sums. Of course, this environment incentivized plaintiffs’ lawyers to bring claims of questionable or little repair value in cases where the attorney’s fees and expert costs often far exceeded the costs of repair.
HOW AB125 CHANGED THE LANDSCAPE
Such was the reality in Nevada until 2015 and the passage of Assembly Bill 125, which eliminated the nearly automatic award of attorneys’ fees and expert costs and overhauled Chapter 40 in many other respects. AB125 made over portions of Chapter 40 by:
- Placing awards of attorneys’ fees into the framework of offers of judgment, utilized extensively in other fields of civil litigation and available equally to homeowner plaintiffs as well as construction industry defendants; and
- Reworking expert costs and costs of investigation to allow for the award of those items only in the case of proven defects and only as to those costs directly related to the investigation and proof of those defects.
INTRODUCING SB250
The 2017 Legislative Session saw efforts to return Chapter 40 to its pre-2015 version through the introduction of SB250. Fortunately for construction and design professionals in the home building industry in Nevada, the State Senate Judiciary Committee did not act upon the bill and the effort died having never made it to a floor vote. Considering that Nevada’s Legislature meets biannually, the current framework of Chapter 40 is intact until at least 2019. The 2017 Legislative Session, however, is an illustration to how quickly those of the construction defect plaintiffs’ bar can move to initiate efforts to turn back the clock to a much riskier time for construction and design professionals.
Those in the industry should remain vigilant and monitor future legislative efforts to reinstate such awards or other clearly anti-builder measures. Such measures simply drive-up the overall cost and expense of home construction and, in turn, home ownership, which it is often said, is one of the cornerstones of the American dream.
Aaron Lovaas is a partner in the Las Vegas office of Newmeyer & Dillion. As a transactional attorney and business litigator, Aaron has the ability to evaluate legal issues from both points of view and help his clients understand their best option. He can be reached at aaron.lovaas@ndlf.com.
About Newmeyer & Dillion
For more than 30 years, Newmeyer & Dillion has delivered creative and outstanding legal solutions and trial results for a wide array of clients. With over 70 attorneys practicing in all aspects of business, employment, real estate, construction and insurance law, Newmeyer & Dillion delivers legal services tailored to meet each client’s needs. Headquartered in Newport Beach, California, with offices in Walnut Creek, California and Las Vegas, Nevada, Newmeyer & Dillion attorneys are recognized by The Best Lawyers in America©, and Super Lawyers as top tier and some of the best lawyers in California, and have been given Martindale-Hubbell Peer Review's AV Preeminent® highest rating. For additional information, call 949-854-7000 or visit www.ndlf.com.
Read the court decisionRead the full story...Reprinted courtesy of
Previously Owned U.S. Home Sales Rise to Eight-Month High
July 23, 2014 —
Victoria Stilwell – BloombergSales (ETSLTOTL) of previously owned U.S. homes climbed in June to an eight-month high as more listings helped prices cool, luring buyers into the market.
Sales increased 2.6 percent to a 5.04 million annual rate last month, led by gains in all four U.S. regions, figures from the National Association of Realtors showed today in Washington. The median forecast of 78 economists surveyed by Bloomberg projected sales would rise to a 4.99 million rate. Prices advanced at the slowest pace since March 2012 and inventories rose to an almost two-year high.
Historically low interest rates and smaller price increases are helping bring homeownership within reach for more Americans. A pickup in employment opportunities that lead to faster wage growth would provide an added spark for a residential real-estate market that began to soften in the middle of 2013.
Read the court decisionRead the full story...Reprinted courtesy of
Victoria Stilwell, BloombergMs. Stilwell may be contacted at
vstilwell1@bloomberg.net
Standard For Evaluating Delay – Directly from An Armed Services Board Of Contract Appeal’s Opinion
October 04, 2021 —
David Adelstein - Florida Construction Legal UpdatesSometimes, it is much better to hear it from the horse’s mouth. That is the case here. The Armed Services Board of Contract Appeal’s (ASBCA) opinion in Appeals of -GSC Construction, Inc., ASBCA No. 59402, 2020 WL 8148687 (ASBCA November 4, 2020) includes an informative discussion of a contractor’s burden when it encounters excusable delay and, of importance, the standard for evaluating delay. It’s a long discussion but one that parties in construction need to know, appreciate, and understand. EVERY WORD IN THIS DISCUSSION MATTERS.
