No Third-Quarter Gain for Construction
November 18, 2011 —
CDJ STAFFThe Associated Builders and Contractors released their analysis of construction work under contract and found that there was no increase in construction backlog from the second quarter of 2011. There was still improvement, however, over 2010, as the third quarter backlog is 16.3 percent higher than that of a year ago.
The current backlog is 8.1 months, which according to Anirban Basu, the chief economist of the ABC, “is consistent with flat construction spending.” He noted that less than 8 months indicated a decline.
Read the full story…
Read the court decisionRead the full story...Reprinted courtesy of
Connecticut Court Clarifies Construction Coverage
June 28, 2013 —
CDJ STAFFThe Connecticut Supreme Court has recently ruled on a case in which breach of contract and bad-faith claims were made against an insurer in an construction defect case. Joseph K. Scully of Day Pitney LLP discussed the case in a piece on Mondaq.
Mr. Scully noted that the background of the case was that Capstone Building was the general contractor and project developer of a student housing complex for the University of Connecticut. Unfortunately, the building had a variety of problems, some of which were violations of the building code. Mr. Scully noted that the building had “elevated carbon monoxide levels resulting from inadequate venting, improperly sized flues.” Capstone entered into mediation with the University of Connecticut. Capstone’s insurer, the American Motorists Insurance Company (AMICO), declined involvement in the participation. Afterward, Capstone sued AMICO. The issues the court covered involved the insurance on this project.
The court addressed three questions. The first was “whether damage to a construction project caused by construction defects and faulty workmanship may constitute ‘property damage’ resulting from an ‘occurrence.’” The court concluded that it could “only if it involved physical injury or loss of use of ‘nondefective property.’”
The second question dealt with whether insurers were obligated to investigate insurance claims. The court, “agreeing with the majority of jurisdictions,” did not find “a cause of action based solely on an insurer’s failure to investigate a claim.” Under the terms of the contract, it was up to AMICO to decide if it was going to investigate the claim.
Thirdly, the court examined whether “an insured is entitled to recover the full amount of a pre-suit settlement involving both covered and noncovered claims after an insurer wrongfully disclaims coverage.” The court concluded that the limits are that the settlement be reasonable, the policy limit, and the covered claims.
Mr. Scully concludes that the decision will limit “the scope of coverage for construction defect claims” and “also imposes reasonable requirements on an insured to allocate a settlement between covered and noncovered claims.
Read the court decisionRead the full story...Reprinted courtesy of
2016 Hawaii Legislature Enacts Five Insurance-Related Bills
May 12, 2016 —
Tred R. Eyerly – Insurance Law HawaiiThe 2016 Hawaii legislative session passed five insurance-related bills. Bills that have been enacted are the following:
HB 260 - The bill establishes motor vehicle insurance requirements for transportation network companies and drivers that will take effect on September 1, 2016. The Insurance Commissioner is directed to examine the effects of this measure on personal motor vehicle insurance policy rates in the State and submit an annual report to the Legislature. The bill will sunset on September 1, 2021. The measure has been transmitted to the Governor for signature.
HB 1705 - Electronic insurance cards, in addition to paper cards, are permitted by the bill. The card serves as proof of insurance for motor vehicles and is to be carried in the vehicle at all times. The legislation has been forwarded to the Governor for signature.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Insurance Law HawaiiMr. Eyerly may be contacted at
te@hawaiilawyer.com
Does a No-Damage-for-Delay Clause Also Preclude Acceleration Damages?
January 27, 2020 —
Ted R. Gropman & Christine Z. Fan - ConsensusDocsConstruction contracts often include a “no damage for delay” clause that denies a contractor the right to recover delay-related costs and limits the contractor’s remedy to an extension of time for noncontractor-caused delays to a project’s completion date. Depending on the nature of the delay and the jurisdiction where the project is located, the contractual prohibition against delay damages may well be enforceable. This article will explore whether an enforceable no-damage-for-delay clause is also a bar to recovery of “acceleration” damages, i.e., the costs incurred by the contractor in its attempt to overcome delays to the project’s completion date.
