COLUMBUS OHIO BUILDING EXPERT
DIRECTORY AND CAPABILITIES

General Contractor’s Excess Insurer Denied Equitable Contribution From Subcontractor’s Excess Insurer

December 15, 2016 — Christopher Kendrick & Valerie A. Moore – Haight Brown & Bonesteel LLP
In Advent v. National Union Fire Ins. Co., etc. (No. H041934 filed 12/6/16), a California appeals court refused to order a subcontractor’s excess insurer to contribute to a general contractor’s excess insurer because the general contractor did not qualify as an additional insured of the subcontractor’s insurer, and the policy wording made the subcontractor’s excess insurer second level excess above the general contractor’s own excess insurance. Advent was the general contractor on a housing development and Johnson was a sub-subcontractor providing concrete on perimeter walls. A Johnson employee dispatched to retrieve plywood dumped between some of the buildings somehow fell down an open stairwell inside one of the unfinished buildings and suffered serious injury. He sued Advent and others for negligence, but could not remember how he fell. Reprinted courtesy of Christopher Kendrick, Haight Brown & Bonesteel LLP and Valerie A. Moore, Haight Brown & Bonesteel LLP Mr. Kendrick may be contacted at ckendrick@hbblaw.com Ms. Moore may be contacted at vmoore@hbblaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

The Hazards of Carrier-Specific Manuscript Language: Ohio Casualty's Off-Premises Property Damage and Contractors' E&O Endorsements

October 05, 2020 — Theresa A. Guertin & Eric M. Clarkson - Saxe Doernberger & Vita
Risk transfer in the construction industry depends heavily on industry-standard insurance language. Insurance provisions in subcontracts typically reference ISO standard insurance terminology or endorsements in order to guarantee (or, at least, attempt to secure) coverage for upstream parties. The contract may require, for example, that a subcontractor maintains general liability insurance on a “current ISO occurrence form,” and name upstream parties as additional insureds, and both parties will have a general understanding of what that entails for purposes of risk transfer. Problems arise, however, when insurance companies stray from standard language, especially on issues that go to the heart of construction risk transfer. In some instances, provisions that track ISO language may contain subtle changes that seem to meet the contractual insurance requirements. Upon closer scrutiny, it could significantly change how a policy will respond to a given claim. Given the extent of potential liability arising from construction projects, if the insurance programs intended to back up risk transfer and indemnity agreements do not respond as expected, all the potentially liable parties may be left in the lurch. Reprinted courtesy of Theresa A. Guertin, Saxe Doernberger & Vita and Eric M. Clarkson, Saxe Doernberger & Vita Ms. Guertin may be contacted at tag@sdvlaw.com Mr. Clarkson may be contacted at emc@sdvlaw.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Insured's Motion for Reconsideration on Protecting the Integrity of Referral Sources under Florida Statute s. 542.335

September 28, 2017 — David Adelstein - Florida Construction Legal Updates
Referral sources are generally important for all businesses. Due to their importance, certain businesses require employees to execute non-solicitation or even non-compete agreements to protect the integrity of their referral sources. Now, whether referral sources for a particular business constitutes a legitimate business interest (very important words) is a question where the context must be examined. Nonetheless, in a case that is certainly important for businesses, the Florida Supreme Court held that referral sources can serve as a legitimate business interest. While this case dealt with home health care companies, the rationale would be the same no matter the business, provided that referral sources are contextually a legitimate business interest for that business. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Florida Construction Legal Updates
Mr. Adelstein may be contacted at dadelstein@gmail.com

