Cambridge Massachusetts Building Expert Directory

Coverage, Bad Faith Upheld In Construction Defect Case

October 26, 2017 — Tred R. Eyerly - Insurance Law Hawaii
The California Court of Appeal affirmed the trial court's finding of coverage for faulty workmanship allegations and bad faith by the insurer. Pulte Home Corp. v. Am Safety Indem. Co., 2017 Cal. App. LEXIS 748 (Cal. Ct. App. Aug. 30, 2017). Pulte Home Corporation was the general contractor and developer of two residential projects. American Safety issued several sequential comprehensive general liability policies to three of Pulte's subcontractors which named Pulte as an additional insured. The projects were completed by 2006. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly - Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Turner Construction Selected for Anaheim Convention Center Expansion Project

May 21, 2014 — Beverley BevenFlorez-CDJ STAFF
The Anaheim, California city council selected Turner Construction Company “to manage a $180 million expansion of the Anaheim Convention Center, a venue that hosted 238 tradeshows, conventions, meetings and consumer events in 2013,” according to Construction Digital. “Turner’s Southern California office calls Anaheim home, and we are pleased to be working on such a great project in our own backyard,” Kevin Dow, Vice President and General Manager of Turner’s Southern California office told Construction Digital. Read the court decision
Read the full story...
Reprinted courtesy of

What Every Project Participant Needs to Know About Delay Claims

August 05, 2024 — Andrew G. Vicknair - The Dispute Resolver
A “delay” on a construction project is defined as the stretching out of the time for completion of certain key milestone scopes of work which can impact the completion date of an entire project, due to some circumstances or events that were not reasonably anticipated when the project began. 2 Construction Law ¶ 6.01 (Matthew Bender, 2024). While delays can be caused by any number of events, the most common are defective plans and specifications; design changes; severe weather and other, similar unforeseeable events; unforeseen or differing site conditions; unavailability of materials or labor; labor inefficiencies or stoppages; contractor negligence; and owner influences, including construction changes or outright interference by the owner or its agents. If the project schedule is not recovered following a delay, then the project schedule will likely be extended, resulting in an increase in the contractor’s costs of performance. A contractor that has experienced a delay on a project can take certain actions to pursue recovery of any damages the contractor may have incurred. However, to do so it is important to understand the different types of delays and the methods for establishing the delays. I. Types of Delays Delays may be categorized as (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. A critical delay is a delay that affects the project completion date and delays the entire project. In essence, a critical delay is one that will extend the critical path of a project. A non-critical delay is a delay that has no effect on the project’s critical path. Courts have recognized that delays to work not on the critical path will generally not delay the completion of a project. G.M. Shupe, Inc. v U.S., 5 Cl. Ct. 662, 728 (1984). Such a non-critical delay may affect the completion of certain activities, but does not affect the completion date of the entire project. In order for a delay to provide the basis for a claim for additional time or money, the delay must impact critical path activities on the project schedule. Read the court decision
Read the full story...
Reprinted courtesy of Andrew G. Vicknair, D'Arcy Vicknair, LLC
Mr. Vicknair may be contacted at agv@darcyvicknair.com

Business Interruption Claim Upheld

April 01, 2015 — Tred R. Eyerly – Insurance Law Hawaii
A business interruption claim survived an appeal after it was determined the claim was satisfactorily presented to the trial court. Citadel Broadcasting Corp. v. Axis U.S. Ins. Co., 2015 La. App. LEXIS 274 (La. Ct. App. Feb. 11, 2015). When Hurricane Katrina hit on August 29, 2005, the insured owned three radio stations that broadcast in and around New Orleans. All three stations suffered property damage and were off the air for varying periods of time. The insured's policy with Axis covered both physical damage and business interruption (BI) losses. The policy also insured contingent business interruption income (CBI). Both ordinary BI and CBI losses were covered under a 365 day extended period of indemnity (EPI). Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Resolving Subcontractor Disputes with Pass-Through Claims and Liquidation Agreements

May 13, 2024 — Stephanie Cooksey - Peckar & Abramson, P.C.
Imagine a project where you are unable to reach final completion due to an unresolved subcontractor claim. If the project owner is responsible for the claim, and both the owner and subcontractor are entrenched in their positions, how would you resolve this dispute? The default option is a three-party lawsuit where the subcontractor sues you in your capacity as general contractor. By denying the claim, you bring the owner into the lawsuit as a liable party to the subcontractor’s claim. This option is efficient from the judicial system’s perspective, as it means one lawsuit instead of two. The subcontractor cannot sue the owner since the two have no contract between them. Thus, the subcontractor’s recourse is limited to suing the contractor. In the three-party lawsuit, you argue that if the subcontractor prevails in its claim against you, the owner is liable. If the owner successfully defends against the claim, the subcontractor takes nothing. Putting judicial economy aside, it may not make economic sense for contractors to have a lawyer involved in litigating a case where they have no skin in the game. Fortunately, there is a better option than the three-party lawsuit on multi-party construction projects. Read the court decision
Read the full story...
Reprinted courtesy of Stephanie Cooksey, Peckar & Abramson, P.C.
Ms. Cooksey may be contacted at scooksey@pecklaw.com

Second Circuit Certifies Question Impacting "Bellefonte Rule"

December 15, 2016 — Ellen Burrows – White and Williams LLP
Calling into question the continued validity of the so-called “Bellefonte Rule,” on December 8, 2016, the United States Court of Appeals for the Second Circuit certified to the New York Court of Appeals the question whether a facultative reinsurance contract limit is presumptively all-inclusive and “caps” the reinsurer’s total exposure even where the reinsured policy pays defense costs in addition to the limit. Global Reinsurance Corporation v. Century Indemnity Company Docket No. 15-2164-cv (December 8, 2016).[1] In Bellefonte Reinsurance Company v. Aetna 903 F.2d 910 (2d Cir. 1990), the court ruled that a reinsurer was not liable to pay defense costs above the stated reinsurance contract limit. Although litigants argued that this ruling was dependent on the fact that the reinsured policy limits were defense cost-inclusive, a later panel of the Second Circuit applied the “cap” ruling in Bellefonte to a situation where the reinsured policy limit was not cost-inclusive and where the insurer was obligated to pay defense costs in addition to the policy limit. Unigard Security Insurance Company v. North River Insurance Company 4 F.3d 1049 (2d Cir. 1993). Read the court decision
Read the full story...
Reprinted courtesy of Ellen Burrows, White and Williams LLP
Ms. Burrows may be contacted at burrowse@whiteandwilliams.com

Feds to Repair Damage From Halted Border Wall Work in Texas, California

May 31, 2021 — Mary B. Powers - Engineering News-Record
With hurricane season fast approaching, the U.S. Dept. of Homeland Security has begun repair of large breaches in a 13-mile section of Rio Grande flood barriers in Texas caused by Trump administration border wall contractors building on them—after local officials feared "extensive problems" with their integrity and threatened to bring in their own crews. Reprinted courtesy of Mary B. Powers, Engineering News-Record ENR may be contacted at ENR.com@bnpmedia.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Illinois Appellate Court Affirms Duty to Defend Construction Defect Case

August 04, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The Illinois Appellate Court affirmed the trial court's ruling that the insurer had a duty to defend a construction defect case. West Bend Mut. Ins. Co. v. Pulte Home Corp., 2015 Ill App. Unpub. LEXIS 1039 (Ill. Ct. App. May 15, 2015). Pulte Home Corporation was a developer who developed and constructed a residential condominium development known as The Reserve of Elgin (The Reserve). G.H. Siding was subcontracted by Pulte to work on the development, including the installation of exterior siding. The Reserve Homeowners Association (HOA) filed suit against Pulte and James Hardie Building Products Inc., the company that manufactured the exterior siding. The complaint alleged that Pulte developed, designed, constructed and sold the units and common areas. Pulte installed siding manufactured by Hardie on the exterior of the units. The siding was allegedly defective. The HOA alleged breach of implied warranty of habitability and breach of contract by Pulte. Hardie was sued for breach of express warranty and breach of implied warrant of habitability. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

CAMBRIDGE MASSACHUSETTS BUILDING EXPERT DIRECTORY AND CAPABILITIES