Seattle Washington Building Expert Directory

Insurer's Motion to Dismiss Allegations of Collapse Rejected

August 08, 2018 — Tred R. Eyerly - Insurance Law Hawaii
In yet another of the collapse cases being litigated in state and federal courts in Connecticut, the federal district court denied the insurer's motion to dismiss. Rosenberger v. Amica Mut. Ins. Co., 2018 U.S. Dist. LEXIS 95345 (D. Conn. June 6, 2018). The insureds had policies with Amica since 1989. Policies before December 18, 2006, covered collapse caused by hidden decay or other specified causes. "Collapse" was not defined by the policy. These policies did not include any provisions explicitly excluding coverage for a chemical reaction. The post-2006 policies held by the insureds covered collapse, but under a significantly modified definition. The newer policy language stated that "collapse applies only to an abrupt collapse." Further, collapse was defined as "an abrupt falling down or caving in of a building or any part of a building with the result that the building or part of the building cannot be occupied for its intended purpose." Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Damon Key Leong Kupchak Hastert
Mr. Eyerly may be contacted at te@hawaiilawyer.com

New York Supreme Court Building Opening Delayed Again

September 24, 2014 — Beverley BevenFlorez-CDJ STAFF
SI Live reported that the opening of the new state Supreme Court building in St. George, New York is delayed again due to problems with the air-conditioning and elevator systems. Delay, however, is not new to this project, which was originally expected to be completed over a decade ago. Initial delay was introduced “with the finding of remains from a 19th-century burial ground at the site, a former municipal parking lot, and more recently, with construction set-backs and other tie-ups,” according to SI Live. When completed, the new “building will boast 14 courtrooms, jury assembly, hearing and deliberation rooms, judges' chambers and court offices. There will also be holding cells for prisoners.” Read the court decision
Read the full story...
Reprinted courtesy of

A Termination for Convenience Is Not a Termination for Default

April 22, 2024 — David Adelstein - Florida Construction Legal Updates
A termination for convenience is NOT a termination for default. They are NOT the same. They should NOT be treated as the same. I am a huge proponent of termination for convenience provisions because sometimes a party needs to be able to exercise a termination for convenience, but the termination is not one that rises to a basis for default. However, exercising a termination for convenience does not mean you get to go back in time and convert the termination for convenience into a termination for default. It does not work like that. Nor should it. An opinion out of the Civilian Board of Contract Appeals – Williams Building Company, Inc. v. Department of State, CBCA 7147, 2024 WL 1099788 (CBCA 2024 – demonstrates a fundamental distinction between a termination for convenience and a termination for default, i.e., that you don’t get to conjure up defaults when you exercise a termination for convenience:

Because a termination for convenience essentially turns a fixed-price construction contract into a cost-reimbursement contract, allowing the contractor to recover its incurred performance costs, the resolution of this appeal will involve identifying the total costs that [Contractor] incurred in performing this contract before [Government] terminated it for convenience. Since [Government] terminated the contract for convenience rather than for default, it no longer matters whether, in the past,[Contractor] acted intentionally in overstating the amount of its incurred costs or committed a contract breach. Ultimately, as permitted in response to a termination for convenience, [Contractor] will recover those allowable costs that [Contractor]establishes it incurred in performing the contract.

Williams Building Company, supra.

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Termination of Construction Contracts

November 30, 2020 — Stuart Rosen - Construction Executive
Lately, in view of the COVID-19 pandemic, there is a heightened concern that some construction projects will not proceed as planned. Therefore, it is important to review each party’s right to terminate a construction contract and to examine some of the resulting consequences. While the parties to a construction contract can, as always, agree to other mutually acceptable terms and provisions, in broad terms, a typical construction contract includes four triggering events that can lead to termination. First, an owner can terminate a construction contract if the contractor defaults and thereafter fails to cure such default, which may include, without limitation, the failure to remediate deficient work, the failure to meet the construction schedule, the failure to pay subcontractors and the failure to comply with applicable law. A contractor must be mindful of the fact that in the case of such termination by the owner for cause, the vast majority of construction contracts provide that the contractor will not be entitled to receive any further payment for work performed by the contractor until the work is finished. Reprinted courtesy of Stuart Rosen, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Rosen may be contacted at srosen@proskauer.com