---

Shifting the Risk of Delay by Having Float Go Your Way

July 05, 2021 — Christopher J. Brasco & Matthew D. Baker - ConsensusDocs
Critical path delay plays a central role in allocating responsibility for project delay. The interrelated concept of concurrency is also frequently determinative of entitlement on a range of claims including by owners for liquidated damages and by contractors for delay damages. What constitutes critical/concurrent delay, however, is hotly debated by scheduling experts. The lack of real consensus regarding how critical/concurrent delay should be determined and analyzed has created significant uncertainty in scheduling disputes. Indeed, courts have adopted differing and at times conflicting theories of concurrency that can produce divergent outcomes for the parties. In an effort to reduce uncertainty, stakeholders have increasingly adopted specialized contractual provisions and scheduling techniques which have significant implications for the evaluation of the companion concepts of criticality and concurrency. One such mechanism is float sequestration. Regardless of whether float sequestration is ultimately in the construction industry’s broader interest, stakeholders must be able to recognize its use and appreciate the implications for delay disputes on their projects. Simply defined, float is the number of days an activity can be delayed before affecting the project’s critical path (i.e., the longest chain of activities which determines the project’s minimal duration). Typically, only delays affecting the critical path can produce concurrent delay. Consequently, the concept of float is integral to understanding and resolving issues of both criticality and concurrency. Reprinted courtesy of Christopher J. Brasco, Watt, Tieder, Hoffar & Fitzgerald, LLP and Matthew D. Baker, Watt, Tieder, Hoffar & Fitzgerald, LLP Mr. Brasco may be contacted at cbrasco@watttieder.com Mr. Baker may be contacted at mbaker@watttieder.com Read the court decision
Read the full story...
Reprinted courtesy of

---

Kiewit Hired as EPC for Fire-Damaged Freeport Gas Terminal Fix

September 19, 2022 — Mary B. Powers - Engineering News-Record
Freeport LNG’s $13.5-billion natural gas liquefaction plant and export terminal in Texas, closed since a June 8 fire and explosion that damaged the facility, said it will not partially reopen until possibly mid-November, and not fully operate until next March—the third delay it has announced. Reprinted courtesy of Mary B. Powers, Engineering News-Record ENR may be contacted at enr@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

---

AI in Construction: What Does It Mean for Our Contractors?

December 17, 2024 — Patrick Scarpati - Construction Executive
Artificial intelligence is revolutionizing the construction industry by enhancing efficiency, safety and decision-making throughout the project lifecycle. AI in construction involves the application of advanced technologies like machine learning, computer vision and data analytics to various construction processes. Through AI, machines can learn and imitate human cognitive functions. The possibilities may sound endless, but as an industry traditionally looking from the outside in at technology, we must first step back to educate ourselves on the basics. This paper is meant to function as a starting point in your journey to understand AI and its potential impact on the construction industry. By reading through definitions, construction use cases and considerations, the reader should walk away with a base level of knowledge to ensure they can actively participate in future conversations on AI in construction. Reprinted courtesy of Patrick Scarpati, Construction Executive, a publication of Associated Builders and Contractors. All rights reserved. Read the court decision
Read the full story...
Reprinted courtesy of

---

What To Do When the Government is Slow to Decide a Claim?

October 02, 2015 — Craig Martin – Construction Contractor Advisor
You may know this situation all too well. You’ve submitted your certified claim to the contracting officer and there it sits. You ask for a decision and they say soon, but it’s not soon. And pretty soon, several months have gone by. Since the Court of Federal Claims’ decision in Rudolph and Sletten, Inc. v. U.S., the government may have to decide in 60 days or your claim will be deemed denied which would allow you to file your claim in the Court of Federal Claims. Background Rudolph and Sletten (R&S) were awarded a contract to construct the La Jolla Laboratory. On August 20, 2013, R&S submitted a certified claim seeking $26,809,003 as compensation for costs due to alleged government-caused delays and disruption, additional consultant costs and extra work. Read the court decision
Read the full story...
Reprinted courtesy of Craig Martin, Lamson, Dugan and Murray, LLP
Mr. Martin may be contacted at cmartin@ldmlaw.com

---

Construction Laborers Sue Contractors Over Wage Theft

September 17, 2014 — Beverley BevenFlorez-CDJ STAFF
Aspen Journalism reported that “[f]our laborers who worked on the Burlingame Phase II affordable housing project financed by the city of Aspen are suing three of the project’s contractors, alleging they weren’t paid for some of their work and were never paid overtime when they worked more than 40 hours per week.” Towards Justice, nonprofit legal services group, filed suit in August on behalf of Fernando Villalobos, Sergio Roman, Ramon Gonzalez and Hugo Esqueda, and against construction companies Haselden Construction, LLC of Centennial, Continental Constructors, LLC of Littleton, and JMS Building of Glenwood Springs. Both sides have agreed that “the men were paid for some, but not all, of their work,” but dispute “the value of the work done by the laborers.” Read the court decision
Read the full story...
Reprinted courtesy of

---