SEATTLE WASHINGTON BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Ordinary Use of Term In Insurance Policy Prevailed

June 08, 2020 — David Adelstein - Florida Construction Legal Updates
There are cases where you feel for the plaintiff, but understand why they did not prevail, despite the creative efforts of their counsel. The case of Robinson v. Liberty Mutual Ins. Co., 958 F.3d 1137 (11th Cir. 2020) is one of these cases. In Robinson, the plaintiff moved into a home that turned out to be infested with a highly venomous spider. Efforts to eradicate the spider proved unsuccessful and the spider apparently infested the entire home. The plaintiff made a claim under their homeowner’s property insurance policy arguing that their home suffered a physical loss caused by the spider infestation as the spider presented an irreparable condition that rendered the home unsafe for occupancy. (It probably did!). The property insurer denied coverage because the policy had an insurance exclusion for loss caused by birds, vermin, rodents, or insects. The insurer claimed the spider is an insect or vermin and, therefore, there is no coverage based on the exclusion. The insured creatively argued that “scientifically speaking” a spider is an arachnid and not an insect. Neither the trial court nor the Eleventh Circuit found this argument persuasive. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Top Developments March 2024

April 22, 2024 — Complex Insurance Coverage Reporter
CLAIMS-MADE COVERAGE Zurich Am. Ins. Co. v. Syngenta Crop Prot. LLC, 2024 Del. LEXIS 68 (Del. Feb. 26, 2024) Delaware Supreme Court concludes that a letter from a lawyer informing an insured of possible lawsuits without identifying potential plaintiffs or demanding payment is not a “claim for damages” within the meaning of claims-made CGL and umbrella liability policies. Citing case law from Delaware and other jurisdictions, it reasoned that, in the ordinary sense, a “claim for damages” (which the policies did not define) is “a demand or request for monetary relief by or on behalf of an identifiable claimant.” According to the court, the letter in question did not meet this definition because it did not identify any claimants “except in the vaguest terms” or request monetary relief on any claimant’s behalf, but rather communicated only a threat of future litigation. As a result, the letter was not a claim made before the policy periods at issue. POLLUTION EXCLUSION Wesco Ins. Co. v. Brad Ingram Constr., 2024 U.S. App. LEXIS 1488 (9th Cir. Jan. 23, 2024) A divided Ninth Circuit panel, applying California law, holds that a pollution exclusion* in a CGL policy does not preclude a duty to defend an underlying suit alleging physical injury from exposure to “clouds of toxic dust” deposited in the environment by a wildfire and released during clean up efforts. Citing MacKinnon v. Truck Ins. Exch., 73 P.3d 1205 (Cal. 2003), the majority explained that determining whether a “pollution event” (i.e., “environmental pollution”) resulting in excluded injury has occurred involves consideration of “the character of the injurious substance” and whether the exposure resulted from a “mechanism specified in the policy.” It concluded that a potential for coverage (and, therefore, a defense obligation) existed because, although wildfire debris may be considered a “pollutant” in certain circumstances, the mechanism alleged in the underlying complaint – “expos[ure] . . . to clouds of toxic dust during the loading and unloading of [the underlying plaintiff’s] truck” – did not clearly constitute an “event commonly thought of as pollution.” Read the court decision
Read the full story...
Reprinted courtesy of White and Williams LLP

---

Endorsements Do Not Exclude Coverage for Wrongful Death Claim

August 30, 2017 — Tred R. Eyerly - Insurance Law Hawaii
The insurer's motion for summary judgment, attempting to bar coverage under two endorsements for a wrongful death suit, was denied. Essex Ins. Co. v. FD Event Co., LLC, 2017 U.S. Dist. LEXIS 124400 (C.D. Calif. July 25, 2017). FD Event owned an amusement attraction known as Free Drop, which was operated at county fairs and festivals. Participants paid an admission fee to FD Event in order to jump from a scaffold structure onto an inflatable airbag below. FD Event had a policy with Essex. When securing the policy, FD Event understood that there was no coverage for amusement devices, inflatables, rides or animals. 28th Event, who ran the San Bernardino County Fair, was an additional insured on the policy. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly - Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

---

Formal Request for Time Extension Not Always Required to Support Constructive Acceleration

April 25, 2022 — David Adelstein - Florida Construction Legal Updates
Does a constructive acceleration claim require the contractor to always request an extension of time which is then denied by the owner? While this is certainly the preference and the contractor should be requesting an extension of time as a matter of course for an excusable delay, the answer is NO! in certain circumstances. This is conveyed in the factually detailed case discussed below where a formal request for an extension of time was not required for the contractor to support its constructive acceleration claim. But first, what is constructive acceleration: Constructive acceleration “occurs when the government demands compliance with an original contract deadline, despite excusable delay by the contractor.” The Federal Circuit in Fraser defined the elements of constructive acceleration as follows: (1) that the contractor encountered a delay that is excusable under the contract; (2) that the contractor made a timely and sufficient request for an extension of the contract schedule; (3) that the government denied the contractor’s request for an extension or failed to act on it within a reasonable time; (4) that the government insisted on completion of the contract within a period shorter than the period to which the contractor would be entitled by taking into account the period of excusable delay, after which the contractor notified the government that it regarded the alleged order to accelerate as a constructive change in the contract; and (5) that the contractor was required to expend extra resources to compensate for the lost time and remain on schedule. Nova Group/Tutor-Saliba v. U.S., 2022 WL 815826, *42 (Fed.Cl. 2022) quoting Fraser Constr. Co. v. U.S., 384 F.3d 1354, 1361 (Fed. Cir. 2004) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Washington Court of Appeals Upholds Standard of Repose in Fruit Warehouse Case

August 04, 2011 — CDJ STAFF

On July 28, the Washington Court of Appeals ruled in Clasen Fruit & Cold Storage v. Frederick & Michael Construction Co., Inc. that more than six years had passed since a contractor had concluded work and so granted a summary dismissal of the suit.



