Seattle Washington Building Expert Directory

COVID-19 Damages and Time Recovery: Contract Checklist and Analysis

April 27, 2020 — Patrick J. Greene, Jr. - Peckar & Abramson
This Alert explores the contract provisions and related rights that are likely to govern time and compensation adjustments for COVID-19 impacts. As parties begin analyzing such rights, this is intended to serve as a useful guide and checklist. Analysis of relevant contract provisions should start with careful consideration of the specific impacts that have been experienced and the causes of those impacts. The nature of the impact (delay, extra work, disruption, etc.) and the causes of such impacts (owner direction, government order, etc.) will generally govern the analysis and resulting course of action. Listing or creating a matrix of impacts and their causes may be an effective working tool. Essentially, there are five primary impacts that will likely require critical analysis under the relevant contract provisions, and notably, more than one impact may be present: a) complete or partial suspension of work, b) additional work or requirements, c) added cost, d) delay, and e) disruption. Read the court decision
Read the full story...
Reprinted courtesy of Patrick J. Greene, Jr., Peckar & Abramson
Mr. Greene may be contacted at pgreene@pecklaw.com

Federal Judge Vacates CDC Eviction Moratorium Nationwide

May 24, 2021 — Zachary Kessler, Amanda G. Halter & Adam Weaver - Gravel2Gavel Construction & Real Estate Law Blog
Late last week a federal district court judge for the District of Columbia held that the nationwide eviction moratorium issued by the Centers for Disease Control and Prevention (CDC) went beyond the agency’s statutory authority and vacated it nationwide. This decision effectively expanded a similar decision by a Texas federal court last month that found the CDC’s moratorium was an improper use of federal power but limited its decision to the litigants to that case and declined to vacate the CDC order. The CDC eviction moratorium (the Order) was designed to halt certain cases of eviction for low-income tenants and was the most significant nationwide tenant protection for nonpayment of rent due to the COVID-19 pandemic. While the federal government has said it will appeal this week’s decision and has sought to stay its effect, it is a significant blow to the federal government’s efforts to halt evictions due to the COVID-19 pandemic. This decision may now open an avenue for landlords to begin evicting nonpaying tenants that had been halted by the eviction moratorium since mid-2020. Reprinted courtesy of Zachary Kessler, Pillsbury, Amanda G. Halter, Pillsbury and Adam Weaver, Pillsbury Mr. Kessler may be contacted at zachary.kessler@pillsburylaw.com Ms. Halter may be contacted at amanda.halter@pillsburylaw.com Mr. Weaver may be contacted at adam.weaver@pillsburylaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Payment Bond Claim Notice Requires More than Mailing

June 18, 2019 — Christopher G. Hill - Construction Law Musings
It’s been a while since I posted something new relating to Virginia’s “Little Miller Act” and its various notice requirements for a subcontractor to make a payment bond claim. I have posted on the basics of a Virginia payment bond claim previously here at Musings. One of these basics is the 90 day notice requirement for suppliers or second tier subcontractors with no direct contractual relationship to the general contractor. A recent case from the Norfolk, Virginia Circuit Court examined when notice is “given” under the Little Miller Act. In R T Atkinson Building Corp v Archer Western Construction, LLC the Court looked at the question of whether mailing of the notice of claim is enough to constitute notice being “given” in a manner that would satisfy the statutory requirements. In that case, the supplier mailed the notice within the 90 day window, but the defendant argued on summary judgment that it did not receive the notice until 2 days after the 90 day window had closed. In support of this contention, the defendant provided tracking information showing delivery by the USPS on the non-compliant date. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

Brenner Base Tunnelers Conquer Peaks and Valleys in the Alps

October 21, 2019 — Scott Blair - Engineering News-Record
A logistics tangle decades in the unraveling, the Brenner Base Tunnel project is having a banner year. Twin tunnel boring machines in May were released on their relentless journey to mine the main tunnels underneath the Alps between Austria and Italy, while a multinational crew of 2,400 workers armed with a toolkit of just about every mining technique is swarming four major worksites, including a particularly challenging area where workers must undercut a river and pass through the fast-flowing aquifer below it. Read the court decision
Read the full story...
Reprinted courtesy of Scott Blair, ENR
Mr. Blair may be contacted at blairs@enr.com

California Contractors – You Should Know That Section 7141.5 May Be Your Golden Ticket

