CAMBRIDGE MASSACHUSETTS BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Supply Chain Delay Recommendations

August 07, 2022 — Denise Motta - Gordon & Rees Construction Law Blog
This Bulletin provides guidance to contractors, subcontractors, suppliers, and others to ensure compliance with contractual change order requirements in the event work on a construction project is impacted by supply chain delays. Contract Protection Tips: The construction industry is being impacted substantially by inability to obtain necessary construction products due to supply chain issues. Most construction contracts do not accommodate time extensions due to supply chain impacts. To address this gap in contract terms, we recommend including language such as: “lack of or failure of or other inability to obtain necessary transportation, fuel, power, materials, machinery, equipment or facilities, delays caused by other contractors, subcontractors or their subcontractors of any tier, or any materialmen or suppliers” as part of the defined force majeure event under the contract. This provision can be included in the Change Order section of the contract as well by including a provision such as: “If the Work is delayed by the failure of or other inability to obtain necessary transportation, fuel, power, materials, machinery, equipment or facilities, delays caused by other contractors, subcontractors or their subcontractors of any tier, or any materialmen or suppliers, contractor shall be entitled to a change order for its costs and time associated with the delay.” Read the court decision
Read the full story...
Reprinted courtesy of Denise Motta, Gordon Rees Scully Mansukhani, LLP
Ms. Motta may be contacted at dmotta@grsm.com

---

What Types of “Damages Claims” Survive a Trustee’s Sale?

February 28, 2018 — Ben Reeves – Real Estate Litigation blog / Snell & Wilmer
Introduction Arizona’s trustee’s sale statutory scheme provides for the waiver of all defenses and objections to a trustee’s sale that: (i) are not raised prior to the sale, and (ii) do not result in an injunction against the sale going forward. See A.R.S. § 33-811(C). In other words, if you have an objection to a trustee’s sale, you must seek and obtain an injunction prior to the sale or your objection will be waived. Arizona’s Court of Appeals previously held that notwithstanding this statutory waiver, “common law” defenses to repayment of the debt survive a non-judicial foreclosure even in the absence of an injunction prior to the sale. See Morgan AZ Financial, L.L.C. v. Gotses, 235 Ariz. 21, 326 P.3d 288 (Ct. App. 2014). Our analysis of the Morgan decision can be found here. In Zubia v. Shapiro, 243 Ariz. 412, 408 P.3d 1248 (2018), the Arizona Supreme Court revisited the issue of what claims survive a trustee’s sale, and clarified that if a person fails to enjoin a trustee’s sale prior to its occurrence, then that person waives any and all damages claims dependent upon a trustee’s sale. That person does not, however, waive damages claims that are independent of the sale. Thus, determining what types of claims are “dependent” versus “independent” of a trustee’s sale is of critical importance to lenders and borrowers alike. Read the court decision
Read the full story...
Reprinted courtesy of Ben Reeves, Snell & Wilmer
Mr. Reeves may be contacted at breeves@swlaw.com

---

Jobsite Safety Should Be Every Contractors' Priority

December 09, 2019 — Ray Reese - Construction Executive
Any general contractor understands the range of factors that go into building and sustaining a successful jobsite: hiring the right team, maintaining cutting-edge equipment, ensuring constant communication with clients and effectively leveraging the newest building technologies, just to name a few. But any good general contractor understands that there is one factor that should always be considered as top priority: jobsite safety. The health and wellbeing of a project’s team is paramount for obvious reasons, and it isn’t a lighthearted matter. Injuries and fatalities have too often been a piece of our industry’s story. In 2017 alone, there were 971 reported deaths on construction sites, which accounted for 20% of total worker fatalities, according to a report from the Occupational Safety and Health Administration. Of these 971 fatalities, 582 were the result of construction’s “fatal four”—falls, workers being struck by objects, electrocutions and workers being caught between equipment. For members of the industry, these are difficult numbers to read and to process; yet, it is extremely important to consider the injuries and lives lost when we take into consideration the seriousness of jobsite safety. Often, general contractors’ and superintendents’ greatest challenge isn’t being convinced of the necessity of jobsite safety practices in protecting employees or the value of safety in creating a productive work environment. Instead, the focus should be providing industry leaders tips on exactly how to improve safety measures on their own jobsites. Understanding that safety is everyone’s responsibility is paramount. Reprinted courtesy of Ray Reese, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Reese may be contacted at rreese@rives.com

---

Ohio “property damage” caused by an “occurrence.”

May 18, 2011 — CDCoverage.com

In JTO, Inc. v. State Automobile Mut. Ins. Co., No. 2010-L-062 (Ohio Ct. App. March 25, 2011), general contractor JTO was sued by hotel project owner Marriott for breach of contract and warranties seeking damages for the repair of construction defects resulting in moisture penetration property damage to interior components. JTO filed a third party complaint against subcontractor Farizel and also tendered its defense as an additional insured under Farizel’s State Auto CGL policy.



Read the full story…



Reprinted courtesy of CDCoverage.com



---



Census Bureau, HUD Show Declines in Residential Construction



May 17, 2011 – CDJ Staff



The U.S. Census Bureau and the Department of Housing and Urban Development released their summary of residential construction for April 2011 on May 17.



Building permits for privately owned housing units were down 4% from last month and 12% from last year. Similarly, privately-owned housing starts were down 10% from March and 23% below the previous year.



For further details, read the Census Bureau/HUD report

Read the court decision
Read the full story...
Reprinted courtesy of

---

BWBO Celebrating Attorney Award and Two New Partners

July 14, 2016 — Beverley BevenFlorez-CDJ STAFF
Congratulations is due to Nicole Whyte of Bremer Whyte Brown & O’Meara LLP (BWBO) for being recognized as one of America’s Top 100 Attorneys by America’s Top 100, which identifies the top 100 attorneys in each state. In an email release, the firm stated, “We are pleased to celebrate this lifetime achievement and it is an honor to have Ms. Whyte listed alongside her esteemed peers.” Furthermore, BWBO announced that two of their attorneys have been promoted to partner: Alex Giannetto and Benjamin Price. “Mr. Giannetto believes that hard work, dedication, caring about clients and work product, and surrounding himself with good people, has helped him become successful in his profession,” as stated in an email release. “To be successful you have to surround yourself with successful people,” Mr. Price stated. “A combination of humility, confidence, and hard work is also important.” Read the court decision
Read the full story...
Reprinted courtesy of

---

NYC Luxury-Condo Buyers Await New Towers as Sales Slow

September 24, 2014 — Oshrat Carmiel – Bloomberg
Sales at One57, the ultra-luxury Manhattan condominium tower that set off a high-end residential construction boom, have slowed to a trickle amid competition from newer properties reaching the market. Only two units at Extell Development Co.’s Midtown property went under contract this year through June 30, according to filings on the Tel Aviv Stock Exchange, where the company sells debt to investors. There were no sales in the final three months of 2013 at the building, which had earlier found buyers for two penthouses at more than $90 million each. About 25 of the 94 units on the market were unsold as of June 30, the filings show. “This is not a normal pace,” Jonathan Miller, president of New York-based appraiser Miller Samuel Inc., said in an interview. “This building had many price increases when it was the only building out there, so maybe they overdid it. In other words, the sky is not the limit.” Read the court decision
Read the full story...
Reprinted courtesy of Oshrat Carmiel, Bloomberg
Ms. Carmiel may be contacted at ocarmiel1@bloomberg.net

---

Insurer Not Responsible for Insured's Assignment of Policy Benefits

February 21, 2022 — Tred R. Eyerly - Insurance Law Hawaii
The Florida Court of Appeals affirmed the lower court's granting summary judgment to the insurer after failing to abide by an assignment to which it was not a party. Expert Inspections, LLC v. United Property & Cas. Ins. Co., 2022 Fla. App. LEXIS 88 (Fla. Ct. App. Jan. 5, 2022). The insured's property sustained damage from Hurricane Irma resulting in a covered loss. The insured retained Expert Inspections to perform mold-related services. As payment, the insured assigned her policy benefits pursuant to an assignment of benefits agreement. Under the agreement, the insured agreed to cooperate with the assignee to ensure that payments were made by the insurer upon completion of work. The insured gave authority to the assignee to endorse any checks with her name listed on the check. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Pancakes Decision Survives Challenge Before Hawaii Appellate Court

March 12, 2015 — Tred R. Eyerly – Insurance Law Hawaii
In 1997, the Hawaii Intermediate Court of Appeals (ICA) decided Pancakes of Hawaii, Inc. v. Pomare Prop. Corp., 85 Haw. 286, 944 P.2d 83 (Haw. Ct. App. 1997). Although not an insurance coverage case, Pancakes addressed the duty to defend in terms of a contractual indemnity obligation. Under challenge in a recent appeal before the ICA, the Court reaffirmed the holding in Pancakes. Arthur v. State of Hawaii, Dept. of Hawaiian Home Lands, 2015 Haw. App. LEXIS 109 (Haw. Ct. App. Feb. 27, 2015). The decision is long with detailed facts complicated and many indemnities running in favor of various parties. This post focuses on the decision's discussion of Pancakes. A resident, Mona Arthur, of the Kalawahine Streamside Housing Development, was killed when she apparently slipped and fell from a hillside adjacent to the project. She was on the hillside tending to her garden there. At the bottom of the hill was a two foot fence in front of a drainage ditch, where Mona allegedly hit her head. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---