Construction projects get delayed and with a delay comes money because time is money. Many claims are predicated on delay. These can be an owner assessing liquidated damages due to a delayed job or a contractor seeking its costs for delay. Either way, the standard for evaluating delay and the burdens imposed on a party cannot be understated and, certainly, cannot be overlooked. For this reason, here is the discussion on evaluating delay directly from the horse’s mouth in the Appeal of-GSC Construction, Inc.:
The critical path is the longest path in the schedule on which any delay or disruption would cause a day-for-day delay to the project itself; those activities must be performed as they are scheduled and timely in order for the project to finish on time. Wilner v. United States, 23 Cl. Ct. 241, 245 (1991). In Yates-Desbuild Joint Venture, CBCA No. 3350 et al., 17-1 BCA ¶ 36,870, our sister board compiled an excellent and very helpful synopsis of the standards for evaluating delay claims, which I adopt nearly verbatim among the discussion that follows.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Business Risk Exclusions Do Not Preclude Coverage
November 13, 2013 —
Tred Eyerly — Insurance Law HawaiiThe court rejected the insurer's arguments that the business risk exclusions barred coverage for a contractor. Gen. Cas. Co. of Wisconsin v. Five Star Bldg. Corp., 2013 U.S. Dist. LEXIS 134122 (D. Mass. Sept. 19, 2013).
Five Star was hired by the University of Massachusetts to upgrade the ventilation (HVAC) system on a portion of a building. The large majority of the work involved work in the interior of the building, but a small portion required installation of duct work and supports on top of the roof of the complex. Five Star also penetrated the roof at numerous locations to install supports for duct work and other rooftop structures for the ventilation system. Other subcontractors then secured supports to the concrete roof deck and installed permanent patches where Five Star had penetrated the roofing system.
On same days, Five Star could not accomplish the process in a single day after penetrating the roof. It would install temporary patches until the next day. This was the only work on the roof performed by Five Star.
Read the court decisionRead the full story...Reprinted courtesy of
Tred EyerlyTred Eyerly can be contacted at
te@hawaiilawyer.com
How Mansions Can Intensify Wildfires
May 30, 2022 —
Todd Woody - BloombergA neighborhood of $4 million homes that burned Wednesday in a Southern California wildfire highlights the vulnerability of large suburban dwellings to climate-driven blazes, according to fire experts.
The Coastal Fire destroyed at least 20 homes in a gated community in Laguna Niguel, a wealthy Orange County enclave near Laguna Beach. Houses in the Coronado Pointe development line a ridge overlooking the Pacific Ocean. Homes in the neighborhood are palatial, ranging in size from about 4,000 square feet to 10,000 square feet, and sit on large lots with room for swimming pools with coastal views. But the mansions are wedged together with relatively little space between buildings.
When a fire broke out near a wastewater treatment plant on Wednesday, it raced up a chaparral-covered hillside until it encountered an explosive source of fuel – Coronado Pointe.
Read the court decisionRead the full story...Reprinted courtesy of
Todd Woody, Bloomberg
A Homeowner’s Subsequent Action is Barred as a Matter of Law by way of a Prior “Right to Repair Act” Claim Resolved by Cash Settlement for Waiver of all Known or Unknown Claims
February 26, 2015 —
Richard H. Glucksman, Esq., Jon A. Turigliatto, Esq., and David A. Napper, Esq. – Chapman Glucksman Dean Roeb & Barger BulletinDavid Belasco v. Gary Loren Wells et al. (2015) B254525
OVERVIEW
In a decision published on February 17, 2015, the Second District Court of Appeal made clear that settlement agreements containing waivers of unknown claims in connection with a construction of a property, absent fraud or misrepresentation, will be upheld. In brief, the homeowner plaintiff had made a claim against the builder pursuant to California Code of Civil Procedure Section 896 (“Right to Repair”) and settled for a cash payment and obtained a Release of all Claims including for all known and unknown claims. The court held that homeowner’s subsequent construction defect claim was barred pursuant to the terms and conditions of the earlier release.
