Fairfield Connecticut Building Expert Directory

Policy's Operation Classification Found Ambiguous

May 21, 2014 — Tred R. Eyerly – Insurance Law Hawaii
Property damage caused by a subcontractor's sheet piling was found to be within the policy's operation classification, which included "grading of land." Canal Indemn. Co. v. Margaretville of NSM, Inc., No. 13-13541 (11th Cir. April 15, 2014). Canal issued a CGL policy to the insured. The policy had a classification limitation provision: “This insurance applies to bodily injury, property damage, personal injury, advertising injury or medical expense arising out of only those operations that are classified and shown on the Commercial General Liability Coverage Declarations . . .” The policy's Declarations, in turn, referred to the operation classification as "Grading of Land - INCL. Borrowing, Filling or Back Filling." The policy did not define these terms. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Does a No-Damage-for-Delay Clause Also Preclude Acceleration Damages?

January 27, 2020 — Ted R. Gropman & Christine Z. Fan - ConsensusDocs
Construction contracts often include a “no damage for delay” clause that denies a contractor the right to recover delay-related costs and limits the contractor’s remedy to an extension of time for noncontractor-caused delays to a project’s completion date. Depending on the nature of the delay and the jurisdiction where the project is located, the contractual prohibition against delay damages may well be enforceable. This article will explore whether an enforceable no-damage-for-delay clause is also a bar to recovery of “acceleration” damages, i.e., the costs incurred by the contractor in its attempt to overcome delays to the project’s completion date. Courts are split as to whether damages for a contractor’s “acceleration” efforts are distinguishable from “delay” damages such that they may be recovered under an enforceable no-damage-for-delay clause. See, e.g., Siefford v. Hous. Auth. of Humboldt, 223 N.W.2d 816 (Neb. 1974) (disallowing the recovery of acceleration damages under a no-damage-for-delay clause); but see Watson Elec. Constr. Co. v. Winston-Salem, 109 N.C. App. 194 (1993) (allowing the recovery of acceleration damages despite a no-damage-for-delay clause). The scope and effect of a no-damage-for-delay clause depend on the specific laws of the jurisdiction and the factual circumstances involved. There are a few ways for a contractor to circumvent an enforceable no-damage-for-delay clause to recover acceleration damages. First, the contractor may invoke one of the state’s enumerated exceptions to the enforceability of the clause. It is helpful to keep in mind that most jurisdictions strictly construe a no-damage-for-delay clause to limit its application. This means that, regardless of delay or acceleration, courts will nonetheless permit the contractor to recover damages if the delay is, for example, of a kind not contemplated by the parties, due to an unreasonable delay, or a result of the owner’s fraud, bad faith, gross negligence, active interference or abandonment of the contract. See Tricon Kent Co. v. Lafarge N. Am., Inc., 186 P.3d 155, 160 (Colo. App. 2008); United States Steel Corp. v. Mo. P. R. Co., 668 F.2d 435, 438 (8th Cir. 1982); Peter Kiewit Sons’ Co. v. Iowa S. Utils. Co., 355 F. Supp. 376, 396 (S.D. Iowa 1973). Reprinted courtesy of Ted R. Gropman, Pepper Hamilton LLP and Christine Z. Fan, Pepper Hamilton LLP Mr. Gropman may be contacted at gropmant@pepperlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Colorado Springs may be Next Colorado City to Add Construction Defects Ordinance

October 28, 2015 — Beverley BevenFlorez-CDJ STAFF
The Gazette reported that Colorado Springs city councilwoman Jill Gaebler stated that “she would bring a proposal to the council next month that would address the construction defects issue.” Gaebler told The Gazette: “We have gone back and forth with how best to address this issue. It is a statewide concern, so how do we bring forward something that is meaningful to our community without stepping on the toes of our legislators?” The state of Colorado has tried and failed to pass construction defects legislation three years in a row, according to The Gazette. If Colorado Springs adopts an ordinance, it will become the ninth city to pass construction defects laws. Read the court decision
Read the full story...
Reprinted courtesy of

Multiple Occurrences Found For Claims Against Supplier of Asbestos Products

May 07, 2015 — Tred R. Eyerly – Insurance Law Hawaii
The federal district court found that various claims for bodily injury against a supplier of asbestos products arose from multiple occurrences, increasing indemnity amounts available under the policy. Westfield Ins. Co. v. Continental Ins. Co., 2015 U.S. Dist. LEXIS 45437 (N.D. Ohio April 7, 2015). Mahoning Valley Supply Company (MVS) was sued by numerous claimants who alleged that they had been injured by asbestos-containing products manufactured by third parties, but supplied by MVS. The claimants alleged exposure to asbestos fibers at a variety of job sites, on numerous dates, and under a variety of conditions. Two insurers shared defense and indemnity costs. In 2013, Continental informed MVS that the three policies issued to MVS were nearly exhausted. Therefore, the parties disputed whether MVS' asbestos claims arose out of a single "occurrence" rather than multiple occurrences. The policies defined "occurrence" as "an accident, including continuous or repeated exposure to conditions, which results in bodily injury or property damage neither expected nor intended from the standpoint of the insured." Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Study Finds San Francisco Bay is Sinking Faster than Expected

July 15, 2019 — Alan Rider - Engineering News-Record
All coastal cities in the U.S. face some potential threat from sea-level rise, but areas around San Francisco Bay may be more vulnerable than previously thought according to a recent study by Arizona State University’s Manoochehr Shirzaei and UC Berkley’s Roland Bürgmann published in the peer-reviewed journal Science Advances. Read the court decision
Read the full story...
Reprinted courtesy of Alan Rider, ENR
ENR may be contacted at ENR.com@bnpmedia.com

Liability policy covers negligent construction: GA high court

October 31, 2010 — Michael Bradford in Business Insurance

ATLANTA—Negligent construction that results in damage to surrounding property constitutes an occurrence under a commercial general liability policy, the Georgia Supreme Court has ruled.

In a 6-1 opinion Monday in American Empire Surplus Lines Insurance Co. Inc. vs. Hathaway Development Co. Inc., the Georgia high court upheld a lower court ruling that the general contractor’s claim for damage caused by a subcontractor’s faulty plumbing work was covered.

The ruling on construction defects is the latest in number of such cases across the United States

Read Full Story...

Reprinted courtesy of Michael Bradford of Business Insurance.

Read the court decision
Read the full story...
Reprinted courtesy of

When Brad Pitt Tried to Save the Lower Ninth Ward

February 18, 2019 — Rob Walker - Bloomberg
In the months that followed Hurricane Katrina in 2005, there was much discussion about how to rebuild the New Orleans neighborhoods devastated by flooding. Some even questioned whether certain areas should be rebuilt at all: The city’s population would likely be smaller; perhaps its footprint should be revised? The Lower Ninth Ward, for instance—a working-class black neighborhood ravaged when a floodwall failed—might be a lost cause, some said, because it was so severely damaged. Neighborhood residents and activists pushed back, insisting the Lower Nine deserved rebuilding. One of the most high-profile efforts to do so came from an unlikely figure: Brad Pitt. In 2007 the actor founded the Make It Right Foundation, a nonprofit whose mission was to build affordable housing to help Lower Nine residents come home. Attracting designs from prize-winning architects and committing to the highest energy-efficiency standards, Make It Right pledged to build 150 residences. As Pitt later wrote, the organization aimed to make “a human success story of how we can build in the future, how we can build with equality, how we can build for families." Read the court decision
Read the full story...
Reprinted courtesy of Rob Walker, Bloomberg

Cleveland Condo Board Says Construction Defects Caused Leaks

March 01, 2012 — CDJ STAFF

A Cleveland condo association has sued the developer of their building, claiming that construction defects resulted in water intrusion. The K&D Group, which still owns forty units in the 160-unit building, claim that it’s a maintenance issue that they’d like to see fixed, but it’s their responsibility as the developer. Doug Price, CEO of K&D calls it a “frivolous lawsuit.” He blames a “hostile board” and told The Plain Dealer “there’s simple maintenance that they refuse to do.”

An outside company evaluated Stonebridge Towers. According to the condo board’s lawyer, Laura Hauser, the building design and construction are to blame for the water intrusion. Hauser said that the board’s “goal through this litigation is to find a resolution for the association, the building and the owners.”

David Kaman, a Cleveland attorney not involved in the lawsuit, told the Plain Dealer that construction litigation in the Cleveland area had fallen off from 2007, but he sees it on the rise, which he attributes to cost-cutting on recently finished projects. “If an owner moves in and two years later the wallpaper needs to be replaced because the wall is leaking, that’s a construction defect.”

Read the full story…