Second Circuit Affirms Win for General Contractor on No Damages for Delay Provision
September 02, 2024 —
Bill Wilson - Construction Law ZoneIn NASDI, LLC v. Skanska Koch Inc. Kiewit Infrastructure Co. (JV), 2024 WL 1270188 (2d Cir. Mar. 26, 2024), the U.S. Court of Appeals for the Second Circuit affirmed the District Court’s grant of summary judgment dismissing a subcontractor’s delay claim against a general contractor on a public project in New York state. The Court enforced a typical no-damages-for-delay provision to bar the subcontractor’s breach of contract claim. The no-damages-for-delay provision in the subcontract at issue provided:
NO DAMAGE FOR DELAY. Except as otherwise provided …, Subcontractor agrees that it shall have no Claim against Contractor for any loss or damage it may sustain through delay, disruption, suspension, stoppage, interference, interruption, compression, or acceleration of Subcontractor’s Work (‘Delay Damages’) caused or directed by Contractor for any reason, and that all such Claims shall be fully compensated for by Contractor’s granting Subcontractor such time extensions as it is entitled to as a result of any of the foregoing.
Read the court decisionRead the full story...Reprinted courtesy of
Bill Wilson, Robinson & Cole LLPMr. Wilson may be contacted at
wwilson@rc.com
Construction Contract Provisions that Should Pique Your Interest
September 30, 2019 —
Christopher G. Hill - Construction Law MusingsConstruction contracts are a big part of my legal practice and the drumbeat here at Construction Law Musings. Why? Because not only does your construction contract set the expectations and “rules of the game” for a construction project, it will be read strictly and literally by the Virginia courts should there be a dispute. For these reasons, construction professionals need to be alert for the language in certain key clauses in a construction contract to assure that these clauses are as balanced as possible and also well understood. Here are my “Top Five”:
- “Pay if Paid”- These clauses are almost always in the subcontracts between a general contractor and a subcontractor and are enforceable in Virginia if drafted correctly and under the proper circumstances.
- Change Orders- Whether work is subject to a change order and the required payment for any changed work are often a key source of contention (read legal fees). A properly drafted and followed change order provision can help avoid much of this contention.
- Indemnity- Much has been made in recent years about indemnity provisions and their enforceability. All parties in the construction payment chain can and should be aware of how to best draft their indemnity provisions to make them enforceable. Failure to do so can be catastrophic.
Read the court decisionRead the full story...Reprinted courtesy of
The Law Office of Christopher G. HillMr. Hill may be contacted at
chrisghill@constructionlawva.com
3D Printing Innovations Enhance Building Safety
October 07, 2019 —
Mahmut Ekenel & Melissa Sanchez - Construction ExecutiveThe mention of 3D printing alone is enough to get people excited, often conjuring images of a desktop console that can download and create three dimensional objects such as prototypes, or mechanical parts. And yet, in recent years the technology has given way to a slight impatience, as people begin to wonder how and when it will have a direct impact on both their lifestyles and their businesses.
The construction industry has been quick to take advantage of these innovations, and the effects are tangible, especially regarding building safety. The 3D construction technology allows for several key advantages in terms of faster construction times, uncompromised quality of construction and lower costs—allowing for affordable dwellings to be quickly built for people in need.
These advantages also lead to safety improvements during the building process. The ability to accelerate construction time without requiring an increase in labor results in a fewer construction-related workplace injuries and a reduction in material waste, making it an environmentally friendly construction method as well.
ICC-Evaluation Service (ICC-ES), a subsidiary of the International Code Council (ICC) which develops model codes and standards (i.e. International Building Code, International Residential Code) and delivers a wide array of building safety services, has taken the lead on developing acceptance criteria to address building code compliance of 3D printed construction. Currently, 3D construction technology is not within the provisions of the International Building Code (IBC) or International Residential Code (IRC). The acceptance criteria introduces new compliance measures for interior and exterior 3D printed concrete walls (with and without structural steel reinforcement), load-bearing and non-load-bearing walls, and shear walls in one-story, single-unit, residential dwellings. The 3D walls are constructed by printing two outer layers of 3D concrete and then filling the core with 3D concrete to form a solid wall.
Reprinted courtesy of
Mahmut Ekenel & Melissa Sanchez, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved.
Mr. Ekenel may be contacted at mekenel@icc-es.org
Ms. Sanchez may be contacted at msanchez@icc-es.org
Read the court decisionRead the full story...Reprinted courtesy of
Boston Team Secures Summary Judgment Dismissal on Client’s Behalf in Serious Personal Injury Case
October 21, 2024 —
Lewis Brisbois NewsroomBoston, Mass. (October 14, 2024) - Boston Managing Partner Kenneth B. Walton and Partner Matthew M. O' Leary recently secured summary judgment on behalf of a civil engineering firm in a serious personal injury matter arising from a trip-and-fall incident in a mall parking lot.
The client was retained to provide site civil engineering design for the parking lot of a local mall. The design included multiple bioretention areas known as rain gardens. In November of 2019, a woman tripped and fell while attempting to cross a rain garden to reach her car. She suffered significant bodily injuries, including a fracture of the cervical spine that resulted in partial paralysis.
The woman and her husband sued the mall's owner for negligence and loss of consortium in June 2021. The owner, in turn, impleaded Lewis Brisbois' client and the lot's builder, asserting third-party claims for contribution, contractual and common law indemnity, and breach of contract. In addition, the builder cross-claimed against Lewis Brisbois' client for contribution and common law indemnity.
Read the court decisionRead the full story...Reprinted courtesy of
Lewis Brisbois
Substituting Materials and Failure to Comply with Contractual Requirements
November 19, 2021 —
David Adelstein - Florida Construction Legal UpdatesIt is important to remember that if you are going to substitute materials from those specified, you need to make sure there is proper approval in doing so–make sure to comply with the contractual requirements to substitute materials. Otherwise, you could be in a situation where you are contractually required to remove the installed substituted materials and replace with the correct specified materials. This is not the situation you want to find yourself in because this is oftentimes a costly endeavor. This was the situation in Appeal-of-Sauer, Inc., discussed below, on a federal project. The best thing that you can do is comply with the contractual requirements if you want to substitute materials. If you are in the situation where it is too late, i.e., you already installed incorrect materials, you want to demonstrate the substituted materials are functionally equivalent to the specified materials and/or come up with an engineering solution, as required, that could be less costly then ripping out the installed material and replacing with the correct material. Even doing so, however, is not a “get out of jail free card” and does not necessarily mean there is not a strong basis to require you to install the correct specified material.
In Appeal of- Sauer, Inc., ASBCA 61847, 2021 WL 4888192 (ASBCA September 29, 2021), a federal project’s engineering requirements required cast iron piping for the above ground sanitary system. However, the prime contractor installed PVC piping instead of cast iron piping. The prime contractor believed it had the appropriate approval through its submittal. The government, through its contracting officer, directed the prime contractor to remove installed PVC piping to replace with cast iron. The government did not believe PVC piping was the functional equivalent of cast iron piping for the above ground sanitary system due to its concern with the noise level of waste materials flowing through the piping. The prime contractor submitted a claim for its removal and replacement costs which was denied by the contracting officer. On appeal with the Armed Services Board of Contract Appeals, the Board agreed with the contracting officer explaining: “While we agree that a design change could be approved by the designer of record and brought to the attention of the government before being incorporated into the design documents, the [prime contractor’s] task order required that such a design change meet the minimum requirements of the solicitation and accepted proposal. The plumbing submittal [the prime contractor] issued here, showing the use of PVC instead of cast iron for the above ground waste piping, did not meet the minimum requirements of the solicitation.” Appeal of-Sauer, Inc., supra.
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
NTSB Faults Maintenance, Inspection Oversight for Fern Hollow Bridge Collapse
March 19, 2024 —
Jim Parsons - Engineering News-RecordThe City of Pittsburgh’s failure to act for more than a decade on repeated maintenance and repair recommendations regarding the Fern Hollow Bridge was the probable cause for the structure’s dramatic 2022 collapse, the National Transportation Safety Board (NTSB) said at its Feb. 21, 2024, meeting. The city is the owner of the bridge.
Reprinted courtesy of
Jim Parsons, Engineering News-Record
ENR may be contacted at enr@enr.com
Read the full story... Read the court decisionRead the full story...Reprinted courtesy of
2015 California Construction Law Update
December 31, 2014 —
Garret Murai – California Construction Law BlogOver 2,200 bills were introduced during the second and final year of the 2013-2014 legislative session of which 931 were signed into law. For the design and construction industry, the end of the second session, like the end of the first session, saw a number of new prevailing wage bills signed into law, which again reflected the strong Democratic majorities in both the Assembly and Senate. The end of the second session also saw the enactment of laws consolidating several existing design-build authorization sections and extending the 5% cap on retention for public works projects.
Read the court decisionRead the full story...Reprinted courtesy of
Garret Murai, Wendel Rosen Black & Dean LLPMr. Murai may be contacted at
gmurai@wendel.com
Sometimes it Depends on “Whose” Hand is in the Cookie Jar
January 21, 2015 —
Roger Hughes – California Construction Law BlogIn a lengthy and somewhat detailed decision, the California Court of Appeal for First District, in Pittsburg Unified School District v. S.J. Amoroso Construction Company, Inc., Case No. A138825 (December 22, 2014), held that a public entity could unilaterally withdraw retention funds during a pending legal dispute without the court first finding that the contractor had defaulted on the public works project.
Background
In 2008, general contractor S.J. Amoroso Construction Company, Inc. (“S.J. Amoroso”) entered into a construction contract with the Pittsburg Unified School District (“District”) for the reconstruction and modernization of a high school in Pittsburg, California.
Read the court decisionRead the full story...Reprinted courtesy of
Roger Hughes, Wendel Rosen Black & Dean LLPMr. Hughes may be contacted at
rhughes@wendel.com
