Economic Loss Rule Bars Claims Against Manufacturer
November 02, 2020 —
David Adelstein - Florida Construction Legal UpdatesThe economic loss rule lives to bar a claim against a product manufacturer in a real estate transaction. In a products liability action, there needs to be personal injury or property damage, other than to the property itself, in order to recover economic damages. Otherwise, the economic loss rule will bar the recovery of such economic losses when the economic losses deal to the product itself. This is important to keep in mind in any product liability action against a manufacturer.
In a recent case, 2711 Hollywood Beach Condominium Assoc’n, Inc., v. TRG Holiday, Ltd., 45 Fla. L. Weekly D2179a (Fla. 3d DCA 2020), a condominium association purchased the condominium from the developer. Subsequently, it noticed leaks with the fire suppression system in the condominium and sued multiple parties for damages for repairs due to the leaks and the replacement of the fire suppression system. One of the parties sued in negligence and strict liability was a manufacturer of pipe fittings used in the fire suppression system. The manufacturer moved for summary judgment based on the economic loss rule and relying on the 1993 Florida Supreme Court opinion in Casa Clara Condominium Assoc’n v. Charley Toppino & Sons, Inc., 620 So.2d 1244 (Fla. 1993), holding “the economic loss rule limited a defendant’s tort liability for allegedly defective products to injuries caused to persons or damage caused to property other than the defective product itself.” 2711 Hollywood Beach Conominium Assoc’n, supra. The trial court agreed with the manufacturer and granted summary judgment. On appeal, the Third District affirmed based on the economic loss rule:
The Association bargained for, purchased and received a building; [the manufactuer’s] fittings were only a component of the FSS [fire suppression system], incorporated into the building. Applying the rule set forth in Casa Clara, the Association purchased a completed building from the developer. [The manufactuer’s] fittings were “an integral part of the finished product and, thus, did not injure ‘other’ property.” Injury to the building itself is not injury to “other” property because the product purchased by the Association was the building. See Casa Clara, 620 So. 2d at 1247. The economic loss rule therefore bars the Association’s recovery as to [the manufacturer] to the extent that it sought damages to replace the FSS [fire suppression system] and repair damage to the building.
2711 Hollywood Beach Conominium Assoc’n, supra (internal citations omitted).
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
NIBS Consultative Council Issues Moving Forward Report on Healthy Buildings
July 25, 2021 —
National Institute of Building Sciences(WASHINGTON, DC, July 13, 2021) – The
National Institute of Building Sciences Consultative Council has issued its
2020 Moving Forward Report, looking closely at the importance of healthy buildings.
The report examines how buildings can protect and promote public health, providing recommendations for President Biden and policymakers on three components of healthy buildings: indoor environmental quality, the importance of design in promoting health, and promoting knowledge transfer between building owners and public health officials.
“Ensuring that the spaces where we live and work are healthy and safe for continued occupancy is critical to overcoming the pandemic,” said Lakisha A. Woods, CAE, President and CEO of NIBS. “This is a fundamental pillar of public health and community resilience. The concept of healthy buildings goes well beyond continual sanitation of a building’s indoor environment to eliminate pathogens.”
About NIBS
National Institute of Building Sciences brings together labor and consumer interests, government representatives, regulatory agencies, and members of the building industry to identify and resolve problems and potential problems around the construction of housing and commercial buildings. NIBS is a nonprofit, non-governmental organization. It was established by Congress in 1974. For more information, visit nibs.org or follow @bldgsciences on Twitter and Facebook.
Read the court decisionRead the full story...Reprinted courtesy of
No Coverage For Construction Defect Under Illinois Law
January 28, 2015 —
Tred R. Eyerly – Insurance Law HawaiiThe court followed precedent in Illinois and upheld the insurer's denial of coverage for construction defects that did not damage other property. Design Concrete Founds., Inc. v. Erie Ins. Prop. & Cas. Co., 2014 Ill. App. Unpub. LEXIS 2684 (Ill Ct. App. Nov. 26, 2014).
In 2005, the homeowners contracted with the general contractor to build a home. The general contractor hired Design to do the foundation work. Design performed its work in August 2005. After the work was completed, cracks formed in the foundation, allowing water to enter the basement and an inward shifting of the foundation.
The homeowners sued the general contractor and Design. The complaint alleged that Design failed to build the foundation in a workmanlike manner, resulting in the development of cracks in the foundation.
Read the court decisionRead the full story...Reprinted courtesy of
Tred R. Eyerly, Insurance Law HawaiiMr. Eyerly may be contacted at
te@hawaiilawyer.com
NTSB Pittsburgh Bridge Probe Update Sheds Light on Collapse Sequence
June 06, 2022 —
Tom Ichniowski - Engineering News-RecordThe National Transportation Safety Board (NTSB) has issued an update in its investigation of the Jan. 28 collapse of Pittsburgh's Fern Hollow Bridge that provides additional information about how the collapse proceeded, but does not discuss why the accident occurred. That finding of a probable cause isn't expected until sometime in 2023.
Reprinted courtesy of
Tom Ichniowski, Engineering News-Record
Mr. Ichniowski may be contacted at ichniowskit@enr.com
Read the full story...
Read the court decisionRead the full story...Reprinted courtesy of
The Connecticut Appellate Court Decides That Construction Contractor Was Not Obligated To Continue Accelerated Schedule to Mitigate Its Damages Following Late Delivery of Materials by Supplier
April 11, 2022 —
Robert M. Barrack - Gordon & ReesIn United Concrete Prods. v. NJR Constr., LLC, 207 Conn. App. 551, 263 A.3d 823 (2021), the Connecticut Appellate Court has issued a decision that should be of interest to the Connecticut construction industry and the construction bar. The lawsuit arose out of the late delivery of materials on a construction project, which is a frequent problem on construction projects. In United Concrete Products, the defendant general contractor, NJR Construction, LLC (“NJR”) was retained by the State of Connecticut Department of Transportation (“DOT”) to replace a bridge over the Hockanum River (“Project”). Id. at 555-58 (2021). The Prime Contract provided that NJR with an eight-week time-frame to perform the work, at which time the road would be closed to traffic. Id. The Prime Contract also provided for a bonus of $3,000 for each day the road was opened to traffic prior to the eight week deadline of August 8, 2016, and for liquidated damages of $3,000 for each day the road remained closed beyond the deadline. Id.
NJR subsequently entered into a purchase order (“Subcontract”) with the plaintiff, United Concrete Products, Inc. (“United”), whereby United agreed to provide certain concrete components for the Project, including ten pre-stressed concrete beams. Id. The Subcontract required that United deliver the concrete beams by June 7, 2016, but, NJR did not actually schedule the delivery until June 29, 2016. Id. Nevertheless, even with that schedule NJR could have reopened the road by July 19, 2016, which would have allowed it to receive the full $60,000 incentive bonus. However, United did not deliver the concrete beams until July 26, 2016, which caused NJR to lose the incentive bonus, be assessed liquidated damages by the DOT, and to incur additional delay damages. Id. After deducting the amount of $179,500 in damages that it incurred due to United’s late delivery of the beams, NJR paid United the balance of $66,074.75. Id.
Read the court decisionRead the full story...Reprinted courtesy of
Robert M. Barrack, Gordon Rees Scully Mansukhani, LLPMr. Barrack may be contacted at
rbarrack@grsm.com
U.S. Homeownership Rate Rises for First Time in Two Years
October 28, 2015 —
Prashant Gopal – BloombergThe homeownership rate in the U.S. rose for the first time in two years as sustained job growth and low borrowing costs fueled demand for housing.
The share of Americans who own their homes was 63.7 percent in the third quarter, up from 63.4 percent in the previous three months, the Census Bureau reported Tuesday. It was the first quarterly increase since the third quarter of 2013.
The pool of eligible buyers is expanding as U.S. employment improves and families who lost properties during the recession repair their credit and seek another chance at owning. Sales of existing homes rebounded in September to the second-highest level since February 2007.
Read the court decisionRead the full story...Reprinted courtesy of
Prashant Gopal, Bloomberg
Battle of “Other Insurance” Clauses
March 23, 2011 —
Tred R. EyerlyThe New York Court of Appeals considered the impact of competing “other insurance” provisions located in both a CGL policy and a D&O policy. See Fieldston Property Owners Assoc., Inc. v. Hermitage Ins. Co., Inv., 2011 N.Y. LEXIS 254 (N.Y. Feb. 24, 2011).
In the underlying case, Fieldston’s officers were charged with making false statements and fraudulent claims with respect to a customer's right to access its property from adjacent streets. Suit was eventually filed against Fieldston and its officers, alleging several causes of action including injurious falsehood. Damages were sought.
Fieldston’s CGL policy was issued by Hermitage. The “other insurance” provision stated, “If other valid and collectible insurance is available to the insured for a loss we cover . . . our obligations are limited,” but also stated it would share with all other insurance as a primary policy.
Read the full story...Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii. Mr. Eyerly can be contacted at te@hawaiilawyer.com
Read the court decisionRead the full story...Reprinted courtesy of
Nine Haight Attorneys Selected for Best Lawyers®: Ones to Watch 2021
September 14, 2020 —
Haight Brown & Bonesteel LLPNine Haight Brown & Bonesteel LLP attorneys were selected for Best Lawyers®: Ones to Watch 2021. Congratulations to
Courtney Arbucci,
Frances Brower,
James de los Reyes,
Kyle DiNicola,
Arezoo Jamshidi,
Kristian Moriarty,
Beth Obra-White,
Casey Otis and
Kaitlin Preston!
Since it was first published in 1983, Best Lawyers® has become universally regarded as the definitive guide to legal excellence. Best Lawyers lists are compiled based on an exhaustive peer-review evaluation. Almost 94,000 industry leading lawyers are eligible to vote (from around the world), and Best Lawyers has received over 11 million evaluations on the legal abilities of other lawyers based on their specific practice areas around the world. Lawyers are not required or allowed to pay a fee to be listed; therefore inclusion in Best Lawyers is considered a singular honor. Corporate Counsel magazine has called Best Lawyers “the most respected referral list of attorneys in practice.”
Read the court decisionRead the full story...Reprinted courtesy of
Haight Brown & Bonesteel LLP