Fairfield Connecticut Building Expert Directory

Is The Enforceability Of A No-Damage-For-Delay Provision Inappropriate For Summary Judgment

February 24, 2020 — David Adelstein - Florida Construction Legal Updates
Is the enforceability of a no-damage-for-delay provision inappropriate for resolution on a summary judgment? The recent decision in U.S. f/u/b/o Kingston Environmental Services, Inc. v. David Boland, Inc., 2019 WL 6178676 (D. Hawaii 2019), dealing with Florida law, suggests that it is inappropriate for a summary judgment resolution, particularly when there is a right to a jury trial. In this case, a prime contractor was hired on a federal construction project in Hawaii. The prime contractor hired a subcontractor and the subcontractor sued the prime contractor and its surety under the Miller Act. Of interest, the subcontractor was seeking to recover for the costs it incurred due to construction delays. The prime contractor moved for summary judgment as to the no-damage-for-delay provision in the subcontract. The no-damages-for-delay provision read as follows (and it is a well-written no-damage-for-delay provision): The Subcontractor expressly agrees that the Contractor shall not be liable to the Subcontractor for any damages or additional costs, whether foreseeable or unforeseeable, resulting in whole or in part from a delay, hindrance, suspension, or acceleration of the commencement or execution of the Work, caused in whole or in part by the acts or omissions, whether negligent or not, of the Contractor including other subcontractors or material suppliers to the Project, its agents, employees, or third parties acting on behalf of the Contractor. The Subcontractor’s sole remedy for any such delay, hindrance, suspension, or acceleration shall be a noncompensable time extension. Read the court decision
Read the full story...
Reprinted courtesy of David Adelstein, Kirwin Norris, P.A.
Mr. Adelstein may be contacted at dma@kirwinnorris.com

Real Estate Trends: Looking Ahead to 2021

November 09, 2020 — Adam Weaver - Gravel2Gavel Construction & Real Estate Law Blog
2020 has been an unprecedented year, and, while there are likely more twists and turns to come before December 31, it is essential to look at how the real estate markets have changed this year and which trends are likely to continue into 2021. The COVID-19 pandemic has impacted nearly every industry, including commercial real estate, and its impact will continue to influence the market and commercial real estate long after the virus has been eradicated. Commercial Real Estate Loan Modifications As the United States’ economy stalled, shut down and slowly started to recover throughout 2020, many businesses were negatively impacted, and most property owners found themselves negotiating with both their lenders and tenants. As tenants were unable to pay rent, property owners were unable to service their debt, which led to a surge of loan modifications this year. This trend certainly will continue through the first half of 2021, as the economy continues to recover. Read the court decision
Read the full story...
Reprinted courtesy of Adam Weaver, Pillsbury
Mr. Weaver may be contacted at adam.weaver@pillsburylaw.com

High Court Case Review Frees Jailed Buffalo Billions Contractor CEO

August 22, 2022 — Mary B. Powers & Debra K. Rubin - Engineering News-Record
Hidden amid the U.S. Supreme Court's flurry of high-profile rulings that ended its current term—such as overturning Roe v. Wade and scaling back federal regulation of greenhouse gas emissions—was a less-noticed decision to take a case next year that could change the fortunes of a convicted New York contractor who was serving a federal prison term for bid-rigging. Reprinted courtesy of Mary B. Powers, Engineering News-Record and Debra K. Rubin, Engineering News-Record Ms. Rubin may be contacted at rubind@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

Crypto and NFTs Could Help People Become Real Estate Tycoons

June 21, 2021 — Josh D. Morton - Gravel2Gavel Construction & Real Estate Law Blog
By using online cryptocurrency technologies like tokens and blockchains, people could participate in real estate transactions that are too unwieldy in the analog world. Soon, these technologies may let anyone with a few thousand dollars play tycoon and buy a part of a condo or iconic building. NFTs, or non-fungible tokens—digital certificates that convey exclusive rights to something—is a new concept being applied to real estate, supporters say they will become standard in the industry. “The NFT operates in many respects exactly like a deed would in real estate transactions,” said Josh Morton, a Real Estate special counsel at Pillsbury. “What a deed ordinarily does is give evidence of ownership to a piece of property.” Read the court decision
Read the full story...
Reprinted courtesy of Josh D. Morton, Pillsbury
Mr. Morton may be contacted at josh.morton@pillsburylaw.com

Update Regarding New York’s New Registration Requirement for Contractors and Subcontractors Performing Public Works and Covered Private Projects

February 06, 2023 — Christopher B. Kinzel, K. Greer Kuras, Aaron C. Schlesinger - Peckar & Abramson, P.C.
Some significant changes are being made by chapter amendments (S.838 and A.984) to Section 220-i of New York’s Labor Law. Contractors and subcontractors bidding on public contracts and performing work on covered private projects will have two years (by December 30, 2024) to register with the Department of Labor, Bureau of Public Works, rather than one year. The amendments also remove the requirement that a contractor submit registration certificates for all its subcontractors at the time its bid is submitted; amend language with respect to notice and hearing requirements; require re-registration to occur not less than 90 days before expiration; and add language to require a monitor to oversee ongoing work if a contractor or subcontractor is found unfit. The stated purpose of the law is to help enforce New York’s prevailing wage and other worker protection laws. The DOL will create an online system through which contractors and subcontractors will have to answer questions and submit documents about:

the business entity and its owners and officers
unemployment and workers’ compensation insurance
any outstanding wage assessments
debarment under New York or federal law, or any other state’s laws
final determinations of a violation of any labor laws, employment tax laws, or workplace safety standards (including OSHA)
association or signatory to an apprenticeship program

Reprinted courtesy of Christopher B. Kinzel, Peckar & Abramson, P.C., K. Greer Kuras, Peckar & Abramson, P.C. and Aaron C. Schlesinger, Peckar & Abramson, P.C. Mr. Kinzel may be contacted at ckinzel@pecklaw.com Ms. Kuras may be contacted at gkuras@pecklaw.com Mr. Schlesinger may be contacted at aschlesinger@pecklaw.com Read the court decision
Read the full story...
Reprinted courtesy of

Senate Overwhelmingly Passes Water Infrastructure Bill

November 06, 2018 — Tom Ichniowski – Engineering News-Record
Congress has approved major water infrastructure legislation that authorizes $3.7 billion for new Army Corps of Engineers civil-works projects and $4.4 billion for the Environmental Protection Agency drinking-water program. Read the court decision
Read the full story...
Reprinted courtesy of Tom Ichniowski, ENR
Mr. Ichniowski may be contacted at ichniowskit@enr.com

‘Like a War Zone’: Malibu Fire Ravages Multimillion-Dollar Homes

December 04, 2018 — John Gittelsohn, Anousha Sakoui, & Christopher Palmeri - Bloomberg
Malibu resident Lance Schultz was jolted awake at 2 a.m. Friday with word that he needed to evacuate. With a roaring fire approaching the coastal community, he gathered his girlfriend, dog and 8-month-old son and headed to nearby Zuma Beach. He returned Sunday to survey the damage. His home was saved after his girlfriend’s 82-year-old father returned to hose down the property he had built years before. But Schultz estimates about one-fifth of the houses in the neighborhood are gone, including a mansion down the block that was on sale for $16 million. Much of the rest of the area is covered in black soot. Read the court decision
Read the full story...
Reprinted courtesy of John Gittelsohn, Anousha Sakoui, & Christopher Palmeri, Bloomberg

What ENR.com Construction News Gained the Most Views

January 09, 2023 — C.J. Schexnayder - Engineering News-Record
As the construction industry continued its ongoing recovery from the global pandemic in 2022, it also faced a number of formidable challenges—including staffing gaps, materials shortages, supply chain delays and the ongoing specter of inflation. Throughout the year, ENR editors reported on how these issues—and many more—were impacting the sector and how it responded. Reprinted courtesy of C.J. Schexnayder, Engineering News-Record Mr. Schexnayder may be contacted at schexnayderc@enr.com Read the full story... Read the court decision
Read the full story...
Reprinted courtesy of

FAIRFIELD CONNECTICUT BUILDING EXPERT DIRECTORY AND CAPABILITIES