February 18, 2020 — Amy L. Pierce, Mark A. Oertel & John Lubitz - Lewis Brisbois Bisgaard & Smith LLP
Under California’s Contractors’ State License Law, Cal. Bus. & Prof. Code §§ 7000 et seq., all contractors’ and subcontractors’ licenses expire two years from the last day of the month in which the license issued, or two years from the date on which the renewed license last expired. The Contractors State License Board (CSLB) sends licensees a renewal application 60 to 90 days prior to the date the license is set to expire. Most contractors have various controls in place to make sure that the renewal application is timely filed and the required fee paid. Even so, we are only human and mistakes are made, and a renewal application filing deadline can be missed for a variety of reasons, e.g., the licensee’s mailing address has not been updated on the CSLB’s records, the individual responsible for filing the license renewal is out on leave, there has been a death in the family or a serious health issue, etc. Quoting Robert Burns, even “[t]he best-laid schemes of mice and men go oft awry” (To a Mouse, 1786). General contractors should be cognizant of both their and their subcontractors’ license renewal obligations and deadlines. If a licensee missed timely filing its renewal application, Business & Professions Code Section 7141.5may provide some relief. Section 7141.5 provides that the Registrar of Contractors,

“may grant the retroactive renewal of a license if the licensee requests the retroactive renewal in a petition to the registrar, files an application for renewal on a form prescribed by the registrar, and pays the appropriate renewal fee and delinquency fee prescribed by this chapter. This section shall only apply for a period not to exceed 90 days from the due date and only upon a showing by the contractor that the failure to renew was due to circumstances beyond the control of the licensee.”

Reprinted courtesy of Lewis Brisbois Bisgaard & Smith LLP attorneys Amy Pierce, Mark Oertel and John Lubitz Ms. Pierce may be contacted at Amy.Pierce@lewisbrisbois.com Mr. Oertel may be contacted at Mark.Oertel@lewisbrisbois.com Mr. Lubitz may be contacted at John.Lubitz@lewisbrisbois.com Read the court decision
Read the full story...
Reprinted courtesy of

Construction Needs Collaborative Planning

January 20, 2020 — Aarni Heiskanen - AEC Business
What makes construction different from manufacturing is its dynamic nature. Unlike a systemized production plant, a construction site is a mesh of interconnected processes that are far from optimized. The traditional top-down planning practice does not solve problems on the construction site, as recent research reveals. Making planning collaborative is a necessary step in making construction less wasteful. Everybody in the industry has felt frustration with inefficiencies in construction, but seeing the data is still disconcerting. I’ve had the pleasure of attending several workshops organized by the Finnish Aalto University’s research teams. These eye-opening events both revealed how much waste we have in construction today and suggested solutions to this problem. Four Aalto University graduate students shared insights from their research at a workshop of the Waste Workgroup of the Building 2030 consortium. They focused on projects where takt production, a lean construction method, had been used. Takt production breaks the work down into equally timed work batches and typically shortens project lead time considerably—up to 50%. However, even these well-planned projects included waste and unnecessary movement, as the researchers found out. Read the court decision
Read the full story...
Reprinted courtesy of Aarni Heiskanen, AEC Business
Mr. Heiskanen may be contacted at aec-business@aepartners.fi

Wilke Fleury Attorneys Recognized in “The Best Lawyers in America” & “Best Lawyers: One’s to Watch” 2024 Editions

September 06, 2023 — Wilke Fleury LLP
Congratulations 2024 Best Lawyers & Ones to Watch wf | Wilke Fleury David A. Frenznick, Kathryne E. Baldwin Daniel L. Egan, Adriana C. Cervantes, Jason G. Eldred Wilke Fleury is extremely proud to have two attorneys recognized in The Best Lawyers in America and three attorneys recognized in the Best Lawyers: Ones to Watch in America! Best Lawyers has been regarded by lawyers and the public for more than 40 years as the most credible measure of legal integrity and distinction in the United States. Read the court decision
Read the full story...
Reprinted courtesy of Wilke Fleury LLP

City Covered From Lawsuits Filed After Hurricane-Damaged Dwellings Demolished

January 15, 2014 — Tred R. Eyerly - Insurance Law Hawaii
The Fifth Circuit affirmed the District Court's finding that a duty to defend was owed St. Bernard Parish after it was sued for condemning and demolishing housing destroyed by Hurricane Katrina. Lexington Ins. Co. v. St. Bernard Parish Gov't, 2013 U.S. App. LEXIS 24292 (5th Cir. Dec. 6, 2013). St. Bernard's policies with Lexington provided coverage for "property damage" and "personal and advertising injury." The policies included a $10,000,000 per occurrence and aggregate limit, subject to a $250,000 retained limit. Lexington denied coverage and filed for a declaratory judgment that the policies' $250,000 retained limit applied separately to each alleged demolition or property damage asserted in the underlying actions. Under this theory, no defense would be owed because no property had a value exceeding $250,000. The District Court found that only one retained limit applied. Read the court decision
Read the full story...
Reprinted courtesy of Tred R. Eyerly, Insurance Law Hawaii
Mr. Eyerly may be contacted at te@hawaiilawyer.com

SEATTLE WASHINGTON BUILDING EXPERT DIRECTORY AND CAPABILITIES