DISCUSSION
Plaintiff and Appellant, David Belasco ("Belasco"), purchased a newly construction home in Manhattan Beach from builder Gary Loren Wells ("Wells"). Two years after purchasing the property, Belasco filed a Complaint for construction defects, which eventually resulted in settlement between the parties. The settlement agreement included a California Civil Code Section 1524 waiver of all known or unknown claims with the word "claims" defined in part as “any and all known and unknown construction defects." Six years later in 2012, Belasco filed a Complaint alleging a claim, amongst others, that the defective and leaky roof breached the statutory warranty on new construction under California Civil Code section 896 ("Right to Repair Act").
Relying on San Diego Hospice v. County of San Diego (1995) 31 Cal.App.4th 1048, Wells and Wells' surety, American Contractors Indemnity Company (collectively "Wells"), filed a motion for summary judgment contending that the 2012 action was barred by the settlement of Belasco’s prior Complaint against Wells for construction defects to his home. When the trial court ruled in favor of Wells, Belasco appealed. Belasco, a patent attorney, made the following contentions:(1) the general release and section 1542 wavier in the settlement agreement for patent construction defects is not a "reasonable release" of a subsequent claim for latent construction defects within the meaning of section 929 and the “Right to Repair” Act; (2) a reasonable release can only apply to a "particular violation" and not to a latest defect under the language of section945.5, subdivision (f), and the settlement was too vague to be valid because it does not reference a "particular violation;" (3) section 932 of the California Civil Code specifically authorizes an action on "[s]subsequently discovered claims of unmet standards;" (4) public policy prohibits use of a general release and section 1542 waiver to bar a subsequent claim for latent residential construction defects; and (5) a genuine issue of material fact exists concerning Belasco's fraud and negligence claims that would have voided the settlement pursuant to section 1668.
Pursuant to the "Right to Repair Act" Section 929 subsection (a), a builder can make a cash offer in lieu of a repair and the homeowner is free to accept or reject such offer. Section 929subsection (b) goes on to state that
"[t]he builder may obtain a reasonable release in exchange for the cash payment. The builder may negotiate the terms and conditions of any reasonable release in terms of scope and consideration in conjunction with a cash payment under this chapter."
The Second District Court of Appeal ruled that the prior cash settlement, with a release and section 1524 wavier, was a "reasonable release" under the language of California Civil Code Section 929.
On multiple occasions, the Court noted that Belasco is an attorney and was represented by an attorney during the negotiation of the settlement agreement. By executing the agreement with express language regarding what claims were to be release, Belasco released Wells of "any and all claims" due to "any and all known and unknown construction defects." The Court reasoned that because Belasco is an attorney in his own right, he should have understood the import of the Section 1542 waiver and had the opportunity to reject or revise the settlement agreement prior to binding himself to it. The Court further found that the agreement "could not have been more clear" regarding the waiver of all unknown and known construction defect claims and therefore was not vague. Belasco's additional contentions were found to be without merit because Belasco availed himself of the statutory remedy of a cash settlement in lieu of repairs and voluntarily entered into a negotiated settlement agreement. Lastly, Belasco failed to present any evidence regarding his misrepresentation claim.
When a homeowner files a "Right to Repair Act" claim, often it seems that only two options exist: either repair the alleged defects or go to court. However, Belasco is a reminder to builders that the "Right to Repair Act" does offer an avenue for settlement. The Second District Court of Appeal presented a clear, unqualified opinion regarding the validity and enforceability of settlement agreements releasing all known or unknown construction defects in a single family home case. The Court will hold parties to the settlements they agree to. This is especially so when one of the parties is an attorney and provides deposition testimony expressly acknowledging that he understood the scope of the agreement. Attorneys for builders should always include a waiver of all known and unknown claims, which pursuant to Belasco and San Diego Hospice, will ensure that any future claims at the property will be effectively barred by the terms of the settlement agreement.
Reprinted courtesy of Chapman Glucksman Dean Roeb & Barger attorneys
Richard H. Glucksman,
Jon A. Turigliatto and
David A. Napper
Mr. Glucksman may be contacted at rglucksman@cgdrblaw.com
Mr. Turigliatto may be contacted at jturigliatto@cgdrblaw.com
Mr. Napper may be contacted at dnapper@cgdrblaw.com
Read the court decisionRead the full story...Reprinted courtesy of
