FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Drug Company Provides Cure for Development Woes

November 18, 2011 — CDJ STAFF

Vertex Pharmaceuticals is poised to become the holder of Boston’s biggest commercial lease, paying $72.5 million for 1.1 million square feet on Boston’s waterfront. Vertex’s new buildings are still under construction, but the plans have spurred other development in the Fan Pier area, according to the New York Times. The Times quotes Mary A. Burke, a senior economist at the Federal Reserve Bank of Boston that the Vertex project gives “a big push” to the “momentum for economic growth.”

The Fallon Company is building Vertex’s new laboratory and office space. They are separately planning to build a high-rise with 150 luxury condominium units. According to Joseph Fallon, the chief executive and president of the Fallon Company, there is already a waiting list of 50 buyers for the condominiums.

Across the street from the Vertex site, a group including Morgan Stanley and Boston Global Investors is planning a 23-block mixed use project that would include 1.2 million square feet of retail space. Additionally, the New England Development and the Hanover Group is building a 356-unit apartment building at the adjacent Pier 4.

Read the full story…

Read the court decision
Read the full story...
Reprinted courtesy of

---

Formal Request for Time Extension Not Always Required to Support Constructive Acceleration

April 25, 2022 — David Adelstein - Florida Construction Legal Updates
Does a constructive acceleration claim require the contractor to always request an extension of time which is then denied by the owner? While this is certainly the preference and the contractor should be requesting an extension of time as a matter of course for an excusable delay, the answer is NO! in certain circumstances. This is conveyed in the factually detailed case discussed below where a formal request for an extension of time was not required for the contractor to support its constructive acceleration claim. But first, what is constructive acceleration: Constructive acceleration “occurs when the government demands compliance with an original contract deadline, despite excusable delay by the contractor.” The Federal Circuit in Fraser defined the elements of constructive acceleration as follows: (1) that the contractor encountered a delay that is excusable under the contract; (2) that the contractor made a timely and sufficient request for an extension of the contract schedule; (3) that the government denied the contractor’s request for an extension or failed to act on it within a reasonable time; (4) that the government insisted on completion of the contract within a period shorter than the period to which the contractor would be entitled by taking into account the period of excusable delay, after which the contractor notified the government that it regarded the alleged order to accelerate as a constructive change in the contract; and (5) that the contractor was required to expend extra resources to compensate for the lost time and remain on schedule. Nova Group/Tutor-Saliba v. U.S., 2022 WL 815826, *42 (Fed.Cl. 2022) quoting Fraser Constr. Co. v. U.S., 384 F.3d 1354, 1361 (Fed. Cir. 2004) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Quick Note: Mitigation of Damages in Contract Cases

October 02, 2018 — David Adelstein - Florida Construction Legal Updates
In an earlier article, I discussed an owner’s measure of damages when a contractor breaches the construction contract. This article discussed a case where the contractor elected to walk off a residential renovation job due to a payment dispute when he demanded more money and the owners did not bite. This case also discussed the commonly asserted defense known as mitigation of damages, i.e., the other party failed to properly mitigate their own damages. In the breach of contract setting, mitigation of damages refers to those damages the other side could have reasonably avoided had he undertaken certain (reasonable) measures. This is known as the doctrine of avoidable consequences. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Quick Note: Subcontractor Payment Bond = Common Law Payment Bond

February 16, 2017 — David Adelstein – Florida Construction Legal Updates
What is a common law payment bond? A common law payment bond is a bond not required or governed by a statute. For example, if a prime contractor provides the owner a payment bond, that bond will be a statutory payment bond. On the other hand, if a subcontractor provides the general contractor with a payment bond, that bond will be a common law payment bond. Why? Because there is not a statute that specifically governs the requirements of a subcontractor’s payment bond given to a general contractor. The subcontractor’s payment bond is aimed at protecting the general contractor (and the general contractor’s payment bond) in the event the subcontractor fails to pay its own subcontractors and suppliers. The subcontractor’s payment bond will generally identify that claimants, as defined by the bond, are those subcontractors and suppliers the subcontractor has failed to pay. This common law payment bond is not recorded in the public records so sometimes it can be challenging for a claimant (anyone unpaid working under the subcontractor that furnished the bond) to obtain a copy of the bond. With that said, an unpaid claimant should consider pursuing a copy of this bond in certain situations, particularly if it may not have preserved a claim against the general contractor’s statutory payment bond. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at dadelstein@gmail.com