Golf Resorts Offering Yoga, Hovercraft Rides to the Green

June 18, 2014 — Nadja Brandt – Bloomberg
Florida’s Woodmont Country Club, which once boasted 1,200 members, has been hit hard in the past decade as hurricanes and then the recession kept golfers away. Now the club’s owner is adding conference space, stores, restaurants, a spa and a hotel as part of a planned revival. About $100 million will be spent on the revamp of the property in Tamarac, about 14 miles (23 kilometers) northwest of Fort Lauderdale, owner Mark Schmidt said. After years of negotiations with local authorities, he expects to receive approval this month for the planned Woodmont improvements. While tennis courts and swimming pools have long had a place at golf clubs, a growing number of course owners are embracing mixed-use real estate, a concept more often used in urban developments to hedge risk and diversify returns. Property investors are adding everything from medical facilities to amphitheaters and hovercraft operations to increase revenue. Read the court decision
Read the full story...
Reprinted courtesy of Nadja Brandt, Bloomberg
Ms. Brandt may be contacted at nbrandt@bloomberg.net

Is It Time to Get Rid of Retainage?

June 15, 2020 — David K. Taylor - Construction Executive
Many debate the pros, cons and claims of retainage—when one party to a construction contract withholds a percentage (typically 5%-10%) from an otherwise approved contractor pay application, and which typically is not paid until a project is substantially complete. If an owner withholds retainage from a prime contractor, typically the contractor will in turn withhold retainage from its subcontractors. While retainage has been part of the construction industry for decades, its concept, use (and abuse) have been under more discussion during the past 10 years. Based on heavy lobbying from primary subcontractor groups, state legislatures have passed laws to regulate retainage in commercial projects. Lenders have become more careful about loans and are frequently involved in retainage discussions. Bonded projects are subject to criticism when a surety does not step in and, like the mythical insurance company, write a check. Reprinted courtesy of David K. Taylor, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of
Mr. Taylor may be contacted at dtaylor@bradley.com

County Sovereign Immunity Invokes Change-Order Ordinance

December 20, 2017 — Lizbeth Dison - AHC Contruction Law Blog
The recent case of Fulton County v. Soco Contracting Company, Inc. addresses two very interesting questions for local government attorneys. First, can a county ordinance bolster a defense of sovereign immunity against a contractor’s claims? Second, can a county waive sovereign immunity by failing to respond to Requests for Admission? Facts: County hired Contractor to construct a facility near the airport. The contract provided that change orders must satisfy a county ordinance, which required approval by the Board of Commissioners. But in emergency situations, the County Manager could approve change orders, as long as the contractor executes a proposed modification and the purchasing agent approves it. The project suffered substantial delays, which Contractor attributed to weather, design delays, delays by the County in providing decisions on changes, and delays in obtaining permits during the federal government’s shutdown. As a result of these issues, Contractor comes County changed the scope of the contract. Contractor asserted claims against County for the delays and the changes to the work. The appellate opinion addresses the change order claims. Read the court decision
Read the full story...
Reprinted courtesy of Lizbeth Dison, Autry Hall & Cook, LLP

Newport Beach Attorneys John Toohey and Nick Rodriguez Receive Full Defense Verdict

July 31, 2024 — Dolores Montoya - Bremer Whyte Brown & O'Meara LLP
Bremer Whyte Brown & O’Meara is pleased to report that Partner John Toohey and Senior Associate Nicholas Rodriguez received a complete defense verdict after a 5-week jury trial in Orange County Superior Court. The case involved a multimillion-dollar home in Orange County. Plaintiff had originally suffered a water loss throughout areas of the home. Our client, an Orange County restoration and construction company, was hired to provide on-going estimates and perform demolition. Plaintiff claimed that, in the course of the demolition process, asbestos containing material was disturbed and spread resulting in contamination throughout home. Plaintiff claimed contractor negligence and breach of contract against our client. Plaintiff sought millions against our client in general and special damages for whole home restoration and other related general damages. The jury found in complete favor of our client on all allegations and awarded zero dollars to the opposing party. Read the court decision
Read the full story...
Reprinted courtesy of Dolores Montoya, Bremer Whyte Brown & O'Meara LLP

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES