Fairfield Connecticut Building Expert Directory

County Sovereign Immunity Invokes Change-Order Ordinance

December 20, 2017 — Lizbeth Dison - AHC Contruction Law Blog
The recent case of Fulton County v. Soco Contracting Company, Inc. addresses two very interesting questions for local government attorneys. First, can a county ordinance bolster a defense of sovereign immunity against a contractor’s claims? Second, can a county waive sovereign immunity by failing to respond to Requests for Admission? Facts: County hired Contractor to construct a facility near the airport. The contract provided that change orders must satisfy a county ordinance, which required approval by the Board of Commissioners. But in emergency situations, the County Manager could approve change orders, as long as the contractor executes a proposed modification and the purchasing agent approves it. The project suffered substantial delays, which Contractor attributed to weather, design delays, delays by the County in providing decisions on changes, and delays in obtaining permits during the federal government’s shutdown. As a result of these issues, Contractor comes County changed the scope of the contract. Contractor asserted claims against County for the delays and the changes to the work. The appellate opinion addresses the change order claims. Read the court decision
Read the full story...
Reprinted courtesy of Lizbeth Dison, Autry Hall & Cook, LLP

A “Flood” of Uncertainty; Massachusetts SJC Finds Policy Term Ambiguous

August 26, 2024 — Michael S. Levine & Torrye Zullo - Hunton Insurance Recovery Blog
The highest court in Massachusetts recently held that term “Flood” and the associated phrase “surface waters,” as used in two all-risk insurance policies, is ambiguous in the context of water that accumulated on a parapet roof and rooftop courtyard, thereby negating the insurers’ attempt to limit coverage to a sublimited coverage for “Flood.” Background In June 2020, a severe storm caused damage to Norwood Hospital, owned by Medical Properties Trust, Inc. (“MPT”) and leased to Steward Health Care System (“Steward”), the policyholders. The relevant portion of the damage included damage from rain that accumulated on the rooftop courtyard and seeped into the interior of the building causing damage to the building and its contents. Reprinted courtesy of Michael S. Levine, Hunton Andrews Kurth and Torrye Zullo, Hunton Andrews Kurth Mr. Levine may be contacted at mlevine@HuntonAK.com Ms. Zullo may be contacted at tzullo@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

Five Types of Structural Systems in High Rise Buildings

November 02, 2020 — Chris Jackson - Construction Executive
Today, many cities in different countries have high-rise buildings or more popularly known as skyscrapers. The concept of skyscraper was first used to define the more than 137-foot-high buildings constructed in Chicago in 1885. It is generally defined as one that is taller than the maximum height that requires mechanical vertical transportation for people. Usually, these buildings only have limited uses and are primarily focused on functioning as residential apartments, hotels and office buildings, though they occasionally include retail and educational facilities. Because high-rise buildings are among the largest buildings built, it is necessary that their commercial and office functions require a high degree of flexibility. That’s why it is important for high-rise buildings to have structural systems or structural frames—the assembly of interrelated or interdependent elements that forms a complex structure. These structural systems are built and designed for resisting different loads. To further understand how structural systems work, take the human body as a comparison. If human bones are weak and not properly aligned, the human body as a whole will not be able to perform or work well. Structural systems, in the same way, would not be able to take loads if not built properly. After all, no one wants a toppling skyscraper. To give the readers more information about structural systems in high-rise buildings, this article will discuss some of them. Reprinted courtesy of Chris Jackson, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

California Precludes Surety from Asserting Pay-When-Paid Provision as Defense to Payment Bond Claim

December 21, 2020 — Nicholas Korst - Ahlers Cressman & Sleight PLLC
In a recent case in California, the Court of Appeals held that a surety who had issued a public works payment bond cannot rely on the “Pay-When-Paid” provision in the subcontract as a defense against the subcontractor’s claim against the payment bond.[1] The case was a public works project in Kern County, CA where the North Edwards Water District (the “District”) hired Clark Bros., Inc. (“Clark”) as the general contractor to build an arsenic removal water treatment plant. Clark hired subcontractor Crosno Construction (“Crosno”) to build and coat two steel reservoir tanks. The subcontract included the following “pay-when-paid” provision, which provided a definition of “reasonable time”: If the Owner or other responsible party delays in making any payment to the Contractor from which payment to Subcontractor is made, Contractor and its sureties shall have a reasonable time to make payment. “Reasonable time” shall be determined according to the relevant circumstances, but in no event shall be less than the time Contractor and Subcontractor require to pursue to conclusion their legal remedies against the Owner or other responsible party to obtain payment, including (but not limited to) mechanics lien remedies. (emphasis added). Read the court decision
Read the full story...
Reprinted courtesy of Nick Korst, Ahlers Cressman & Sleight PLLC
Mr. Korst may be contacted at nicholas.korst@acslawyers.com

Will Colorado Pass a Construction Defect Reform Bill in 2016?

December 17, 2015 — Beverley BevenFlorez-CDJ STAFF
According to blogger Jill Jamieson-Nichols of the Colorado Real Estate Journal, another construction defects bill may be debated in Colorado next year. Representative Dan Pabon told Jamieson-Nichols that “the answer lies in ‘thinking about the insurance piece’ so condominium developers can afford insurance against litigation that might arise.” She also stated that the city of Denver is considering ways to increase funding to increase affordable housing in the area. Read the court decision
Read the full story...
Reprinted courtesy of

Precast Standards' Work Under Way as Brittle Fracture Warnings Aired

December 22, 2019 — Nadine M. Post - Engineering News-Record
The American Concrete Institute is gearing up to develop ACI’s first code requirements specifically for precast concrete. The recent announcement of the initiative comes on the heels of an article in the September issue of ACI’s monthly magazine, Concrete International, that sounds the alarm about the potential for brittle failures of precast, prestressed-concrete double-T parking decks, with flanges reinforced with a non-code-compliant polymer-coated carbon-fiber grid product, called C-Grid. Reprinted courtesy of Nadine M. Post, Engineering News-Record Ms. Post may be contacted at postn@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

2025 Construction Law Update

January 07, 2025 — Garret Murai - California Construction Law Blog
It’s that time of year again. The second half of the 2023-2024 legislative session saw the introduction of 2,124 bills, of which, 1418 were signed into law. Among the bills signed by the governor impacting contractors is an increase in the small work licensing exemption for $500 to $1,000, the licensing of Indian tribes by the CSLB, and a number of project-specific bills, as is typical, related to project-specific alternative project delivery methods. Wishing you and yours a great 2025! Licensing AB 2622 – Increases the small work licensing exemption from $500 to $1,000 provided that the work: (1) does not require a building permit; and (2) does not involve the employment of others to perform or assist in the work. Read the court decision
Read the full story...
Reprinted courtesy of Garret Murai, Nomos LLP
Mr. Murai may be contacted at gmurai@nomosllp.com

Attorney Risks Disqualification If After Receiving Presumptively Privileged Communication Fails to Notify Privilege Holder and Uses Document Pending Privilege Determination by Court

May 03, 2017 — David W. Evans & Stephen J. Squillario - Haight Brown & Bonesteel LLP
In McDermott Will & Emery LLP v. Superior Court (4/18/2017 – No. G053623), the Fourth Appellate District, in a 2-1 decision, considered two distinct issues: 1. Whether the attorney-client privilege for a confidential e-mail communication between a client and his attorney had been waived by the client’s inadvertent disclosure of the communication to a third party; and 2. Whether the opposing counsel’s failure to respect the claimed privilege as to the inadvertently produced document or to follow the rules for handling such documents set forth in State Compensation Ins. Fund v WPS, Inc. (1999) 70 Cal.App.4th 644 (State Fund) supported the trial court’s disqualification of counsel and his law firm. This case arose from an intra-family dispute over the deceased matriarch’s substantial investment holdings, a related probate matter, and two subsequent legal malpractice actions. The opinion sets forth in great detail the facts surrounding the claimed inadvertent disclosure by the client (i.e., the privilege holder) of the subject attorney-client e-mail communication, its subsequent dissemination to, and use by, the client’s family members, the ultimate receipt and review by an opposing family member’s counsel, the efforts by the client’s counsel to assert the privilege and “claw-back” the document, and in the face of this privilege claim, the opposing counsel’s extensive use of the document during discovery, including depositions, in the legal malpractice actions. The opposing counsel, who had received the subject document from his own client, had independently concluded that the clearly privileged document lost its privileged status, believing that the privilege had been waived either because of disclosure to third parties or that his obligation to return inadvertently disclosed documents only applied to those produced in litigation during discovery. As a result, the opposing counsel refused all demands for the return or destruction of the document and insisted upon continuing to use it. This dispute finally came to a head over two years after the client’s disclosure in the context of the client’s motion for a judicial determination that the document was privileged (which the trial court granted) and then a motion to disqualify the opposing counsel (which the trial court also granted); both decisions were eventually reviewed by the appellate court. Reprinted courtesy of David W. Evans, Haight Brown & Bonesteel LLP and Stephen J. Squillario, Haight Brown & Bonesteel LLP Mr. Evans may be contacted at devans@hbblaw.com Mr. Squillario may be contacted at ssquillario@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES