Fairfield Connecticut Building Expert Directory

Reasonableness of Liquidated Damages Determined at Time of Contract (or, You Can’t Look Back Again)

October 05, 2020 — Christopher G. Hill - Construction Law Musings
I’ve discussed the continuing litigation between White Oak Power Constructors v. Mitsubishi Hitachi Power Systems Americas, Inc. previously here at Construction Law Musings because the case was another reminder that your construction contract terms matter and will be interpreted strictly here in the Commonwealth of Virginia. The prior opinion in this case from the Eastern District of Virginia court the Court considered the applicability of a liquidated damages provision. In the latest opinion from the Court (PDF) the Court looked at when and how any liquidated damages would be calculated. In its June 22, 2020 opinion, the Court put the issue as follows:

White Oak’s motion for partial summary judgment presents a narrow issue: whether courts may consider the damages actually sustained by a party as a result of a contract breach when deciding if liquidated damages required by a contract “grossly exceed” a party’s actual damages.

Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

A Quick Virginia Mechanic’s Lien Timing Refresher

February 27, 2023 — Christopher G. Hill - Construction Law Musings
As those who read Construction Law Musings on a regular basis know, mechanic’s liens are a big part of my construction law practice. These tricky and strictly enforced statutory collection tools are very powerful when correctly recorded and utterly useless if they aren’t recorded in a timely fashion and with the correct information contained within them. Couple that fact with recent changes to the mechanic’s lien form in 2019, and I feel the need to give a quick refresher. If you’ve kept up with Musings, you know about the two big numbers for Virginia mechanic’s lien timing, 90 and 150. These should be kept in mind for every general contractor, subcontractor, or supplier on any construction project in Virginia. Virginia Code Section 43-4 sets out the reasons to keep these numbers in mind. The code section sets out why you need to know these numbers. The 90 refers to the deadline for recording a lien. This number affects the right to a lien in Virginia. In order to preserve lien rights, a construction contractor must record the lien within ninety days of the last day of the last month in which the last work was performed or no later than ninety days from the date of completion of the project or other termination of work. The short version is that most general contractors on commercial projects have 90 days from the last work in which to record their lien and most subcontractors have 90 days from the last day of the last month of work. However, the best practice is to simply calculate the 90 days from the last work performed or material supplied to avoid issues and arguments between attorneys regarding timing. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

U.S. Supreme Court Limits the Powers of the Nation’s Bankruptcy Courts

June 11, 2014 — Earl Forte – White and Williams LLP
On June 9, 2014, the Supreme Court of the United States issued its much-awaited decision in Executive Benefits Insurance Agency v. Arkison, Chapter 7 Trustee of Estate of Bellingham Insurance Agency, Inc., Case No. 12-1200, in which the court confirmed that the power of the nation’s bankruptcy courts to hear and decide cases involving state-created private rights in which the bankruptcy proof of claim process has not been directly invoked, is severely limited by Article III of the Constitution of the United States. The decision in Executive Benefits, while providing some clarity to practitioners and the public following the Court’s June 2011 decision in Stern v. Marshall, 131 S. Ct. 2594 (2011), nevertheless will make a substantial portion of bankruptcy litigation matters more cumbersome and potentially more expensive to guide through the bankruptcy system. Clients and practitioners are best advised to hire knowledgeable counsel to help navigate the more complex procedural waters created by this decision. Although the Court in Executive Benefits did resolve a pending procedural question that had dogged practitioners since Stern was decided in 2011, the Court’s decision in Executive Benefits now makes it abundantly clear that many disputes that were previously heard and decided in the nation’s bankruptcy courts can no longer be decided there and must be submitted to the district courts for full de novo review and entry of a final judgment or order. It is difficult to see how this decision will not make bankruptcy litigation more cumbersome and expensive by adding an additional layer of judicial involvement to many matters, notably to fraudulent transfer and other avoidance “claw back” actions that historically have been decided in the bankruptcy courts and used famously in Madoff and other cases as an efficient device for creating value for creditors. Read the court decision
Read the full story...
Reprinted courtesy of Earl Forte, White and Williams LLP
Mr. Forte may be contacted at fortee@whiteandwilliams.com

Worker’s Compensation Exclusivity Rule Gets “Trumped” by Indemnity Provision

October 27, 2016 — Garret Murai – California Construction Law Blog
Sorry, I couldn’t help myself with the title. The next case, Aluma Systems Concrete Construction of California v. Nibbi Bros., Inc., California Court of Appeals for the First District, Case No. A145734 (August 16, 2016), discusses the interplay between indemnity provisions and the worker’s compensation exclusivity rule. The worker’s compensation exclusivity rule generally provides that worker’s compensation insurance is the exclusive remedy of employees for injuries or death arising out of the course and scope of their employment. In the Aluma case, the California Court of Appeals, addressed what happens when a subcontractor’s employees are injured on a project, sue the general contractor, and the general contractor, pursuant to an indemnity provision in its subcontract, tenders the claim to the subcontractor whose worker’s compensation insurance has already paid the employees. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Wendel Rosen Black & Dean LLP
Mr. Murai may be contacted at gmurai@wendel.com

Pennsylvania Supreme Court Adopts New Rule in Breach-of-the-Consent-to-Settle-Clause Cases

August 19, 2015 — Sean Mahoney – White and Williams LLP
In Babcock & Wilcox Company, et al. v. America Nuclear Insurers, et al., the Pennsylvania Supreme Court recently held that where a liability insurer has agreed to provide a defense to its insured in an underlying tort action subject to a reservation of rights but refuses to consent to a settlement in that action, the insured may nevertheless accept the settlement over the insurer’s objection where the settlement is “fair, reasonable, and non-collusive” from the perspective of a reasonably prudent person in the insured’s position in light of the totality of the circumstances and is covered. Babcock & Wilcox Company v. America Nuclear Insurers, No. 2 WAP 2014, 2015 WL 4430352 (Pa. Jul. 21, 2015). This decision fills an important gap in Pennsylvania precedent addressing the rules applicable when an insurer refuses to consent to an insured’s settlement of a lawsuit. In Babcock, the underlying plaintiffs sued Babcock & Wilcox Company and Atlantic Richfield Company (“the Insureds”) alleging that the Insured’s nuclear facilities caused bodily injury and property damage. The Insureds’ liability insurers agreed to defend the Insureds subject to a reservation of rights. The insurers later refused to consent to an offer to settle the underlying action for a total of $80 million because they believed the Insureds were likely to succeed on the merits. Nevertheless, in 2009, the Insureds accepted that offer and settled the underlying action for $80 million, notwithstanding the insurer’s refusal. The Insureds then sought reimbursement of the $80 million settlement from their insurers, who rejected that request on the ground that the Insureds had breached the consent-to-settlement/cooperation provisions of the implicated policies. Read the court decision
Read the full story...
Reprinted courtesy of Sean Mahoney, White and Williams LLP
Mr. Mahoney may be contacted at mahoneys@whiteandwilliams.com

Disappointment on an Olympian Scale After Rio 2016 Summer Games

February 23, 2017 — Augusto Diniz, O Empreiteiro - Engineering News-Record
The single word to describe the sports infrastructure created for the Rio 2016 Olympic Games is abandonment. Uncertainty over the future of the dilapidated sports stadiums and arenas threatens the legacy of the Olympics, which ended five months ago. Read the court decision
Read the full story...
Reprinted courtesy of Augusto Diniz, O Empreiteiro, ENR
ENR may be contacted at ENR.com@bnpmedia.com

Failure to Comply with Contract Leaves No Additional Insured Coverage

January 07, 2015 — Tred R. Eyerly – Insurance Law Hawaii
Indemnity obligations and additional insured coverage were at issue in Strauss Painting, Inc. v. Mt. Hawley Ins. Co., 2014 N.Y. LEXIS 3347 (N.Y. Nov. 24, 2014). Strauss Painting, Inc. (Strauss) contracted with the Metropolitan Opera Association, Inc. (the Met) to strip and repaint the rooftop steel carriage track for the opera house's automated window-washing equipment. The contract provided that Strauss would indemnify and hold the Met harmless. Exhibit D to the contract set forth three types of insurance that Strauss was to procure: (1) workers' compensation; (2) owners and contractors protective liability (OCP); and (3) comprehensive general liability. The OCP policy was to add the Met as an additional insured. Strauss failed to obtain the OCP policy. At the time it contracted with the Met, Strauss had a CGL policy issued by Mt. Hawley. The policy's additional insured endorsement (ICO form CG 20 33 07 04) stated that "an insured" included "any organization for whom Strauss is performing operations when Strauss and such organization have agreed in writing that such organization be added as an additional insured." Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Rio de Janeiro's Bursting Real-Estate Bubble

September 17, 2015 — Juan Pablo Spinetto & Peter Millard – Bloomberg
At opposite ends of downtown Rio de Janeiro, projects tied to Donald Trump and Eike Batista-- one a billionaire-turned-politician, the other Brazil’s most famous ex-billionaire -- have come to represent the city’s real estate bust. The 23-story Serrador building, a granite-and-glass art deco tower near Rio’s Santos Dumont airport, has sat empty since Batista’s failed empire of commodities companies abandoned it last year. Four miles away, in the city’s gritty port district, an ambitious office project that Trump lent his name to is still nothing more than a weed-filled lot about a year after construction was slated to begin. Reprinted courtesy of Juan Pablo Spinetto, Bloomberg and Peter Millard, Bloomberg Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES