Understanding Entitlement to Delays and Proper Support
December 10, 2024 —
Andrew G. Vicknair - The Dispute ResolverIn a previous
post, we discussed delays on construction projects including (1) critical versus non-critical delays, (2) excusable versus non-excusable delays, and (3) compensable versus non-compensable delays. We also reviewed the common methods of delay analysis include (1) the Total Cost Method, (2) the Modified Total Cost Approach, and (3) the Measured Mile Method.
Once you have determined the type of delay and the method to be used to analyze and quantify the delay, it is important to understand the type of documents/evidence needed to support your claim for delay.
If a party determines that they are entitled to some type of recovery for the delay, the party making a claim for delay, such as a contractor, must have the proper documentation/evidence to assist in proving entitlement for damages from the delay. Without the proper back-up, contractors are generally unable to recover all of the additional costs and expenses associated with the delays or, at best, recover only an “equitable” amount. Generally, damages must be proved with reasonable certainty and may not be based on speculation or conjecture. Thus, it is crucial for a party asserting a delay to have the proper documentation to support a delay claim, if the goal is to recover the damages associated with the delay.
Read the court decisionRead the full story...Reprinted courtesy of
Andrew G. Vicknair, D'Arcy Vicknair, LLCMr. Vicknair may be contacted at
agv@darcyvicknair.com
Home Sales Topping $100 Million Smash U.S. Price Records
May 07, 2014 —
Prashant Gopal – BloombergThe U.S. trophy-home market is shattering price records this year as an increasing number of residential properties change hands for more than $100 million.
Barry Rosenstein, founder of hedge fund Jana Partners LLC, has purchased an 18-acre (7.3-hectare) beachfront property in East Hampton, New York, for $147 million, according to the New York Post. That would break the U.S. single-family price record of $120 million set last month with the sale of a Greenwich, Connecticut, waterfront estate on 51 acres. In Los Angeles, a 50,000-square-foot (4,600-square meter) home sold in February for $102 million in cash after a bidding war.
The world’s richest people are moving cash to real estate as they seek havens for their wealth. In the U.S., an improving economy and stocks at a record are bolstering confidence among the affluent. Home purchases of $2 million or more jumped 33 percent in January and February from a year earlier to the highest level for the two-month period in data going back to 1988, according to an analysis by DataQuick.
Read the court decisionRead the full story...Reprinted courtesy of
Prashant Gopal, BloombergMr. Gopal may be contacted at
pgopal2@bloomberg.net
Do Not Forfeit Coverage Under Your Property Insurance Policy
February 22, 2021 —
David Adelstein - Florida Construction Legal UpdatesIf you have read prior articles (see
here and
here as an example), then you know that when it comes to first-party property insurance policies, an insured must comply with post-loss obligations in the policy. Failure to comply with a post-loss obligation gives the insurer the argument that the insured materially breached the policy and, therefore, forfeited rights to coverage. Naturally, this is avoidable by ensuring post-loss obligations are complied with, ideally under the guidance of counsel and qualified public adjusters to ensure your rights are being preserved and maximized.
[W]hen an insurer has alleged, as an affirmative defense to coverage, and thereafter has subsequently established, that an insured has failed to substantially comply with a contractually mandated post-loss obligation, prejudice to the insurer from the insured’s material breach is presumed, and the burden then shifts to the insured to show that any breach of post-loss obligations did not prejudice the insurer.
Universal Property & Casualty Ins. Co. v. Horne, 46 Fla.L.Weekly D201b (Fla. 3d DCA 2021) quoting American Integrity Ins. Co. v. Estrada, 276 So.3d 905, 916 (Fla. 3d DCA 2019).
Read the court decisionRead the full story...Reprinted courtesy of
David Adelstein, Kirwin Norris, P.A.Mr. Adelstein may be contacted at
dma@kirwinnorris.com
Traub Lieberman Partner Rina Clemens Selected as a 2023 Florida Super Lawyers® Rising Star
July 10, 2023 —
Rina Clemens - Traub LiebermanTraub Lieberman is pleased to announce that Rina Clemens of the Palm Beach Gardens office has been selected to the 2023 Florida Super Lawyers Rising Star list in the area of Personal Injury.
Super Lawyers, a Thomson Reuters business, is a rating service of lawyers from more than 70 practice areas, who have attained a high degree of peer recognition and professional achievement. The annual selections are made using a multiphase process that includes a statewide survey of lawyers, an independent research evaluation of candidates, and peer reviews by practice area. Please
click here to learn more about the methodology for selection.
Read the court decisionRead the full story...Reprinted courtesy of
Rina Clemens, Traub LiebermanMs. Clemens may be contacted at
rclemens@tlsslaw.com
The Connecticut Appellate Court Decides That Construction Contractor Was Not Obligated To Continue Accelerated Schedule to Mitigate Its Damages Following Late Delivery of Materials by Supplier
April 11, 2022 —
Robert M. Barrack - Gordon & ReesIn United Concrete Prods. v. NJR Constr., LLC, 207 Conn. App. 551, 263 A.3d 823 (2021), the Connecticut Appellate Court has issued a decision that should be of interest to the Connecticut construction industry and the construction bar. The lawsuit arose out of the late delivery of materials on a construction project, which is a frequent problem on construction projects. In United Concrete Products, the defendant general contractor, NJR Construction, LLC (“NJR”) was retained by the State of Connecticut Department of Transportation (“DOT”) to replace a bridge over the Hockanum River (“Project”). Id. at 555-58 (2021). The Prime Contract provided that NJR with an eight-week time-frame to perform the work, at which time the road would be closed to traffic. Id. The Prime Contract also provided for a bonus of $3,000 for each day the road was opened to traffic prior to the eight week deadline of August 8, 2016, and for liquidated damages of $3,000 for each day the road remained closed beyond the deadline. Id.
NJR subsequently entered into a purchase order (“Subcontract”) with the plaintiff, United Concrete Products, Inc. (“United”), whereby United agreed to provide certain concrete components for the Project, including ten pre-stressed concrete beams. Id. The Subcontract required that United deliver the concrete beams by June 7, 2016, but, NJR did not actually schedule the delivery until June 29, 2016. Id. Nevertheless, even with that schedule NJR could have reopened the road by July 19, 2016, which would have allowed it to receive the full $60,000 incentive bonus. However, United did not deliver the concrete beams until July 26, 2016, which caused NJR to lose the incentive bonus, be assessed liquidated damages by the DOT, and to incur additional delay damages. Id. After deducting the amount of $179,500 in damages that it incurred due to United’s late delivery of the beams, NJR paid United the balance of $66,074.75. Id.
Read the court decisionRead the full story...Reprinted courtesy of
Robert M. Barrack, Gordon Rees Scully Mansukhani, LLPMr. Barrack may be contacted at
rbarrack@grsm.com
DOI Aims to Modernize its “Inefficient and Inflexible” Type A Natural Resource Damages Assessment Regulations
March 25, 2024 —
Amanda G. Halter, Jillian Marullo & Ashleigh Myers - Gravel2Gavel Construction & Real Estate Law BlogThe U.S. Department of the Interior (DOI) published a
proposed rule aimed at modernizing and streamlining the “Type A” Natural Resource Damage Assessment (NRDA) regulations under the Comprehensive Environmental Response, Compensation, and Liability Act (CERCLA) and the Clean Water Act (CWA). (The comment deadline was later
extended.) The revisions,
first previewed in a January 2023 Advanced Notice of Proposed Rulemaking (ANPR), are intended to fulfill “the original statutory purpose of providing a streamlined and simplified assessment process” with the overarching goal of facilitating settlements and expediting restoration efforts following injury resulting from pollution in a broader range of cases.
The NRDA regulations provide two paths to assessing natural resource damages (NRD): (1) the more complex, site-specific Type B procedures for detailed NRDAs and (2) what is intended to be the standard, simplified Type A assessment procedures requiring minimal field observation. Particularly, the Type A process is reserved for two specific aquatic environments (coastal and marine areas or Great Lakes environments) when a relatively minor release of a single hazardous substance occurs, resulting in a smaller scale and scope of natural resource injury, and the rebuttal presumption for the Type A procedure is limited to damages of $100,000 or less under the current version of the rule.
Reprinted courtesy of
Amanda G. Halter, Pillsbury,
Jillian Marullo, Pillsbury and
Ashleigh Myers, Pillsbury
Ms. Halter may be contacted at amanda.halter@pillsburylaw.com
Ms. Marullo may be contacted at jillian.marullo@pillsburylaw.com
Ms. Myers may be contacted at ashleigh.myers@pillsburylaw.com
Read the court decisionRead the full story...Reprinted courtesy of
New Jersey Supreme Court Rules that Subcontractor Work with Resultant Damage is both an “Occurrence” and “Property Damage” under a Standard Form CGL Policy
September 01, 2016 —
Beverley BevenFlorez-CDJ STAFFAccording to a client alert by the firm Peckar & Abramson, P.C. (P&A), “In a recent significant decision, the Supreme Court of New Jersey held that defective work of a subcontractor that causes consequential property damage is both an ‘occurrence’ and ‘property damage’ under the terms of a standard form commercial general liability (“CGL”) insurance policy.”
Patrick J. Greene, Jr., and Frank A. Hess of P&A wrote that the Cypress Point Condominium Assoc., Inc. v Adria Towers, LLC, 2016 N.J. Lexis 847 (Aug.4,2016) “decision is important in New Jersey and in other jurisdictions that had relied upon the influential New Jersey case, Weedo v. Stone–E–Brick, Inc., 81 N.J. 233 (1979), that had determined that such claims involved non-insured ‘business risks.’”
Read the court decisionRead the full story...Reprinted courtesy of
New Case Alert: California Federal Court Allows Policy Stacking to Cover Continuous Injury
November 23, 2016 —
William S. Bennett - Saxe Doernberger & Vita, P.C.“Stacking” is a practice that is very favorable for policyholders, especially in environmental coverage cases involving extended pollution events. It allows a policyholder to combine the limits of multiple consecutive policies to cover continuous injury claims occurring over multiple policy periods. Without stacking, insurers can limit a policyholder’s recovery to a single policy limit.
The Eastern District of California recently decided that a policyholder could stack the limits of six consecutive policies, where the occurrence was a continuous injury spanning all six policy years. Among other rulings, the court determined that the plain language of the policy under dispute did not prevent stacking.
Read the court decisionRead the full story...Reprinted courtesy of
William S. Bennett, Saxe Doernberger & Vita, P.C.Mr. Bennett may be contacted at
wsb@sdvlaw.com