FAIRFIELD CONNECTICUT BUILDING EXPERT
DIRECTORY AND CAPABILITIES

Federal Interpleader Dealing with Competing Claims over Undisputed Payable to Subcontractor

September 28, 2017 — David Adelstein - Florida Construction Legal Updates
What do you do if you are holding undisputed money owed to a subcontractor? Well, you make an effort to pay it or tender it! Right? I am never a fan of a client holding undisputed sums without a legitimate contractual basis. There are circumstances, however, where the effort to pay an undisputed payable is not so easy. In fact, it is challenging, as in the below case example where the subcontractor filed for an Assignment for the Benefit of Creditors (referred to as an “ABC”). An ABC, in a nutshell, allows an insolvent entity to file an insolvency action in state court governed by state law and choose its assignee (versus a federal bankruptcy action governed by federal law where a trustee is appointed). One major difference is that there is no automatic stay in an ABC as there is in a federal bankruptcy action. Thus, the insolvent entity can still be sued, but, while that entity is in an ABC, there are many creditors that will not be able to enforce a judgment. (See Florida Statute Ch. 727). Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at dadelstein@gmail.com

---

Receiving a $0 Verdict and Still Being Deemed the Prevailing Party for Purposes of Attorney’s Fees

May 24, 2018 — David Adelstein - Florida Construction Legal Updates
Low and behold, a party can be the prevailing party for purposes of attorney’s fees even if that party is awarded $0. That’s right, even if the party is awarded a big fat zero, they can still be the prevailing party for purposes of being entitled to attorney’s fees. This is because a party is the prevailing party if they prevail on the significant issues in the case. A party can prevail on the significant issues even if that party is awarded $0. Whoa! For example, in Coconut Key Homeowner’s Association, Inc. v. Gonzalez, 43 Fla.L.Weekly D1045a (Fla. 4th DCA 2018), a homeowner sued her homeowner’s association claiming the association breached its governing documents. There was a basis for fees under Florida’s homeowner’s association law (and there likely was a basis under the governing documents). At trial, the jury held that the association breached its governing documents, but awarded the homeowner nothing ($0). The trial court also issued injunctive relief in favor of the homeowner. The homeowner claimed she should be deemed the prevailing party for purposes of attorney’s fees; however, this was denied by the trial court based on the $0 verdict and no fees were awarded to the homeowner. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at dadelstein@gmail.com

---

Takeaways From Schedule-Based Dispute Between General Contractor and Subcontractor

September 09, 2024 — David Adelstein - Florida Construction Legal Updates
A recent opinion out of the Southern District of Florida, Berkley Insurance Co. v. Suffolk Construction Co., Case 1:19-cv-23059-KMW (S.D.Fla. July 22, 2024), provides valuable takeaways on schedule-based disputes between a general contractor and subcontractor on a high-rise project. In a nutshell, the general contractor’s original project schedule was abandoned due to project delays and the project wasn’t being built by any updated project schedule. The subcontractor claimed the general contractor was mismanaging the schedule putting unreasonable manpower and supervision constraints on it, i.e., it was working inefficiently. A bench trial was conducted and the Court found in favor of the subcontractor’s arguments. The Court found the general contractor had unrelated delays and that work activities were no longer methodical but, simply, piecemeal demands. The Court also rejected any inadequate manpower arguments finding the subcontract did not place any manpower requirements on the subcontractor. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Colorado Supreme Court Rules that Developers Retain Perpetual Control over Construction Defect Covenants

June 21, 2017 — Jesse Witt - The Witt Law Firm
The Colorado Supreme Court ruled today that developers can retain control over community covenants in perpetuity by recording a covenant that requires declarant consent to any amendments. Although the Colorado Common Interest Ownership Act (CCIOA) states that such controls should be void, the court nevertheless ruled that a declarant may veto amendments that alter the dispute resolution procedures for construction defect actions at any time. The case of Vallagio at Inverness Residential Condominium Ass’n v. Metropolitan Homes, Inc., __ P.3d __, 15CO508, arose when the community’s members discovered widespread construction defects. When the declarant developed the project, it had recorded a declaration of covenants that purported to waive the homeowners’ right to a jury trial and instead require that any construction defect disputes be resolved by a private arbitration panel. The declaration also prohibited the homeowners from recovering attorney fees and costs, and it limited the declarant’s liability for damages. Consistent with CCIOA, the declaration allowed the homeowners to amend their covenants by a 67% vote, but it recited that the declarant could veto any such amendment prior to the sale of the last unit to a homeowner. The covenants further stated that the declarant must consent to any amendment that altered the construction defect restrictions. Reprinted courtesy of Jesse Howard Witt, Acerbic Witt Mr. Witt may be contacted at www.witt.law Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

