CAMBRIDGE MASSACHUSETTS BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Pacing in Construction Scheduling Disputes

September 14, 2017 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway. However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

---

Tacoma Construction Site Uncovers Gravestones

August 11, 2011 — CDJ STAFF

The Seattle Times reports that a transit construction project has uncovered about twenty-five gravestones. The area was historically sensitive, as it is in territory once occupied by the Puyallup Tribe. At current report, no human remains have been found and the article cites the project?s archeological consultant as describing the gravestones as “not historically significant.”

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

---

Certificates of Merit: Is Your Texas Certificate Sufficient?

January 22, 2024 — Gus Sara - The Subrogation Strategist
In Eric L. Davis Eng’g, Inc. v. Hegemeyer, No. 14-22-00657-CV, 2023 Tex. App. LEXIS 8899, the Court of Appeals of Texas (Court of Appeals) considered whether the plaintiffs’ certificate of merit, in support of their professional malpractice claim against the defendant engineers, adequately set forth the experience and qualifications of the expert who submitted the certificate. The defendants filed a motion to dismiss, alleging that the certificate of merit was inadequate because it failed to establish that the expert practiced in the same specific areas as the defendants in relation to the work at issue. The lower court denied the defendants’ motion. The Court of Appeals affirmed the lower court’s decision, finding that there was sufficient information for the lower court to have reasonably found that the plaintiffs’ expert practiced in the same area as the defendants. In Hegemeyer, the plaintiffs sued Eric L. Davis Engineering, Inc. (Davis) and Kenneth L. Douglass (Douglass), alleging improper design of their home’s foundation. The plaintiffs retained Davis to design and engineer the home and Douglass prepared the plans for the home. The plans called for the installation of post-tension cables in the home’s foundation. The plaintiffs alleged that the foundation design was improper and brought professional malpractice claims against Davis and Douglass. Read the court decision
Read the full story...
Reprinted courtesy of Gus Sara, White and Williams
Mr. Sara may be contacted at sarag@whiteandwilliams.com

---

Client Alert: Release of Liability Agreement Extinguishes Duty of Ordinary Care

February 05, 2015 — R. Bryan Martin and Whitney L. Stefko – Haight Brown & Bonesteel LLP
On January 27, 2015, the California Court of Appeal, Fourth Appellate District, in Eriksson v. Nunnink (Case No. E057158), held a release of liability between Decedent and Defendant was enforceable as a defense to the Decedent's Parents' wrongful death and negligent infliction of emotional distress ("NIED") claims. In Eriksson, the Court concluded that on the basis of the signed release agreement, Defendant did not owe a duty of care to Decedent and thus could only be liable for Decedent's death if caused by the Defendant's gross negligence. The Court held that Plaintiffs failed to establish gross negligence and affirmed the lower court's judgment. Reprinted courtesy of Haight Brown & Bonesteel LLP attorneys R. Bryan Martin and Whitney L. Stefko Mr. Martin may be contacted at bmartin@hbblaw.com; Ms. Stefko may be contacted at wstefko@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Excess Insurer On The Hook For Cleanup Costs At Seven Industrial Sites

August 28, 2018 — Lorelie S. Masters & Geoffrey B. Fehling - Hunton Insurance Recovery Blog
A New York district court has held that an insurer must provide coverage under three excess insurance policies issued in 1970 for defense and cleanup costs incurred by Olin Corporation in remediating environmental contamination at seven sites in Connecticut, Washington, Maryland, Illinois, New York, and Washington. Seven of the remaining sites at issue presented questions of fact for trial, with only one site being dismissed due to lack of coverage. Reprinted courtesy of Lorelie S. Masters, Hunton Andrews Kurth and Geoffrey B. Fehling, Hunton Andrews Kurth Ms. Masters may be contacted at lmasters@HuntonAK.com Mr. Fehling may be contacted at gfehling@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

---

SkenarioLabs Uses AI for Property Benchmarking

December 04, 2018 — Aarni Heiskanen - AEC Business
AI continues to be a hot topic across industries. The PropTech startup SkenarioLabs has a data analytics solution that utilizes AI. The results have been successful from the perspective of property owners: reliable technical surveys that contribute to making smart investment decisions. Topi TiihonenWhile automatic valuation is not a recent invention for property owners and investors, there has not previously been an available service that combines it with technical surveying. SkenarioLabs has been building a system that digitizes technical surveys in order to help property owners manage their properties. The algorithm extracts a property’s technical risk from the market value. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

---

Managing Narrative, Capturing Context, and Building Together: Talking VR and AEC with David Weir-McCall

October 19, 2020 — Aarni Heiskanen - AEC Business
We sat down with David Weir-McCall of Epic Games to discuss the role VR plays in the modern AEC ecosystem. Our conversation covered the power of merging digital innovation with human insight, the importance of accessible data visualization, and the role that the Unreal platform plays across a range of sectors every day. Can you tell us a little bit about your career to date and what drove you to merge architectural design with tech dev? Sure – I initially studied architecture and. after graduation, was looking at what I wanted to work on. What really interested me was big, complex, and large-scale projects because of the degree of challenge. So, I ended up heading out to the Middle East for seven and a half years and worked in a variety of multidisciplinary firms. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

---

While Starts Fall, Builder Confidence and Permits are on the Rise

June 17, 2015 — Beverley BevenFlorez-CDJ STAFF
The National Association of Home Builders’ (NAHB) Eye on Housing reported that “the NAHB/Wells Fargo Housing Market Index and the expansion of housing permits, suggest more growth ahead.” While the Census Bureau and HUD reported that housing starts in May declined 11.1%, Eye on Housing points to a positive sign in that building permits were up 11.8% in the same month. Read the court decision
Read the full story...
Reprinted courtesy of

---