---

Electrical Subcontractor Sues over Termination

November 13, 2013 — CDJ STAFF
Millennium Plus, Inc. has sued the contractor for the Efrain A. Duran Water Treatment Plant Facility and Rio Grande City for failing to pay money due to them and terminating the contract. According to the lawsuit, Millennium is claiming that they are owed $161,781 for their work on the water treatment facility. According to the city, the project’s contractor was “very unsatisfied with Millennium’s work.” Although the city disclaims any involvement, Millennium claims it was a “joint enterprise.” Read the court decision
Read the full story...
Reprinted courtesy of

---

First Quarter Gains in Housing Affordability

May 20, 2015 — Beverley BevenFlorez-CDJ STAFF
According to the National Association of Home Builders’ (NAHB) Eye on Housing, the combination of low interest rates and home prices has provided a “solid boost in nationwide affordability in the first quarter of 2015.” Furthermore, “66.5 percent of new and existing homes sold between the beginning of January and end of March were affordable to families earning the U.S. median income of $65,800.” Syracuse, New York remained the U.S.’s most affordable major housing market, while the San Francisco-San Mateo-Redwood City, California region was the nation’s least affordable major housing market. All five of the least affordable small housing markets were in California. Read the court decision
Read the full story...
Reprinted courtesy of

---

In Oregon Construction Defect Claims, “Contract Is (Still) King”

April 25, 2012 — CDJ STAFF

Writing in Oregon’s Daily Journal of Commerce, David Anderson looks at the aftermath of the case Abraham v. T. Henry Construction, Inc. In that case, Anderson notes that “the homeowners hired a contractor to build their house, and subsequently discovered extensive water damage” “after expiration of the time to sue for breach of contract.” The homeowners claimed negligence. Oregon’s Supreme Court concluded that “homeowners only had to prove that the contractor negligently caused reasonably foreseeable harm to the homeowner’s property.”



Anderson views this decision as leading to two risks for contractors. “First, contractors can be held liable in tort for breaching building code standards; second, they can be held liable for violating the often-difficult-to-define ‘reasonable care’ standard.” But here, “contract can be king.” The Oregon Supreme Court noted that the contractor “could have avoided exposure to the general ‘reasonable care’ standard by more carefully defining its obligations in the original construction contract.”



He notes that contractors who fail to define their obligations or use generic definitions “may be exposing themselves to a more vague scope of liability.”



Read the full story…

 Read the court decision
Read the full story...
Reprinted courtesy of

---

Agrihoods: The Best of Both Worlds

July 23, 2014 — Beverley BevenFlorez-CDJ STAFF
Smithsonian Magazine reported on a new U.S. trend of blending farms and housing developments: The concept is called Development Supported Agriculture (DSA), or more commonly known as “Agrihoods.” In a DSA, “consumers pledge money or resources to support a farm operation, and in turn, receive a share of what it produces, but take the concept one step further by integrating the farm within residential developments.” Residents receive similar perks of being a part of a home owner association such as supported pools, tennis courts, and playgrounds through their contribution to the farm. The first DSA, Prairie Crossing, was built in Grayslake, Illinois to preserve land while adding about 350 residential homes. Willowsford, a new DSA being built in Ashburn Virginia, will have over 2,000 homes. Willowsford’s developers have preserved 2,000 acres, with 300 acres of farmland. The development will be broken into four villages, and each will have its own farm. Part of the popularity of DSAs is that they may “require less of an investment than other green space communities—for instance, communities planned around golf courses,” according to Smithsonian Magazine. “What does it cost to leave the open space alone in the first place? Almost nothing,” said Ed McMahon, the Charles E. Fraser chair on sustainable development and environmental policy at the Urban Land Institute, as quoted by Smithsonian Magazine. “A light bulb went off in the mind of savvy developers who said, ‘Jeez, I can build a golf course development without the golf course.’ So that led to designing communities around other green-space amenities such as a farm.” Read the court decision
Read the full story...
Reprinted courtesy of

---