---

Anticipatory Repudiation of a Contract — The Prospective Breach

July 05, 2021 — David Adelstein - Florida Construction Legal Updates
There are instances where a party can engage in the anticipatory repudiation of their obligations under a contract. In essence, this is basically a party prospectively breaching the contract by repudiating their obligations in the contract. A prospective breach of contract occurs where there is absolute repudiation by one of the parties prior to the time when his performance is due under the terms of the contract. Such a repudiation may be evidenced by words or voluntary acts but the refusal must be distinct, unequivocal, and absolute. Moreover, repudiation can be shown where one party makes additional demands not included in the initial agreement:

The law is clear that where one party to the contract arbitrarily demands performance not required by the contract and couples this demand with a refusal to further perform unless the demand is met, the party has anticipatorily repudiated the contract, which anticipatory repudiation relieves the non-breaching party of its duty to further perform and creates in it an immediate cause of action for breach of contract. 24 Hr Air Service, Inc. v. Hosanna Community Baptist Church, Inc., 46 Fla. L. Weekly, D1344a (Fla. 3d DCA 2021) (quotations and citations omitted).

Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

Options When there is a Construction Lien on Your Property

June 02, 2016 — David Adelstein – Florida Construction Legal Updates
There is a construction lien on my property. What are my best options? I hear this question quite a bit…so here it goes… (1) Do nothing. That’s right – do nothing. If you are not looking to sell your house or refinance in the next year or so, you can do nothing and see whether the lienor files a construction lien foreclosure lawsuit. The lienor has one year from the recording of the lien to file the lawsuit. (2) Record a Notice of Contest of Lien. The Notice of Contest of Lien shortens the lienor’s statue of limitations to foreclose on the lien from one year to 60 days. If the lienor fails to foreclose on the lien within 60 days, the lien is extinguished by operation of law. This is the route I tend to prefer. If the lienor is going to file a lien foreclosure lawsuit, I tend to think it is better forcing the issue on the front end as opposed to waiting a year. But every situation is different. Read the court decision
Read the full story...
Reprinted courtesy of David M. Adelstein, Kirwin Norris
Mr. Adelstein may be contacted at dma@kirwinnorris.com

---

"On Second Thought"

October 28, 2024 — Daniel Lund III - Lexology
Rehearing requests are seldom granted by courts, and when they are, there’s usually something uniquely compelling in the request and the granting. So is the case in a matter involving monies deposited in the registry of the federal court in New Orleans related to work performed on cleanup after Hurricanes Maria and Irma in the U.S. Virgin Islands. The party depositing monies – which represented subcontract sums paid to it by the general contractor – held back several hundred thousand dollars based on withholding provisions in the various contracts in play. The Court was tasked with evaluating not only a pay-when-paid provision in the subcontract of the claiming party, but also incorporation of the terms of a higher tiered contract which allowed for the withholding. The Court initially granted summary judgment allowing the monies to be withheld. However, on request for rehearing, it was pointed up that while monies could be retained for purposes of covering attorney’s fees and costs related to litigation initiated by the plaintiff subcontractor’s vendors, there was a particular process for that withholding – and an assertion that the process was not followed. Read the court decision
Read the full story...
Reprinted courtesy of Daniel Lund III, Phelps
Mr. Lund may be contacted at daniel.lund@phelps.com

---

Prime Contractor & Surety’s Recovery of Attorney’s Fees in Miller Act Lawsuit

February 02, 2017 — David Adelstein - Florida Construction Legal Updates
Can a claimant recover attorney’s fees in a Miller Act payment bond dispute even though the Miller Act does not contain a prevailing party attorney’s fee provision? Yes, if the underlying contract that formed the basis of the suit provided for attorney’s fees. What about a prime contractor and surety—can they recover their attorney’s fees if they prevail in a Miller Act payment bond claim and the underlying contract provides a basis for fees? The Eleventh Circuit Court of Appeals in U.S.A. f/u/b/o RMP Capital Corp. v. Turner Construction Co., 2017 WL 244066 (11th Cir. 2017) seemingly just answered this question in the affirmative when it reversed a lower court’s ruling that precluded a prime contractor and surety that prevailed in a Miller Act claim from recovering their attorney’s fees[.] Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at dadelstein@gmail.com

---