Frederick & Michael Construction Co., Inc. (F&M) was contracted to construct several buildings for Clasen Fruit and Cold Storage. These were completed in March, 1999. The buildings suffered wind damage to the roofs in 2001, 2003, 2005, and 2006. In the first two incidents, F&M repaired the roofs with Clasen paying for repairs.



In 2005, Clasen hired Continuous Gutter to make repairs. The final incident was the collapse of the roof of one building. This was attributed to “excessive moisture in the roof’s vapor barriers.” At this point, Clasen demanded that F&M pay for repair and replacement costs. In 2008, Clasen sued F&M for damages for breach of contract and negligent design and construction of the roof.



The decision then covered the meanings, in Washington law, of “termination of services” and “substantial completion.” The panel concluded that construction was “substantially completed in 1997” and “relevant services” by 2001. “But Clasen did not sue until 2008, some seven years after termination of any roof related services.”



Read the court’s decision…

Read the court decision
Read the full story...
Reprinted courtesy of

---

Arctic Roads and Runways Face the Prospect of Rapid Decline

July 19, 2021 — Tony Frangie Mawad - Bloomberg
Melting permafrost across Arctic regions has already caused highways to buckle and homes to sink. A new study conducted in the north of Alaska helps explain why rising temperatures are hitting roads, airports and other infrastructure particularly hard. Researchers who monitored temperatures and melting near Prudhoe Bay on Alaska’s North Slope documented how the thawing of frozen ground beneath a highway tended to spread laterally to the side of the road, with the melting process accelerated by snow accumulations and puddling. Those interactions led to more rapid thawing than in areas of undisturbed permafrost. Researchers also found that melting in their test area, alongside a highway that runs atop permafrost, followed a two-phase process — a gradual initial thaw, followed by an accelerated process once warming exceeded a critical point. Read the court decision
Read the full story...
Reprinted courtesy of Tony Frangie Mawad, Bloomberg

---

Construction Materials Company CEO Sees Upturn in Building, Leading to Jobs

November 05, 2014 — Beverley BevenFlorez-CDJ STAFF
The Washington Post reported that Mesa Industries Inc. (a construction equipment and materials company), are "prepping for significant growth," which suggests that the construction industry is poised for growth. Terry Segerberg, CEO of Mesa Industries Inc., "is seeing enough nonresidential orders to suggest a sustained jobs recovery is underway in the industry — and in firms like hers that supply it." A Bureau of Labor Statistics report predicted that 1.6 million construction jobs will be added through 2022, according to the Washington Post. Read the court decision
Read the full story...
Reprinted courtesy of

---

Insurance Law Alert: Incorporation of Defective Work Does Not Result in Covered Property Damage in California Construction Claims

June 18, 2014 — Valerie A. Moore and Chris Kendrick - Haight Brown & Bonesteel LLP
In Regional Steel Corp. v. Liberty Surplus Ins. (No. B245961, filed 5/16/14, ord. pub. 6/13/14), a California appeals court held that the insured's use of the wrong steel seismic reinforcement hooks in construction of a mixed-use building was not an occurrence, and did not result in covered property damage. Regional Steel was the structural steel subcontractor on a 14-story mixed-use project in North Hollywood, California. Regional supplied plans which were approved by the developer and its structural engineers for installation of steel reinforcements, including seismic reinforcement hooks, to be encased in concrete. During construction, City inspectors determined that the plans called for the wrong hooks, necessitating repairs to finished portions of the work and delays in further construction. This ultimately resulted in a lawsuit between the developer, Regional Steel, the concrete subcontractor, the structural engineer and a quality assurance inspector. The project was insured under a wrap policy issued to the developer, with Regional named as an additional insured. The court rejected an argument that the wrap endorsement fundamentally changed the insurance, and the issue boiled down to whether incorporation of the wrong hooks, the damage caused by tearing out concrete to replace the hooks, or the resulting loss of use, triggered coverage. Liberty asserted that no damage to property was alleged and the purely economic losses caused by the need to reopen the poured concrete to correct the tie hook problem did not constitute "property damage" within the meaning of the policy. Liberty further posited that the tie hook problem did not constitute an “occurrence” within the meaning of the policy because the alleged damage was not caused by an accident. Reprinted courtesy of Valerie A. Moore, Haight Brown & Bonesteel LLP and Chris Kendrick, Haight Brown & Bonesteel LLP Read the court decision
Read the full story...
Reprinted courtesy of

---