Courts are split as to whether damages for a contractor’s “acceleration” efforts are distinguishable from “delay” damages such that they may be recovered under an enforceable no-damage-for-delay clause. See, e.g., Siefford v. Hous. Auth. of Humboldt, 223 N.W.2d 816 (Neb. 1974) (disallowing the recovery of acceleration damages under a no-damage-for-delay clause); but see Watson Elec. Constr. Co. v. Winston-Salem, 109 N.C. App. 194 (1993) (allowing the recovery of acceleration damages despite a no-damage-for-delay clause). The scope and effect of a no-damage-for-delay clause depend on the specific laws of the jurisdiction and the factual circumstances involved.
There are a few ways for a contractor to circumvent an enforceable no-damage-for-delay clause to recover acceleration damages. First, the contractor may invoke one of the state’s enumerated exceptions to the enforceability of the clause. It is helpful to keep in mind that most jurisdictions strictly construe a no-damage-for-delay clause to limit its application. This means that, regardless of delay or acceleration, courts will nonetheless permit the contractor to recover damages if the delay is, for example, of a kind not contemplated by the parties, due to an unreasonable delay, or a result of the owner’s fraud, bad faith, gross negligence, active interference or abandonment of the contract. See Tricon Kent Co. v. Lafarge N. Am., Inc., 186 P.3d 155, 160 (Colo. App. 2008); United States Steel Corp. v. Mo. P. R. Co., 668 F.2d 435, 438 (8th Cir. 1982); Peter Kiewit Sons’ Co. v. Iowa S. Utils. Co., 355 F. Supp. 376, 396 (S.D. Iowa 1973).
Reprinted courtesy of
Ted R. Gropman, Pepper Hamilton LLP and Christine Z. Fan, Pepper Hamilton LLP
Mr. Gropman may be contacted at gropmant@pepperlaw.com
Read the court decisionRead the full story...Reprinted courtesy of
Chesapeake Bay Water Quality Is Still in Trouble, Two Major Reviews Say
November 07, 2022 —
Pam McFarland - Engineering News-RecordTwo separate assessments of the health of the Chesapeake Bay indicate that most jurisdictions within its watershed are not on track to meet target goals to cut nitrogen and phosphorus discharge levels by 2025. But new plans and programs put in place in 2022 could improve the restoration trajectory, according to the U.S. Environmental Protection Agency.
Reprinted courtesy of
Pam McFarland, Engineering News-Record
Ms. McFarland may be contacted at mcfarlandp@enr.com
Read the full story... Read the court decisionRead the full story...Reprinted courtesy of
Construction Worker Dies after Building Collapse
November 18, 2011 —
CDJ STAFFA Bronx construction worker died when the pillars gave way in the basement where he was working. The two-story commercial building collapsed, burying Mr. Kebbeh under about six feet of rubble. The New York Times reports that firefighters dug him out with their bare hands. Mr. Kebbeh was taken to Jacobi Medical Center where he died. Two other construction workers escaped unharmed.
Read the full story…
Read the court decisionRead the full story...Reprinted courtesy of
Georgia Coal-to-Solar Pivot Shows the Way on Climate Regs
July 02, 2014 —
Mark Drajem and Margaret Newkirk – BloombergGeorgia small-business owner Julian Smith keeps hearing that the Obama administration’s latest climate regulations will drive up local electric bills. He doesn’t believe the prediction, but he isn’t arguing: The fears are doing wonders for his solar-panel installation company.
“My phone is blowing up with new customers,” Smith, owner of SolarSmith LLC of Savannah, said in an interview. “It turns out that if you tell everybody the amount they will spend on electricity will skyrocket, they will believe you.”
In Smith’s home state, as in the rest of the nation, businesses and consumers are struggling to size up competing claims about the Environmental Protection Agency’s plan to cut carbon pollution from power plants, released June 2. The proposed regulations are among the most sweeping and complex in the EPA’s history, promising to revamp the way electricity has been generated and distributed for a century.
Mr. Drajem may be contacted at mdrajem@bloomberg.net; Ms. Newkirk may be contacted at mnewkirk@bloomberg.net
Read the court decisionRead the full story...Reprinted courtesy of
Mark Drajem and Margaret Newkirk, Bloomberg
A Sample Itinerary to get the Most out of West Coast Casualty’s Construction Defect Seminar
May 03, 2018 —
Beverley BevenFlorez-CDJ STAFFWith so many worthwhile events stretched across three days, as well as wanting to get out and explore the many attractions in Orange County, California, Construction Defect Journal has come up with a sample itinerary that balances work with recreation.
Day One: Wednesday, May 16th
9:00 a.m. – Breakfast at
Steakhouse 55 (Disneyland Hotel)
Meet up with colleagues at Disney’s Steakhouse 55 where you will find a more peaceful and upscale venue, perfect for networking or just catching up with friends.
10:00 a.m. -
Madara Spa at Disney’s Grand Californian Hotel
With a free morning, this is the perfect time to take advantage of one of the Disneyland Resort’s pools or schedule a massage at the Madara Spa located within the Grand Californian Hotel.
11:30 a.m. – Grab and Go Lunch at
The Coffee House (Disneyland Hotel)
Refuel with a salad or sandwich from one of Disneyland Resort’s quick service restaurants.
12:00 p.m. – Seminar Registration and Schwag Hunting
Start heading over to the seminar to register and be one of the first to check out the amazing exhibitors and grab the free items they have to offer. You don’t want to miss BHA’s golf challenge, where if you sink a putt you win a $25 Amazon gift card for yourself and BHA will match the $25 to the worthwhile WCC charities!
1:00 p.m. – Seminar Begins!
The afternoon starts with a not-to-be-missed panel, “Struggles and Successes of the Past 25 Years.” Next, you’ll learn about “Unwrapped and Unraveled - An insightful (or inciteful?) play at the
changing nature of the relationships between the parties in a wrap program who thought the wrap was supposed to take care of everything.”
3:00 p.m. – Afternoon Break
Get a cup of coffee or water, and head out into the exhibit hall. Don’t forget to go to BHA’s booth to enter to win Dodger tickets.
3:30 p.m. – Seminar Panels Continue
The seminar returns with two more amazing panels: “East Coast Meets West Coast –Hot Construction Defect Issues and Coverage Cases from the Other Coast” and “How to Conduct Your Claim Investigation and Early Claims Handling To Avoid Bad Faith Traps.”
6:00 p.m. – Attend an After Party
After taking a few minutes to unwind and freshen up, go and network as well as have some at one of the reception’s thrown by attending firms. No after party? Head over to the
Uva Bar at Downtown Disney for a cocktail and some people watching.
8:00 p.m. - Late Dinner at
Catal Restaurant (Downtown Disney)
Enjoy a relaxing and sumptuous meal at Catal in Downtown Disney, one of the famed Patina Group’s restaurants.
Day Two: Thursday, May 17th
7:30 a.m. – Breakfast in the Exhibit Hall
Take advantage of West Coast Casualty’s free breakfast, and peruse more exhibits. Check out BHA’s data process collection process and discover meaningful cost improvements that translate to reduced billing while providing superior accuracy and credibility.
8:30 a.m. – Seminar Panels
The seminar returns with more panels you won’t want to miss: “Recent Important Appellate Decisions in California, Nevada, and Arizona” and “Litigating In The Western States - A Judge’s Perspective.”
10:30 a.m. – Morning Break
Grab a cup of coffee or water and chat with your colleagues about the panels you just heard.
10:45 a.m. – Seminar Panel
Another important panel to finish the morning, “Subrogation is not the type of intervention I need. How a subrogated insurer affects construction defect matters.”
11:45 a.m. – Award Presentation
Find out this year’s winners of the Ollie, Legend of the Era and Silver Stars.
12:15 p.m. – WCC Luncheon
Network and chat with your colleagues at one of the meals provided by the seminar.
1:30 p.m. – Seminar Panel
Now that you’ve recharged, you’re ready for another incredible WCC panel: “What Comes Around (Sometimes) Goes Around: Dealing with Recalcitrant Carriers.”
2:30 p.m. – Afternoon Break
Stretch your legs in the exhibit hall and get yourself more schwag. Learn about BHA’s expanding market presence and full range of services in Texas, Florida, and across the Southeast United States.
3:00 p.m. – Seminar Panels Continue
Don’t miss the last two panels of the day: “Effective Use of Experts” and “Claims Managers Speak - A Retrospective & Prospective Discussion.”
5:30 p.m. – Cocktail Reception
With your glass of Cabernet, network with colleagues and then try your hand again at BHA’s golf challenge to win an Amazon gift card and earn money for WCC charities.
6:30 p.m. – Hit the Pool or Jacuzzi
Take those tired feet and soak them in one of the Disneyland Resort’s many pools and jacuzzi’s. Or schedule a spa treatment at
Madara in the Grand Californian Hotel.
7:00 p.m. – After Party or Ball Game
Now that you’ve given yourself some time to rejuvenate, you’re ready to meet up with friends and colleagues at one of the after parties and receptions. Or if you’re a sports fan and want a break from work, go cheer on the
Angel’s as they play Tampa Bay.
8:30 p.m. –
Uva Bar
Unless you chose to go to the game, enjoy a late supper and cocktail under the beautiful southern California sky at the Uva Bar in Downtown Disney.
Day Three: Friday, May 18th
7:30 a.m. – Breakfast at the Seminar
Take advantage of another free meal, and take the time to check out more exhibits as the last day of the seminar begins. Don’t forget to enter BHA’s raffle for Dodger tickets!
8:30 a.m. – Breakout Sessions I
Choose between one of three breakout sessions: “Known Knowns and Known: Unknowns, the Ins and Outs of Extrapolation,” “Risk Transfer Alphabet Soup - A twelve year lookback on legislative tinkering with anti-indemnity statutes - where are we now?” or “Florida – Opening Pandora's Box and How to Close It.”
9:30 a.m. – Breakout Sessions II
Three additional breakout sessions to choose from: “An Update on California’s Right to Repair Act, featuring McMillin Albany et al. v. Superior Court,” “Finding Evidence for your Coverage Case,” or “Northwest Insurance Coverage and Extra-Contractual Issues.”
10:30 a.m. – Morning Break
Refuel with coffee or water before the next group of exciting breakout sessions begins.
11:00 a.m. – Breakout Sessions III
You’ll want to go to one of these three breakout sessions: “Subcontractor Wars: The Last AI,” “Mediating the Luxury Single Family Home Construction Defect Case,” or “Creative Solutions to the Florida Problem: Making No Contribution and No State Law Work for You.”
12:00 p.m. – Breakout Sessions IV and the End of the Seminar
The seminar closes with the last trio of breakout sessions: “Everyone is a Small Player,” “Real World Solutions to the Real Problems Presented By Wrap Up Programs,” or “When Mother Nature Attacks, Are you Covered?”
1:30 p.m. – Lunch at
Corn Dog Castle in California Adventure Park OR
Hollinghead’s Delicatessen in Orange
If you’re a Disney lover, you’ll want to take advantage of the day by going to one of the Disney Resort Parks, of course. Get one of Disney’s amazing corn dogs at Corn Dog Castle in California Adventure Park.
Or if you would rather explore the greater Anaheim area, then head over to Hollinghead’s Delicatessen for a homemade sandwich and a glass of beer on tap.
3:00 p.m. –
Disney Entertainment OR Museum Exploring
If you chose to go to California Adventure, check out the event schedule for the day. Catch the show Frozen – Live at the Hyperion or get a
Fastpass for the Radiator Springs Racers and ride Soarin’ Around the World. If you purchased a two-park pass, don’t forget about Space Mountain or Star Tours located in the Disneyland Park.
North Orange county has many interesting museums. Head to the
Bowers Museum in Santa Ana or the
Muzeo in Anaheim.
7:00 p.m. – Dinner at the
Blue Bayou Restaurant OR the
Summit House Restaurant
Have a one-of-a-kind eating experience at the Blue Bayou in Disneyland Park. Enjoy a dinner in the midst of the Pirates of the Caribbean ride! If you wish to remain in the California Adventure Park, try an alfresco dinner at
Wine Country Trattoria or an indoor, upscale meal at
Carthay Circle.
After an afternoon perusing museums, enjoy a truly superb meal with attentive service at one of Anaheim’s premier restaurants, Summit House. Feeling like having some fun rather than a sedate meal? Head over to the
House of Blues in Anaheim for their Party Like It’s 1999! A Prince Tribute Party.
8:30 p.m. – Paint the Night Parade/Together Forever OR The Blind Rabbit Speakeasy
Head over to watch the
Paint the Night Parade at the California Adventure Park or the fireworks display,
Together Forever — A Pixar Nighttime Spectacular at the Disneyland Park. Be sure to check out the daily
event schedule for up to date information.
End your evening at Anaheim’s only speakeasy,
the Blind Rabbit, located in the Anaheim Meat Packing district. Be sure to check out their “rules” and reserve a table at this popular spot.
Read the court decisionRead the full story...Reprinted courtesy of
