Seattle Washington Building Expert Directory

The Construction Project is Late—Allocation of Delay

November 17, 2016 — David Adelstein – Florida Construction Legal Updates
The construction project is late. Very late. The owner is upset and notifies the contractor that it is assessing liquidated damages. The contractor, in turn, claims that the project is late because of excusable, compensable delays and, perhaps, excusable, noncompensable delays. This is a common and unfortunate story between an owner and contractor on any late construction project. Now the fun begins regarding the allocation of the delay! Through previous articles, I discussed that in this scenario the burden really falls on the contractor to establish that the liquidated damages were improperly assessed against it and, thus, it is entitled to additional time and/or extended general conditions as a result of excusable delays. Naturally, this requires the contractor to develop a critical path analysis (time impact analysis) allocating the impacts / delays (and the reasons for the impacts/ delays) to the project completion date. The reason the burden really falls on the contractor is because the owner’s burden is relatively easy – the project was not complete on time pursuant to the contract and any approved changed orders. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Katz, Barron, Squitero, Faust, Friedberg, English & Allen, P.A.
Mr. Adelstein may be contacted at dma@katzbarron.com

Kentucky Supreme Court Creates New “Goldilocks Zone” to Limit Opinions of Biomechanical Experts

July 24, 2023 — Aimee E. Muller - Lewis Brisbois
Lexington, Ky. (June 26, 2023) – In a recent decision, the Kentucky Supreme Court placed stricter limitations on the opinions that biomechanical engineers may offer at trials in Kentucky courts. Specifically, the published opinion issued in Renot v. Securea, Supreme Ins. Co., 2023 Ky. LEXIS 163, recognizes a new space for the testimony of biomechanics experts – “The Goldilocks Zone.” Where is the Goldilocks Zone? The Goldilocks Zone is a perfect place in which the proffered testimony is neither too specific such that it wanders into the realm of medical causation, nor too general such that it fails to help a lay jury. Specifically, a biomechanical engineer’s expert testimony must be limited to the forces generated by the subject collision, the generally anticipated responses of a hypothetical person’s body to those forces, and the range of typical injuries resulting from such forces. Moreover, following Renot, a biomechanical engineer’s proffered opinions no longer may enter into the realm of diagnosing a specific medical condition associated with a traumatic injury. Instead, the question of whether a trauma actually caused or exacerbated a plaintiff’s injuries falls solely within the purview of a medical doctor. Read the court decision
Read the full story...
Reprinted courtesy of Aimee E. Muller, Lewis Brisbois
Ms. Muller may be contacted at Aimee.Muller@lewisbrisbois.com

Iowa Tornado Flattens Homes, Businesses and Wind Turbines

June 17, 2024 — Annemarie Mannion - Engineering News-Record
Business owners and residents are picking up the pieces after a tornado tore through south-central Iowa May 21, devastating the town of Greenfield, about 60 miles southwest of Des Moines, by destroying homes and businesses, toppling MidAmerican Energy Co. wind turbines and damaging the Adair County Memorial Hospital. Reprinted courtesy of Annemarie Mannion, Engineering News-Record Ms. Mannion may be contacted at manniona@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Property Damage, Occurrences, Delays, Offsets and Fees. California Decision is a Smorgasbord of Construction Insurance Issues

November 15, 2017 — Garret Murai - California Construction Law Blog
I read once that 97 percent of cases never go to trial. However, there are still the ones that do. And, then, there are the ones that do both. The following case, Global Modular, Inc. v. Kadena Pacific, Inc., California Court of Appeals for the Fourth District, Case No. E063551 (September 8, 2017), highlights some of the issues that can arise when portions of cases settle and other portions go to trial, the recovery of delay damages on a construction project through insurance, and the recovery of attorneys’ fees. Global Modular, Inc. v. Kadena Pacific, Inc. The U.S. Department of Veterans Affairs contracted with general contractor Kadena Pacific, Inc. (Kadena) to oversee construction of its Center for Blind Rehabilitation in Menlo Park, California. Kadena, in turn, contracted with subcontractor Global Modular, Inc. (Global) to construct, deliver and install 53 modular units totaling more than 37,000 square feet for a contract price of approximately $3.5 million. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

It’s a Bird, It’s a Plane . . . No, It’s a Drone. Long Awaited FAA Drone Regulations Finally Take Flight

September 22, 2016 — Garret Murai – California Construction Law Blog
It’s a bird. It’s a plane. No, it’s a drone. Also known as an unmanned aerial vehicle (UAV) or unmanned aircraft (UA). And, technically, they’ve been around a long time, since at least 1849 when the Australians attacked Italy with unmanned balloons loaded with explosives. Even a young Marilyn Monroe, when she was known simply as “Norma Jean,” worked at a company called Radioplane making unmanned aircrafts during World War II. Since then, as technology has advanced, which, in turn, has made the cost of older technology go down, what was once old, is now new again. Drones are making regular appearances in the movies (think the Divergent Series: Allegiant). The paparazzi (who are apparently tired of getting punched in the face) are using them. And some day, perhaps very soon, they may just be delivering your packages (think Amazon Prime Air). One of the earliest adopters of drones outside the military, however, has been the construction industry which has used drones to track the progress of construction projects and conduct site surveys such as this one showing the progress of Apple’s new campus in Cupertino[.] Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel, Rosen, Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Evacuations in Santa Barbara County as more Mudslides are Predicted

March 14, 2018 — Dave Suggs – CDJ Staff
Alene Tchekmedyian’s LA times article “Storm triggers evacuations in Santa Barbara County: 'Don't be fooled into thinking that this can’t happen again',” warns of the deadly potential of mudslides following the devastation that occurred in January that caused 21 fatalities and damaged homes in Montecito. Debris flow could be triggered by rainfall rates predicted to exceed half and inch per hour. In some areas as much as seven-tenths of an inch of rain per hour are possible because of a chance of thunderstorms. Mandatory evacuations began Monday to protect residents from the fast-moving storm that is predicted to be worse than January’s. Santa Barbara county officials asked that people help spread the word of the evacuation to everyone in their community. They also created an interactive map to help residents determine their risk level. Matilija Canyon and North Fork in Ventura County are under voluntary evacuation orders. Areas at the highest risk include Thomas, Sherpa, and Whittier burn areas. Residents can find shelter at the Goleta Valley Community Center at 5679 Hollister Avenue. Read the court decision
Read the full story...
Reprinted courtesy of

Latosha Ellis Selected for 2019 Leadership Council on Legal Diversity Pathfinder Program

April 10, 2019 — Michael S. Levine - Hunton Andrews Kurth
Hunton Andrews Kurth has selected Latosha Ellis, an associate in the firm’s Insurance Coverage practice, for the 2019 Leadership Council on Legal Diversity (LCLD) Pathfinder Program. Pathfinder is a national yearlong program that trains diverse, high performing, early-career attorneys in critical career development strategies, including foundational leadership and building professional networks. Read the court decision
Read the full story...
Reprinted courtesy of Michael S. Levine, Hunton Andrews Kurth
Mr. Levine may be contacted at mlevine@HuntonAK.com

Commercial Development Nearly Quadruples in Jacksonville Area

December 04, 2013 — CDJ STAFF
Construction is up in the Jacksonville area, and no sector is doing better than commercial construction. During the first ten months of 2012, there was $21.2 million of commercial construction, but during the first ten months of 2013, there was been $73.2 million of commercial construction, helped along by a $13.7 million medical complex. In addition to the massive growth in commercial construction, residential construction is up, but by a comparatively modest 52%. Read the court decision
Read the full story...
Reprinted courtesy of

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES