Fairfield Connecticut Building Expert Directory

Wildfire Insurance Coverage Series, Part 3: Standard Form Policy Exclusions

July 11, 2022 — Scott P. DeVries & Yosef Itkin - Hunton Insurance Recovery Blog
Even when claims are within the scope of coverage, insurers often rely on exclusions in an attempt to avoid coverage for wildfire claims. In this post in the Blog’s Wildfire Insurance Coverage Series, we discuss the interplay between coverage grants and exclusions, and the “anti-concurrent cause” provision. Insurers may cite exclusions in an attempt to reduce or avoid liability. The insurance industry has long relied on the Insurance Services Office (ISO) to draft standard form policy language and secure approval as required by state regulatory agencies. ISO Form HO 00 03 10 00 (Section I—Exclusions, Part B) provides the following form exclusionary language: We do not insure for loss to property described in Coverages A and B caused by any of the following. However, any ensuing loss to property described in Coverages A and B not precluded by any other provision in this policy is covered. Reprinted courtesy of Scott P. DeVries, Hunton Andrews Kurth and Yosef Itkin, Hunton Andrews Kurth Mr. DeVries may be contacted at sdevries@HuntonAK.com Mr. Itkin may be contacted at yitkin@HuntonAK.com Read the court decision
Read the full story...
Reprinted courtesy of

Legislative Update on Bills of Note (Updated Post-Adjournment)

March 27, 2019 — Christopher G. Hill - Construction Law Musings
In two prior posts, one specifically relating to a bill that was introduced to apply a statute of limitatons on state agencies for construction projects and one more general, I discussed some of the legislation pending in the Virginia General Assembly that could be of interest to construction professionals. This post will update the status of these bills and add one that I neglected to highlight in the prior posts. I’ll begin with the oversight. HB 2218 Makes the unlawful and unlicensed practice of contracting, real estate brokering, or real estate sales, in connection with a consumer transaction, unlawful under the Virginia Consumer Protection Act. In short, it makes explicit what was implicit, namely that contractors that perform work without a license are in violation of the VCPA. This bill has passed the house by unanimous vote and is in committee at the Senate. UPDATE– As of February 20, 2019, this bill has passed both houses, all that is left is the paperwork. Post Adjournment Update: This bill passed and awaits Governor’s signature. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Construction Law Alert: Concrete Supplier Botches Concrete Mix, Gets Thrashed By Court of Appeal for Trying to Blame Third Party

January 21, 2015 — Steven M. Cvitanovic and Whitney L. Stefko – Haight Brown & Bonesteel LLP
On January 8, 2015, the Second Appellate district affirmed judgment of the lower court in State Ready Mix Inc. v. Moffatt & Nichol, and barred a concrete supplier from blaming a third party consultant for the concrete supplier's failure to deliver concrete that met project specifications. In 2012, Major Engineering Marine, Inc. was hired by a project manager to construct a harbor pier in the Channel Islands Harbor. Major hired State Ready Mix, Inc. to supply the concrete for the project. State wrote and submitted a concrete mix design and, at the request of Major, civil engineer Moffatt & Nichol reviewed and approved State's mix design at no charge. Reprinted courtesy of Steven M. Cvitanovic, Haight Brown & Bonesteel LLP and Whitney L. Stefko, Haight Brown & Bonesteel LLP Mr. Cvitanovic may be contacted at scvitanovic@hbblaw.com; Ms. Stefko may be contacted at wstefko@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Architect, Engineer, and Design Professional Liens in California: A Different Animal than the Mechanics’ Lien

August 15, 2022 — William L. Porter - Porter Law Group
Most in the construction industry are familiar with the rules governing California mechanics’ liens. They know that the Preliminary Notice of Civil Code Section 8034 and 8200-8216 is an important foundational prerequisite document and that the deadline to record a mechanics’ lien is generally triggered by events occurring at the end of construction, including completion of the work of improvement and/or the recording of the notice of completion or notice of cessation. Most of these rules are found in California Civil Code sections 8160-8494. While architects, engineers and other design professionals are certainly entitled to pursue a mechanics’ lien at the end of a construction project when they are unpaid for their work, unless they also consider the remedy available to them under the California “design professional lien,” they are missing a powerful opportunity to preserve the right to payment only available to architects, engineers, and design professionals. Read the court decision
Read the full story...
Reprinted courtesy of William L. Porter, Porter Law Group
Mr. Porter may be contacted at bporter@porterlaw.com

Part II: Key Provisions of School Facility Construction & Design Contracts

July 21, 2018 — David R. Cook - Autry, Hall & Cook, LLP
In Part I of this article, published in late April, we discussed the performance risk and time risk involved with construction and design contracts, and in Part II, we will cover cost risk and political risk. Cost Risk School budgets are limited for many reasons, and the construction budget is no exception. As a result, contracts should guard against unwarranted cost increases and claims. In the absence of a written change order signed by the appropriate officer, the contract should absolutely prohibit additional compensation for changes in the work. It should forbid claims for all events except those within the school authority’s sole control. Even for permitted claims, the contractor must provide written notice so that the authority might alleviate the problem and control its costs. To encourage the contractor to limit costs and claims, the contract could include a shared-savings clause, which grants an incentive payment for completion within the budget. Read the court decision
Read the full story...
Reprinted courtesy of David R. Cook, Autry, Hall & Cook, LLP
Mr. Cook may be contacted at cook@ahclaw.com

Contractor’s Burden When It Comes to Delay

October 26, 2020 — David Adelstein - Florida Construction Legal Updates
When a contractor is challenging the assessment of liquidated damages, or arguing that it is entitled to extended general conditions, the contractor bears a burden of proof to establish there were excusable delays that impacted the critical path and, in certain scenarios, the delays were not concurrent with contractor-caused delay:

When delays are excusable, a contractor is entitled to a time extension, such that the government may not assess liquidated damages for those delays. The government bears the initial burden of proving that the contractor failed to meet the contract completion date, and that the period of time for which the government assessed liquidated damages was correct. If the government makes such a showing, the burden shifts to the contractor to show that its failure to timely complete the work was excusable. To show an excusable delay, a contractor must show that the delay resulted from “unforeseeable causes beyond the control and without the fault or negligence of the Contractor.” “In addition, the unforeseeable cause must delay the overall contract completion; i.e., it must affect the critical path of performance.” Further, the contractor must show that there was no concurrent delay.

Ken Laster Co., ASBCA No. 61292, 2020 WL 5270322 (ASBCA 2020) (internal citations omitted). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

"Occurrence" May Include Intentional Acts In Montana

June 22, 2016 — Tred R. Eyerly – Insurance Law Hawaii
The Montana Supreme Court found that policy language defining "accidents may include intentional acts." Employers Mut. Cas. Co. v. Fisher Builders, Inc., 2016 Mont. LEXIS 269 (Mont. Sup. Ct. April 19, 2016). Jerry and Karen Slack hired Fisher Builders to build a remodeled home located on the site of their home at Flathead Lake. The existing home was an aged vacation home. The County zoning regulations required the remodeled home to incorporate the existing structure. The permit issued to the Slacks required the existing deck to remain unchanged. Fisher elevated the existing home structure on steel beams to pour a new foundation. Fisher began to dismantle the walls while the structure was resting on the beams, and found an infestation of carpenter ants. The ant-infested planks were cut out, apparently in order to salvage what usable materials he could from the remaining structure. The ant-infested boards were subsequently burned. Eventually, the deck collapsed. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

Project-Specific Policies and Products-Completed Operations Hazard Extensions

May 31, 2021 — Jeremiah M. Welch - Saxe Doernberger & Vita
1. Understanding the “Products-Completed Operations Hazard” ISO commercial general liability (“CGL”) policies use the term “products-completed operations hazard” (“PCOH”) to define a category of risk which is treated specially by certain exclusions within the policy and often subject to separate limits of insurance. In construction, we think about PCOH as being about coverage for completed work. Bodily injury and property damage arising out of completed work is a significant construction risk. Most construction contracts include warranty and indemnity obligations for completed work. All states allow lawsuits to be brought alleging bodily injury or property damage because of completed work based on common law. Contract and common law claims are subject to statutes of limitation – laws which define the time in which suits must be brought. Most states provide exceptions to their statutes of limitation for common law claims – the most common example is an extension to file a lawsuit based on a latent defect until the defect is discovered. Most states also have “statutes of repose” – laws that set a date after which suit may no longer be brought, no matter what the circumstances are. A construction contractor, therefore, has potential liability until the statute of repose period has expired. Thus, a contractor looks to ensure that it has coverage for the PCOH for its full statute of repose liability period. Read the court decision
Read the full story...
Reprinted courtesy of Jeremiah M. Welch, Saxe Doernberger & Vita
Mr. Welch may be contacted at JWelch@sdvlaw.com

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES