Fairfield Connecticut Building Expert Directory

More (and Simpler) Options Under New Oregon Retention Law

October 21, 2024 — Michael Yelle - Ahlers Cressman & Sleight PLLC
Similar to the changes made by the Washington Legislature last year, the Oregon Legislature recently changed its retention law. Oregon public works agencies and large commercial project owners are now required to accept surety bonds in lieu of withholding retainage on construction projects. There is also no longer a requirement to deposit retention funds in an interest-bearing escrow account. The owner or public agency must accept the bond in lieu of retainage unless specific grounds exist. For example, public agencies must find there is “good cause” for rejection of the bond based on the “unique project circumstances. Private owners have less discretion to reject a bond and if the bond meets the statutory requirements, per ORS 701.435(1)(a) “the owner and lender shall accept” the bond “in lieu of all or any portion of the retainage…” Courts have not analyzed when “good cause” exists for public agencies to reject bonds or exactly what will allow a private owner to reject a bond. However, an agency or owner cannot have a general policy to reject retention bonds. The statute does not provide next steps if the contractor disagrees with a decision to reject the bond. It may be necessary to proceed under the contract’s dispute resolution procedure or it may be more appropriate to take the issue directly to the courts. Read the court decision
Read the full story...
Reprinted courtesy of Michael Yelle, Ahlers Cressman & Sleight PLLC
Mr. Yelle may be contacted at michael.yelle@acslawyers.com

Addressing the Defective Stucco Crisis

November 28, 2018 — Wally Zimolong - Supplemental Conditions
I received several emails regarding the expose by Caitlin McCabe and Erin Arvedlund in the Philadelphia Inquirer titled “Rotting Within.” The story outlines the epidemic of defective stucco and other “building envelope” issues in Southeastern Pennsylvania that is causing homes to literally rot from within. Having litigated several of these cases, they are frustrating for both the attorneys that handle them and the homeowners who must deal with the reality that their home is rotting away. The story points to the multiple (and all too common) causes for the epidemic: unskilled subcontractors, lack of oversight and care, and poor construction drawings. The is no quick solution to the crisis and litigation regarding these defects is sure to proliferate. However, there is one potential solution that the story does not cover and which could help alleviate some of the challenges homeowners face in recovering damages for their claims. The Pennsylvania Legislature must act to change the insurance laws in Pennsylvania to make defective construction covered by a developer’s, contractor’s, and subcontractor’s commercial general liability policy (“CGL”). Most homeowners and many attorneys incorrectly assume that defective construction is covered by insurance. This assumption makes sense. If someone operates a car in a negligent manner and hits your car and causes damage, the negligent driver’s insurance company with cover your loss. In reality, Pennsylvania courts follows a minority of states that holds that generally speaking defective workmanship is not a “covered occurrence” under an insurance policy. (There are several exceptions to this rule and thorough discussion is beyond this blog post and would probably bore you.) Read the court decision
Read the full story...
Reprinted courtesy of Wally Zimolong, Zimolong LLC
Mr. Zimolong may be contacted at wally@zimolonglaw.com

Construction Defect Leads to Death, Jury Awards $39 Million

November 27, 2013 — CDJ STAFF
A failure in the installation of a 13-ton concrete panel in Milwaukee County lead to the death of a 15-year-old boy in 201; two others were also injured. A lawsuit over this has concluded with the contractor, Advance Cast Stone, found culpable due to their concealing that the panel was not installed as prescribed. The incident happened at a parking garage operated by the county. Advanced Cast Stone made the claim that the method they used to secure the panel had been approved by other in the project. The jury awarded $6.3 million to the estate of Jared Kellner, $1.5 million each to the young man who was injured, Eric Wosniki, and his parents. The county was also awarded $6 million for lost revenue in the parking garage and for repairs. Read the court decision
Read the full story...
Reprinted courtesy of

25 Days After Explosion, Another Utility Shuts Off Gas in Boston Area

October 30, 2018 — Johanna Knapschaefer - Engineering News-Record
Three hundred thirty-nine homes in Woburn, Mass., were without power on Oct. 8 after National Grid shut off gas meters following the inadvertent over-pressurization of the natural gas line on Oct. 8, according to the Woburn Fire Dept. Read the court decision
Read the full story...
Reprinted courtesy of Johanna Knapschaefer, ENR
ENR may be contacted at ENR.com@bnpmedia.com

Recovering Time and Costs from Hurricane Helene: Force Majeure Solutions for Contractors

November 18, 2024 — Matthew DeVries - Best Practices Construction Law
When Hurricane Helene struck North Carolina, it caused severe disruptions to construction projects across the state. Baxter International’s North Cove facility in Marion, N.C., was completely shut down after floodwaters damaged the site and bridges leading to it. Elsewhere, landslides and floods wiped out large sections of Interstate 40, making transportation of materials and equipment nearly impossible. Many contractors in western North Carolina found their projects halted, and their schedules thrown off by this force majeure event. In situations like these, contractors and subcontractor need a plan to mitigate the impact of such natural disasters on their projects. Here are five practical tips to help you secure time extensions and/or compensation for delays: 1. Include a Robust Force Majeure Clause in Your Contract When disaster strikes, your contract is your first line of defense. A well-drafted force majeure clause can make the difference between bearing the costs yourself and getting an extension or compensation. The clause should clearly list specific events such as hurricanes, floods, and road closures as qualifying force majeure events. Read the court decision
Read the full story...
Reprinted courtesy of Matthew DeVries, Buchalter
Mr. DeVries may be contacted at mdevries@buchalter.com

A New Study: Unexpected Overtime is Predictable and Controllable

January 31, 2022 — Aarni Heiskanen - AEC Business
A new study by Dodge Construction Network and Versatile, a construction technology pioneer using artificial intelligence (AI) and the internet of things (IoT) to optimize construction processes, found that unexpected overtime is predictable and controllable through regular job site activity measurement. According to the study, overtime is predictable at an 88% confidence level, if proper measurement is utilized. Overtime is a persistent feature of construction sites, however, it is often unplanned and unpredictable. Despite the cost of overtime, its impact on skilled workers, and its implications for safety and other key factors on a project site, it is often applied to address immediate concerns rather than planned to maximize its effects. This recent study shows that in order to best understand overtime and its impact, data and measurement of jobsite activities are key. “Unique insights derived from advanced data and analytics tools will empower construction crews to build better,” said Meirav Oren, co-founder and CEO of Versatile. “Overtime can be a very effective tool on the jobsite. Through the power of data, general contractors gain the ability to minimize unnecessary overtime while maximizing its strategic benefits.” Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

California Supreme Court Holds Insured Entitled to Coverage Under CGL Policy for Negligent Hiring

June 13, 2018 — Traub Lieberman Straus & Shrewsberry LLP - TLSS Insurance Law Blog
In its recent decision in Liberty Surplus Ins. Corp. v. Ledesma & Meyer Constr. Co.,2018 Cal. LEXIS 4063 (Cal. June 4, 2018), the Supreme Court of California addressed the question of whether an insured’s negligent hiring, retention and supervision of an employee who intentionally injured a third-party can be considered an occurrence under a general liability policy. The insured, L&M, was the construction manager on a project at a middle school in California. It was alleged that one of its employees sexually abused a thirteen year old student during the course of the project. The student later brought a civil suit against L&M based on its negligent hiring, retention and supervision of the employee-perpetrator. Read the court decision
Read the full story...
Reprinted courtesy of Traub Lieberman Straus & Shrewsberry LLP

Research Institute: A Shared Information Platform Reduces Construction Costs Considerably

October 26, 2017 — Aarni Heiskanen - AEC Business
A new Danish study shows how the use of a shared digital management and communication platform on large-scale construction projects leads to considerable cost reductions. The Danish Building Research Institute conducted a six-month research project that studied the effects of using a specific IT concept during construction. The three case studies were: 1. The Maersk Tower, a 15-story, 42,700-square-meter extension to the Panum complex. 2. The Niels Bohr Building, a 52,000-square-meter new laboratory and academic building. 3. The Danish Defence’s Property Agency’s construction project portfolio (FES). Each of them used GenieBelt as the shared IT platform. It was used for the progress management of a construction project portfolio, management of construction activities, and communication between the construction management team and contractors. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at info@aepartners.fi

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES