Fairfield Connecticut Building Expert Directory

A Court-Side Seat: Flint Failures, Missed Deadlines, Toad Work and a Game of Chicken

October 05, 2020 — Anthony B. Cavender - Gravel2Gavel
The last few weeks have yielded a number of interesting developments in the Federal courts. FEDERAL COURTS OF APPEAL In re Flint Water Cases Several local and State of Michigan officials, including the former governor, requested dismissal from the civil litigation seeking damages for the massive failure of Flint, Michigan’s public drinking water system. On August 5, 2020, the U.S. Court of Appeals for the Sixth Circuit agreed that the plaintiffs, residents of Flint, have successfully pled a case that the conduct of the defendants so “shocked the conscience” that a claim for a violation of their substantive due process rights was appropriately alleged. The defendants, including the former governor, argued that they were entitled to a qualified immunity defense. The court rejected this argument on the basis of the earlier decisions made by the court in this matter. Judge Sutton concurred because he was bound by this precedent, but remarked that the evidence for the governor’s culpability was very thin; he was not intimately connected to the extraordinary error in judgment. The majority was very upset with this concurrence as indicted by their own opinion. Read the court decision
Read the full story...
Reprinted courtesy of Anthony B. Cavender, Pillsbury
Mr. Cavender may be contacted at anthony.cavender@pillsburylaw.com

Persimmon Offers to Fix Risky Homes as Cladding Crisis Grows

February 22, 2021 — Olivia Konotey-Ahulu - Bloomberg
Persimmon Plc, the U.K.’s biggest homebuilder, has offered to pay for work on potentially unsafe buildings in the wake of the cladding scandal that arose from London’s Grenfell Tower fire. The firm has made a provision of 75 million pounds ($104 million) in its 2020 results for any necessary repair work on 26 buildings it developed that may be affected by the issue, it said in a statement Wednesday. It no longer owns the properties and said it would provide support where owners failed to accept their legal responsibilities. “The concern around now banned cladding is affecting many thousands of homeowners who live in high-rise buildings right across the country,” Chairman Roger Devlin said in the statement. “We believe we have a clear duty to act to address this issue.” Read the court decision
Read the full story...
Reprinted courtesy of Olivia Konotey-Ahulu, Bloomberg

The Pandemic of Litigation Sure to Follow the Coronavirus

March 30, 2020 — Aaron Lovaas - Newmeyer Dillion
As the Coronavirus crisis persists, America’s richly diverse private business sector finds itself increasingly subject to unprecedented governmental orders and restrictions that were unheard of only a few weeks ago. While the various “shutdown,” “shelter in place,” and “non-essential business” orders all aim to protect the public health, there is no doubt that the wave of litigation to follow is already swelling. Business interruption, civil authority, and cyber insurance coverages have already been widely discussed as issues certain to be litigated over the coming months and beyond. Additionally, breach of contract litigation is likely to spike as parties attempt to recoup their losses from canceled events, unfulfilled purchase commitments and other unmet obligations. Moreover, regional and national businesses are now in the difficult position of managing their respective affairs to comply with a patchwork of executive orders that are inconsistent from state to state. And, as the pandemic wears on, many are questioning the authority under which some of these executive orders and emergency regulations are being issued in the first place. Indeed, constitutional challenges are almost certain to follow as the business community reframes the characterization of their losses into notions of unconstitutional takings of private property and governmental impairment of private contract rights. Read the court decision
Read the full story...
Reprinted courtesy of Aaron Lovaas, Newmeyer Dillion
Mr. Lovaas may be contacted at aaron.lovaas@ndlf.com

Coverage Denied for Ensuing Loss After Foundation Damage

February 07, 2014 — Tred R. Eyerly – Insurance Law Hawaii
The insureds attempt to secure coverage for ensuing losses after foundation damage was properly denied by the insurer. Walker v. Nationwide Prop. & Cas. Ins. Co., 2014 U.S. Dist. LEXIS 6683 (W.D. Tex. Jan. 6, 2014). Two provisions excluding coverage under Nationwide's homeowner's policy were key to the court's decision. Exclusion 3 (e) barred coverage for "continuous or repeated seepage or leakage of water or stem over a period of time . . . ." Exclusion 3 (f) (6) precluded coverage for settling, cracking, shrinking, bulging or expansion of pavements, patios, foundations, walls, floors, roof or ceiling. The policy also included a Dwelling Foundation Endorsement which covered settling, cracking, bulging of floor slabs or footings that supported the dwelling caused by seepage or leakage of water or steam. This endorsement stated the limit of liability would not exceed an amount equal to 15% of the limit of coverage for the dwelling. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Business Solutions Alert: Homeowners' Complaint for Breach of Loan Modification Agreement Can Proceed Past Pleading Stage

October 08, 2014 — Krsto Mijanovic, Annette Mijanovic, Blythe Golay - Haight Brown & Bonesteel LLP
In Fleet v. Bank of America, N.A. (No. G050049, published 9/23/14, filed 8/25/14), a California Court of Appeal held that the trial court erred in sustaining the demurrer of a lender, where the homeowners had adequately alleged causes of action for breach of contract, fraud, and promissory estoppel. The homeowners alleged that they made timely payments during the trial period plan under the modification program, but before the last payment was due, the lender foreclosed and their house was sold. The homeowners had applied for a loan modification and were approved for a trial period plan under the modification program. They were required to make three monthly payments and verify financial hardship to permanently modify their loan. The homeowners made two payments and were told that foreclosure proceedings had been suspended. But before the third payment was due, the lender foreclosed. The trial court found that the trial period plan was not a binding loan modification agreement, so the homeowners had no right to any guaranteed loan modification. Reprinted courtesy of Haight Brown & Bonesteel LLP attorneys Krsto Mijanovic, Annette Mijanovic and Blythe Golay Mr. Mijanovic may be contacted at kmijanovic@hbblaw.com Ms. Mijanovic may be contacted at amijanovic@hbblaw.com Ms. Golay may be contacted at bgolay@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Super Lawyers Selects Haight Lawyers for Its 2024 Southern California Rising Stars List

February 05, 2024 — Haight Brown & Bonesteel LLP
Congratulations to the following Haight attorneys who were selected to the 2024 Southern California Rising Stars list:

Kyle DiNicola
Patrick McIntyre
Kathleen Moriarty
Kristian Moriarty
Austin Smith

Each year, no more than 2.5 percent of the lawyers in the state are selected by the research team at Super Lawyers to receive this honor. Super Lawyers, part of Thomson Reuters, is a rating service of outstanding lawyers from more than 70 practice areas who have attained a high degree of peer recognition and professional achievement. The annual selections are made using a patented multiphase process that includes a statewide survey of lawyers, an independent research evaluation of candidates and peer reviews by practice area. The result is a credible, comprehensive and diverse listing of exceptional attorneys. The Super Lawyers lists are published nationwide in Super Lawyers magazines and in leading city and regional magazines and newspapers across the country. Super Lawyers magazines also feature editorial profiles of attorneys who embody excellence in the practice of law. Read the court decision
Read the full story...
Reprinted courtesy of Haight Brown & Bonesteel LLP

Virginia Decision Emphasizes Importance of Naming All Necessary Parties

June 17, 2015 — Beverley BevenFlorez-CDJ STAFF
Nate Budde on the Construction Payment Blog, discussed the potential of mechanics liens, and the pitfalls that occur when not all necessary parties are named. Budde analyzed the case Johnson Controls Inc. v. Norair Eng’g Corp. that involved a “claimant’s failure to name all the necessary parties in his claim against a bond,” resulting “in the claimant losing his claim against the bond, and with it, an opportunity to get paid.” Budde concluded, “Unfortunately, as was the case here, when the bond claim is not handled correctly procedurally, a party can be left with no recourse for payment. It’s important to understand which of the parties involved should be named in both mechanics lien claims and bond claims.” Read the court decision
Read the full story...
Reprinted courtesy of

Formal Request for Time Extension Not Always Required to Support Constructive Acceleration

April 25, 2022 — David Adelstein - Florida Construction Legal Updates
Does a constructive acceleration claim require the contractor to always request an extension of time which is then denied by the owner? While this is certainly the preference and the contractor should be requesting an extension of time as a matter of course for an excusable delay, the answer is NO! in certain circumstances. This is conveyed in the factually detailed case discussed below where a formal request for an extension of time was not required for the contractor to support its constructive acceleration claim. But first, what is constructive acceleration: Constructive acceleration “occurs when the government demands compliance with an original contract deadline, despite excusable delay by the contractor.” The Federal Circuit in Fraser defined the elements of constructive acceleration as follows: (1) that the contractor encountered a delay that is excusable under the contract; (2) that the contractor made a timely and sufficient request for an extension of the contract schedule; (3) that the government denied the contractor’s request for an extension or failed to act on it within a reasonable time; (4) that the government insisted on completion of the contract within a period shorter than the period to which the contractor would be entitled by taking into account the period of excusable delay, after which the contractor notified the government that it regarded the alleged order to accelerate as a constructive change in the contract; and (5) that the contractor was required to expend extra resources to compensate for the lost time and remain on schedule. Nova Group/Tutor-Saliba v. U.S., 2022 WL 815826, *42 (Fed.Cl. 2022) quoting Fraser Constr. Co. v. U.S., 384 F.3d 1354, 1361 (Fed. Cir. 2004) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES