Cambridge Massachusetts Building Expert Directory

Pacing in Construction Scheduling Disputes

September 14, 2017 — Luke Mecklenburg - Snell & Wilmer Real Estate Litigation Blog
On a high level, construction delay litigation involves sorting out the impacts to the critical project path and determining which party is responsible for those impacts. One of the more difficult elements of this process is determining whether a delay would have occurred regardless of one party’s critical path impact due to a separate, independent impact to the critical path by the other party. For example, a contractor cannot collect delay damages for delays caused by the owner if the contractor itself was causing independent impacts that would have pushed off the completion date anyway. However, the concept of “pacing” provides a potential defense for a party who is not on pace with the as-planned schedule for noncritical activities, even where those activities are still ongoing after the planned completion date. “Pacing delays” are a type of concurrent delay that occur when one party makes a conscious decision to decelerate or slow down the pace of noncritical activities to keep pace with the critical delays of another party. A more formal definition would be “deceleration of the work of the project, by one of the parties to a contract, due to a delay caused by the other party, so as to maintain steady progress with the revised overall project schedule.” Zack, Pacing Delays–The Practical Effect, Construction Specifier 47, 48 (Jan. 2000). A party to the construction process may decide to slow down its performance of noncritical activities to keep pace with the delayed progress. For example, contractors may adjust the pace of their work in light of delays in owner-furnished equipment, delays by other multiple prime contractors, delays in permits, limited access, or differing site conditions. Owners may slow down their response time to requests for information or submittals, or postpone the delivery of owner-furnished equipment or the processing of change orders. Id. at 48. Read the court decision
Read the full story...
Reprinted courtesy of Luke Mecklenburg, Snell & Wilmer
Mr. Mecklenburg may be contacted at lmecklenburg@swlaw.com

Kushner Company Files Suit Against Jersey City Over Delays to Planned Towers

July 10, 2018 — Associated Press - Engineering News-Record
JERSEY CITY, N.J. (AP) — Jared Kushner's family company has filed a lawsuit against a New Jersey city, saying it forced the delay of a major twin-tower project due to "political animus" toward President Donald Trump. Read the court decision
Read the full story...
Reprinted courtesy of Engineering News-Record
ENR staff may be contacted at ENR.com@bnpmedia.com

Are Untimely Repairs an “Occurrence” Triggering CGL Coverage?

January 17, 2023 — Christopher G. Hill - Construction Law Musings
All Class A commercial contractors in Virginia are required to have a minimum level of Commercial General Liability (CGL) coverage. As a general rule, this insurance is there for damage to property or persons arising from an “occurrence” that is covered by the policy. Many cases that are litigated relating to coverage for certain events under a CGL policy turn on the definition of “occurrence” and whether the event leading to a request for coverage constitutes an “occurrence.” A recent case in Fairfax County, Virginia, Erie Insurance Exchange v. Spalding Enterprises, et al., is just such a case. In the Spalding Enterprises case, the Court considered the following scenario. A homeowner, Mr. Yen contracted with Spalding Enterprises to fix some fire damage at his home. Spalding promised the repairs would be complete in October of 2019. However, after Mr. Yen paid a $300,000.00 deposit, Spalding Enterprises stated that the work would not be completed until November of 2019. Yen then fired Spalding Enterprises and sued for breach of contract, constructive fraud, and violation of the Virginia Consumer Protection Act. Spalding Enterprises sought coverage from Erie Insurance for the claim and Erie denied coverage and sought a declaratory judgment that the events alleged in the Complaint by Mr. Yen did not fall under the definition of “occurrence” in the CGL policy held by Spalding Enterprises. Read the court decision
Read the full story...
Reprinted courtesy of The Law Office of Christopher G. Hill
Mr. Hill may be contacted at chrisghill@constructionlawva.com

What are Section 8(f) Agreements?

July 02, 2018 — Wally Zimolong – Supplemental Conditions
Like many areas of federal labor law, there are different rules for construction industry employers. One major difference is in how employers become unionized. Typically, under Section 9(a) of the National Labor Relations Act, a union becomes a collective bargaining agent of employees only after a majority of employees show support for union representation. In other words, the employees chose whether to be represented by a particular union. However, under Section 8(f) of the NLRA, construction industry employers can choose to become union without any showing of majority support by employees. In fact, construction industry employers don’t need to have any employees at all to sign a “8(f) agreement.” Thus, these agreements have become known as pre-hire agreements. Read the court decision
Read the full story...
Reprinted courtesy of Wally Zimolong, Zimolong LLC
Mr. Zimolong may be contacted at wally@zimolonglaw.com

Former Sponsor of the Lenox Facing Suit in Supreme Court

January 13, 2014 — Melissa Zaya-CDJ STAFF
Lewis Futterman, former sponsor of the Lenox condominium in Harlem, New York, is being sued by the condo board for alleged “building code violations, construction defects, and fraud” according to New York Curbed. The residents claim that Futterman filed for bankruptcy in 2010 to avoid paying for repairs. The Lenox condo board filed suit in the New York Supreme Court last December 31st. The Lenox’s condo board claims that the building has “fundamental structural flaws, a defective roof and pervasive leakage,” reports Rowley Amato of New York Curbed. The board also claims the original offering plans were not the same as the units purchased by residents in 2006. Residents paid an estimated two hundred and sixty thousand to repair defects within the condominium, and they are pursuing a minimum of four million in damages. Katherine Clarke of The Real Deal stated that Futterman would only “say that the issue was between the residents and the construction company which built the project.” Read the full story at New York Curbed... Read the full story at The Real Deal... Read the court decision
Read the full story...
Reprinted courtesy of

Construction Law Client Alert: California Is One Step Closer to Prohibiting Type I Indemnity Agreements In Private Commercial Projects

June 15, 2011 — Haight Brown & Bonesteel, LLP

On June 1, 2011 by majority vote, the California Senate passed Senate Bill 474, which would amend Civil Code section 2782, and add Civil Code section 2782.05. The passage of this new law is a critical development for real estate developers, general contractors and subcontractors because it will affect how these projects are insured and how disputes are resolved.

Civil Code section 2782 was amended in 2007 to prohibit Type I indemnity agreements for residential projects only. Since 2007, various trade associations and labor unions have lobbied to expand those very same restrictions to other projects. These new provisions apply to contracts, entered into after January 1, 2013, that are not for residential projects, and that are not executed by a public entity. The revisions provide that any provision in a contract purporting to indemnify, hold harmless, and defend another for their negligence or other fault is against public policy and void. These provisions cannot be waived.

A provision in a contract requiring additional insured coverage is also void and unenforceable to the extent it would be prohibited under the new law. Moreover, the new law does not apply to wrap-up insurance policies or programs, or a cause of action for breach of contract or warranty that exists independently of the indemnity obligation.

The practical impact of this new law is that greater participation in wrap-up insurance programs will likely result. While many wrap-up programs suffer from problems such as insufficient limits, and disputes about funding the self-insured retention, the incentive for the developer or general contractor to utilize wrap-up insurance will be greater than ever before because they will no longer be able to spread the risk of the litigation to the trades and the trade carriers.

Read the full story…

Reprinted courtesy of Steve Cvitanovic of Haight Brown & Bonesteel, LLP.

Read the court decision
Read the full story...
Reprinted courtesy of

Rhode Island District Court Dismisses Plaintiff’s Case for Spoliation Due to Potential Unfair Prejudice to Defendant

September 04, 2018 — Lian Skaf - The Subrogation Strategist
In Amica Mutual Ins. Co. v. BrassCraft Mfg., Co., 2018 U.S. Dist. LEXIS 88986 (D.R.I. May 29, 2018), the United States District Court for the District of Rhode Island addressed the question of whether the defendant was so unfairly prejudiced by the subrogating insurer’s spoliation of evidence that dismissal of the plaintiff’s case was the appropriate Rule 37(b)(2)(a)(i)-(vi) sanction. The court, focusing on the potential for undue prejudice to the defendant, granted the defendant’s motion to dismiss. Read the court decision
Read the full story...
Reprinted courtesy of Lian Skaf, White and Williams, LLP
Mr. Skaf may be contacted at skafl@whiteandwilliams.com

Construction Defect Notice in the Mailbox? Respond Appropriately

August 04, 2011 — Douglas Reiser, Builders Council Blog

Recently, I have seen a rash of ignored construction defect notices. What is a construction defect notice? It’s a statutorily required notice, sent from a homeowner to a contractor, listing a number of defects found at their property. If you get one, don’t ignore it.

The Revised Code of Washington includes a number of provisions intended for residential construction disputes. Among them is the “Notice to Customer” requirement in RCW 18.27.114, which can preempt a contractor’s lien rights, and the “Notice of Construction Defects” found in RCW 64.50.020.

The Notice of Construction Defects is a standard notice mandated by RCW 64.50, a chapter in the Revised Code of Washington, intended to provide a pre-litigation resolution process for contractors and consumers. The chapter applies only to those losses “caused by a defect in the construction of a residence or in the substantial remodel of a residence.”(See “Action” RCW 64.50.010).

Unfortunately, many contractors will simply ignore these notices or tell the homeowner to make a warranty claim. But, the notice actually provides a contractor with a forty-five (45) day window to alleviate the dispute.