Fairfield Connecticut Building Expert Directory

Is the Event You Are Claiming as Unforeseeable Delay Really Unforeseeable?

September 26, 2022 — David Adelstein - Florida Construction Legal Updates
Is the item or event you are claiming as an unforeseeable, excusable delay really unforeseeable? This is not a trick question. Just because your construction contract identifies items or events that constitute unforeseeable, excusable delay does not mean those items can be used as a blanket excuse or crutch for the contractor. That would be unfair. For instance, it is not uncommon for a construction contract to list as unforeseeable, excusable delay the following events or items: “(i) acts of God or of the public enemy, (ii) act of the Government in either its sovereign or contractual capacity, (iii) acts of another Contractor in the performance of a contract with the Government, (iv) fires, (v) floods, (vi) epidemics, (vii) quarantine restrictions, (viii) strikes, (ix) freight embargoes, (x) unusually severe weather, or (xi) delays of subcontractors or suppliers at any tier arising from unforeseeable causes beyond the control and without the fault or negligence of both the Contractor and the subcontractors or suppliers.” See, e.g., F.A.R. 52.249-10(b)(1). While the itemization of excusable delay may be worded differently, the point is there may be a listing as to what items or events constitute excusable delay. An excusable delay would justify additional time and, potentially, compensation to the contractor. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Business Interruption Claim Granted in Part, Denied in Part

February 16, 2016 — Tred R. Eyerly – Insurance Law Hawaii
The court granted portions of the business interruption claim, while denying other portions. Phoenix Ins. Co. v. Infogroup, Inc., 2015 U.S. Dist. LEXIS 162810 (S. D. Iowa Nov. 30, 2015). Phoenix insured Infogroup's business buildings and personal business property, including data and data processing equipment. In late May 2011, warnings were issued of possible flooding from the Missouri River. On June 1, 2011, Infogroup moved and relocated its business operations and data centers away from the river and did not intend to return to the facilities. On July 19, 2011, Phoenix advanced $500,000 to Infogroup for anticipated claims under the policy. On August 22, 2011, heavy rain left surface water in the parking lot at Infogroup's facilities. Infogroup claimed that it suffered minor property damage during July and August, 2011, including damage to an uninterruptable power source and damage to a server. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Amada Family Limited Partnership v. Pomeroy: Colorado Court of Appeals Expressly Affirms the Continuing Viability of the Common-Law After-Acquired Title Doctrine and Expressly Recognizes Utility Easements by Necessity

June 28, 2021 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On May 27, 2021, a division of the Colorado Court of Appeals issued its opinion in Amada Family Limited Partnership v. Pomeroy, 2021 COA 73. In that case, the court decided two significant issues that apparently had never been expressly ruled on by a Colorado appellate court before: (1) that Colorado’s common-law after-acquired title doctrine was not abrogated by adoption of the after-acquired interest statute; and (2) that utility easements may be implied by necessity. As is often the case in matters involving access and implied property rights, the facts and history underlying Amada are complicated, but the case’s two most significant rulings are not. Instead, the basic legal principles established (or confirmed) in Amada appear to be broadly applicable, and real property practitioners should take note of these significant developments (or clarifications) in the law. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

Florida’s Fourth District Appeals Court Clarifies What Actions Satisfy Florida’s Construction Defect Statute of Repose

November 14, 2018 — Rahul Gogineni - The Subrogation Specialist
In Gindel v. Centex Homes, 2018 Fla.App. LEXIS 13019, Florida’s Fourth District Court of Appeal recently concluded that the date on which the plaintiffs provided a pre-suit notice in compliance with §558.004 of Florida’s construction defect Right-to-Cure statute, Fla. Stat. §§ 558.001 to 558.005, et. seq., is the date on which the plaintiff commenced a “civil action or proceeding,” i.e. an “action,” within the meaning of Florida’s construction defect statute of repose, Florida Statue § 95.11(3)(c). Thus, reversing the decision of the trial court, the Fourth District held that the plaintiffs timely-filed their construction defect action against the defendants. Read the court decision
Read the full story...
Reprinted courtesy of Rahul Gogineni, White and Williams LLP
Mr. Gogineni may be contacted at goginenir@whiteandwilliams.com

Wisconsin Supreme Court Holds that Subrogation Waiver Does Not Violate Statute Prohibiting Limitation on Tort Liability in Construction Contracts

October 21, 2019 — Gus Sara - The Subrogation Strategist
In Rural Mut. Ins. Co. v. Lester Bldgs., LLC 2019 WI 70, 2019 Wisc. LEXIS 272, the Supreme Court of Wisconsin considered whether a subrogation waiver clause in a construction contract between the defendant and the plaintiff’s insured violated Wisconsin statute § 895.447, which prohibits limitations of tort liability in construction contracts. The Supreme Court affirmed the lower court’s decision that the waiver clause did not violate the statute because it merely shifted the responsibility for the payment of damages to the defendant’s insurance company. The waiver clause did not limit or eliminate the defendant’s tort liability. This case establishes that while § 895.447 prohibits construction contracts from limiting tort liability, a subrogation waiver clause that merely shifts responsibility for the payment of damages from a tortfeasor to an insurer does not violate the statute and, thus, is enforceable. In Rural Mutual, the plaintiff’s insured, Jim Herman, Inc. (Herman), entered into a contract with Lester Buildings, LLC (Lester) to design and construct a barn on Herman’s property. The contract included a provision that stated the following: Both parties waive all rights against each other and any of their respective contractors, subcontractors and suppliers of any tier and any design professional engaged with respect to the Project, for recovery of any damages caused by casualty of other perils to the extent covered by property insurance applicable to the Work or the Project, except such rights as they have to the proceeds of such property insurance and to the extent necessary to recover amounts relating to deductibles of self-insured retentions applicable to insured losses. . . . This waiver of subrogation shall be effective notwithstanding allegations of fault, negligence, or indemnity obligation of any party seeking the benefit or production [sic] of such waiver. Read the court decision
Read the full story...
Reprinted courtesy of Gus Sara, White and Williams
Mr. Sara may be contacted at sarag@whiteandwilliams.com

KB Homes Sues Condo Buyers over Alleged Cybersquatting and Hacking

October 22, 2013 — CDJ STAFF
Willowbrook, a condominium complex in Lakewood Ranch, Florida has had problems with water intrusion. Now the builder is having problems with some of the residents. National home builder KB Homes is alleging that a pair of Willowbrook home owners who created a web site about their problems have violated federal cybersquatting laws, as the web site names they have registered are close to that KB Homes. The suit alleges that Andrew Smith and Daniel Koehler hope to either get KB Homes to purchase the web site or to buy back their homes. The lawsuit also alleges that three other individuals, William Crismon, Patrick McGettigan, and Armando Oyola-Delgado, conspired to intercept e-mails between KB Home and Dueall Construction. KB Homes claims that the three gained access to a WiFi hotspot used by Dueall. Read the court decision
Read the full story...
Reprinted courtesy of

Crisis Averted! Pennsylvania Supreme Court Joins Other Courts in Finding that Covid-19 Presents No Physical Loss or Damage for Businesses

October 21, 2024 — Edward M. Koch & Marc L. Penchansky - White and Williams LLP
Seeking to find some relief from business losses experienced during the COVID-19 pandemic, many businesses turned to their property insurers for coverage for their lost income. A clear national trend emerged among courts deciding the issue, as most businesses could not establish coverage because they had not experienced a “direct physical loss of or damage to their covered property” as required by most policies. While this legal question may have become an afterthought for many attorneys, the question remained an open one in Pennsylvania while the Pennsylvania Supreme Court considered two contradictory holdings issued in the Superior Court on this topic. Compare Macmiles, LLC v. Erie Ins. Exch., 286 A.3d 331 (Pa. Super. 2022) (holding there was no coverage for loss of use of a commercial property unaccompanied by any physical alteration or other physical condition that rendered the property unusable or uninhabitable) with Ungarean v. CNA, 286 A.3d 353 (Pa. Super. 2022) (holding that the policy at issue was ambiguous and therefore the policy covered the insured for COVID-related business losses). Last week, the Supreme Court considered the Superior Court’s holdings in Macmiles and Ungarean and held, at long last, that COVID-19 did not cause a direct physical loss of or damage to covered property. Reprinted courtesy of Edward M. Koch, White and Williams LLP and Marc L. Penchansky, White and Williams LLP Mr. Koch may be contacted at koche@whiteandwilliams.com Mr. Penchansky may be contacted at penchanskym@whiteandwilliams.com Read the court decision
Read the full story...
Reprinted courtesy of

Colorado Senate Revives Construction Defects Reform Bill

January 04, 2018 — BEVERLEY BEVENFLOREZ - CDJ STAFF
Originally Published by CDJ on March 1, 2017 A re-booted construction defects reform bill recently passed its first Senate committee, according to the Denver Business Journal. Next, Senate Bill 156, sponsored by Sen. Owen Hill, R-Colorado Springs, heads to the Senate floor for debate. SB 156 “would require that condominium owners alleging construction defects take their disputes to arbitration or mediation if requested by builders,” the Denver Business Journal reported. “It also would require that homeowners be informed of the consequences of filing legal actions over purported disputes and that a majority of all owners in a condominium complex vote to proceed with legal action, rather than just a majority of homeowners association board members.” However, it is almost identical to the failed measures that were introduced in 2014 and 2015. Homeowners association group members and owners of defective condominiums argued against the measure, stating “that the effort would not improve the quality of building in the state, but simply would block aggrieved Coloradans from taking their complaints before a jury of their peers.” Proponent of the bill, Tom Clark, CEO of Metro Denver Economic Development Corp., said “that Denver’s housing costs have risen since the first bill was introduced in 2013 to the sixth-most-expensive in the country – and are tops for any metro area not on a coast.” Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES